Indicative reprint noteThis is an unofficial version of a reprint of this Act that incorporates all proposed amendments to the Act included in the Building and Other Legislation Amendment Bill 2022. This indicative reprint has been prepared for information only—it is not an authorised reprint of the Act.Some enacted but uncommenced amendments included in the State Penalties Enforcement Amendment Act 2017 No. 13 and the Building Industry Fairness (Security of Payment) and Other Legislation Amendment Act 2020 No. 24 have also been incorporated in this indicative reprint.The point-in-time date for this indicative reprint is the introduction date for the Building and Other Legislation Amendment Bill 2022—29 March 2022.Detailed information about indicative reprints is available on the Information page of this website.Queensland Building and Construction Commission Act 1991An Act to regulate the building industryPart 1Preliminary1Short titleThis Act may be cited as the Queensland Building and Construction Commission Act 1991.s 1 amd 2013 No. 38s 42s 2 om 1998 No. 13s 1863Objects of ActThe objects of this Act are—

(a)to regulate the building industry—

(i)to ensure the maintenance of proper standards in the industry; and

(ii)to achieve a reasonable balance between the interests of building contractors and consumers; and

(b)to provide remedies for defective building work; and

(c)to provide support, education and advice for those who undertake building work and consumers; and

(d)to regulate domestic building contracts to achieve a reasonable balance between the interests of building contractors and building owners; and

(e)to regulate building products to ensure—

(i)the safety of consumers and the public generally; and

(ii)persons involved in the production, supply or installation of building products are held responsible for the safety of the products and their use; and

(f)to provide for the proper, efficient and effective management of the commission in the performance of its functions.

s 3 amd 2000 No. 10s 183sch 1; 2014 No. 57s 4; 2017 No. 29s 4; 2017 No. 43s 2514DefinitionsThe dictionary in schedule 2 defines particular words used in this Act.s 4 amd 1999 No. 43s 4(1)Note—s 4 contained definitions for this Act. Definitions are now located in sch 2—Dictionary.4AAWho is an influential person for a company(1)An influential person, for a company, is an individual, other than a director or secretary of the company, who is in a position to control or substantially influence the company’s conduct.(2)However, an influential person does not include—

(a)a professional, only because the advice given by the professional influences the company’s conduct; or

(b)a regulator, only because the regulator, when exercising a power or performing a function under an Act or other law, influences the company’s business; or

(c)an administrator, controller, provisional liquidator or liquidator within the meaning of the Corporations Act, section 9.

(3)Without limiting subsection (1), a person may be an influential person for a company if the person—

(a)is the chief executive officer or general manager of the company, or holds an equivalent position in the company; or

(b)is acting in a position mentioned in paragraph (a); or

(c)directly or indirectly owns, holds or controls 50% or more of the shares in the company, or 50% or more of a class of shares in the company; or

(d)gives instructions to an officer of the company and the officer generally acts on those instructions; or

(e)makes, or participates in making, decisions that affect the whole or a substantial part of the company’s business or financial standing; or

(f)engages in conduct or makes representations that would cause someone else to reasonably believe the person controls, or substantially influences, the company’s business.

(4)In this section—professional—

(a)means a person who provides professional advice to more than 1 client; but

(b)does not include a person who provides professional advice to a client in the person’s capacity as an employee of the client.Example—a lawyer or accountant, employed in that capacity by a firm of lawyers or accountants, engaged by a company to give the company advice on a particular topic

regulator means—

(a)a person employed by a State, a local government or the Commonwealth; or

(b)a person engaged by a State, a local government or the Commonwealth to provide a particular service or carry out a particular activity; or

(c)an agent of a person mentioned in paragraph (b) if, in that capacity, the person provides the service or carries out the activity the person is engaged to provide or carry out.

s 4AA prev s 4AA ins 2003 No. 1s 4om 2007 No. 47s 4pres s 4AA ins 2017 No. 43s 2524BAct binds all personsThis Act binds all persons, including the State and, so far as the legislative power of the Parliament permits, the Commonwealth and the other States.s 4B ins 1999 No. 43s 54CCertain building contractors not boundParts 5 and 6 do not bind a building contractor to the extent that the business carried on by the building contractor consists of or includes—

(a)carrying out completed building inspections; or

(b)contract administration carried out in relation to building work designed by the building contractor.

s 4C ins 1999 No. 43s 5sub 2003 No. 1s 5Part 2AQueensland Building and Construction Employing Officept 2A hdg ins 2007 No. 20s 54amd 2013 No. 38s 14sch 1Division 1Establishment and functions of employing officept 2A div 1 hdg ins 2007 No. 20s 5429AEstablishment of employing office(1)The Queensland Building and Construction Employing Office is established.(2)The employing office consists of—

(a)the executive officer; and

(b)the employees of the employing office.

(3)The employing office is a separate entity from the commission.s 29A ins 2007 No. 20s 54amd 2013 No. 38s 14sch 129BEmploying office represents the State(1)The employing office represents the State.(2)Without limiting subsection (1), the employing office has the status, privileges and immunities of the State.s 29B ins 2007 No. 20s 5429CFunctions of employing office(1)The main functions of the employing office are—

(a)entering into, for the State, a work performance arrangement with the commission under which employees of the employing office perform work for the commission; and

(b)employing, for the State, staff to perform work for the commission under the work performance arrangement; and

(c)doing anything incidental to the discharge of the functions mentioned in paragraphs (a) and (b).

(2)Also, the employing office has any other function conferred on the employing office under this or another Act.(3)This section does not limit the employing office’s power to enter into and give effect to a work performance arrangement under section 29G with a government entity other than the commission.s 29C ins 2007 No. 20s 54amd 2013 No. 38s 14sch 1Division 2Executive officerpt 2A div 2 hdg ins 2007 No. 20s 5429DAppointment of executive officer(1)There is to be an executive officer of the employing office.(2)The executive officer is to be appointed by the Governor in Council.(3)The executive officer is appointed under this Act and not under the Public Service Act 2008.s 29D ins 2007 No. 20s 54amd 2009 No. 25s 83sch29EExecutive officer acting for employing office(1)The employing office acts through the executive officer.(2)Anything done by the executive officer in the name of, or for, the employing office is taken to have been done by the employing office.s 29E ins 2007 No. 20s 54Division 3Staff of employing officept 2A div 3 hdg ins 2007 No. 20s 5429GEmploying office may enter into work performance arrangements(1)The employing office may, for the State, enter into and give effect to a work performance arrangement with—

(a)the commission; or

(b)the appropriate authority of another government entity.

(2)A work performance arrangement may make provision for all matters necessary or convenient to be provided under the arrangement.(3)For example, a work performance arrangement may provide for—

(a)the appointment of a person to an office, and the holding of the office by the person, for the arrangement; and

(b)the authorising of a person to exercise powers for the arrangement; and

(c)whether payment is to be made for work done under the arrangement and, if so, what payment is to be made and who is to make the payment.

(4)A person performing work for the commission or other government entity under a work performance arrangement entered into under subsection (1)—

(a)is not employed by the commission or other government entity; and

(b)remains an employee of the employing office.

(5)To remove any doubt, it is declared that the commission or another government entity does not have power to employ a person performing work for the commission or other government entity under a work performance arrangement entered into under subsection (1).s 29G ins 2007 No. 20s 54amd 2013 No. 38s 14sch 1Division 4Other provisionspt 2A div 4 hdg ins 2007 No. 20s 5429HEmploying office is statutory body(1)The employing office is a statutory body under—

(a)the Financial Accountability Act 2009; and

(b)the Statutory Bodies Financial Arrangements Act 1982.

(2)For applying the Financial Accountability Act 2009 to the employing office as a statutory body—

(a)the executive officer is taken to be the chairperson of the employing office; and

(b)the Financial Accountability Act 2009 is taken to require the executive officer to consider the annual financial statements and the auditor-general’s report as soon as practicable after they are received by the employing office; and

(c)the Financial Accountability Act 2009 is taken to require the executive officer to consider any observations, suggestions or comments given to the executive officer under the Auditor-General Act 2009 as soon as practicable after the executive officer receives them.

s 29H ins 2007 No. 20s 54amd 2009 No. 9s 136sch 1Part 3AExcluded individuals and excluded companiespt 3A hdg ins 1999 No. 43s 28amd 2014 No. 57s 18Division 1Preliminarypt 3A div 1 hdg ins 1999 No. 43s 2856AAs 56AA ins 1999 No. 43s 28om 2003 No. 1s 2656ABOperation of pt 3AThis part has effect despite anything in part 3, but does not apply to—

(a)a fire protection occupational licence; or

(b)a mechanical services occupational licence.

s 56AB ins 1999 No. 43s 28amd 2007 No. 47s 31; 2018 No. 17s 189; 2020 No. 24s 13956ACExcluded individuals and excluded companies(1)This section applies to an individual if—

(a)the individual takes advantage of the laws of bankruptcy or becomes bankrupt (relevant bankruptcy event); and

(b)3 years have not elapsed since the relevant bankruptcy event happened.

(2)This section also applies to an individual if—

(a)a construction company, for the benefit of a creditor—

(i)has a provisional liquidator, liquidator, administrator or controller appointed; or

(ii)is wound up, or is ordered to be wound up; and

(b)3 years have not elapsed since the event mentioned in paragraph (a)(i) or (ii) (relevant company event) happened; and

(c)the individual—

(i)was, when the relevant company event happened, a director or secretary of, or an influential person for, the construction company; or

(ii)was, within the period of 2 years immediately before the relevant company event happened, a director or secretary of, or an influential person for, the construction company.

(3)If this section applies to an individual because of subsection (1), the individual is an excluded individual for the relevant bankruptcy event.(4)If this section applies to an individual because of subsection (2), the individual is an excluded individual for the relevant company event unless the individual can satisfy the commissioner that at the time the individual ceased to be an influential person, director or secretary for the construction company the company was solvent.(5)An excluded individual for a relevant event does not also become an excluded individual for another relevant event if the commission is satisfied that both events are consequences flowing from what is, in substance, the one set of circumstances.(6)A company is an excluded company if an individual who is a director or secretary of, or an influential person for, the construction company is an excluded individual for a relevant event.(7)In this section—construction company—

(a)means a company that directly or indirectly carries out building work or building work services in this or another State; and

(b)includes a company that, within 2 years immediately before a relevant company event for the company, directly or indirectly carries out building work or building work services in this or another State.

s 56AC ins 1999 No. 43s 28amd 2014 No. 56s 60; 2014 No. 57s 19; 2017 No. 43s 273Division 2pt 3A div 2 hdg ins 1999 No. 43s 28om 2014 No. 57s 2056ADs 56AD ins 1999 No. 43s 28amd 2003 No. 1s 27; 2003 No. 30s 169sch 1; 2007 No. 47s 32; 2013 No. 38s 14sch 1; 2014 No. 56s 61om 2014 No. 57s 20Division 3Licence exclusion and cancellationpt 3A div 3 hdg ins 1999 No. 43s 2856AEExclusion from licenceThe commission must not grant a person a licence if the person is—

(a)an excluded individual for a relevant event; or

(b)an excluded company.

s 56AE ins 1999 No. 43s 28amd 2003 No. 1s 28; 2013 No. 38s 14sch 156AFProcedure if licensee is excluded individual(1)This section applies if the commission considers that an individual who is a licensee is an excluded individual for a relevant event.(2)The commission must give the individual a written notice identifying the relevant event and stating the following—

(a)why the commission considers the individual is an excluded individual for the relevant event;

(b)that the individual may make a submission to the commission about the relevant event within the reply period;

(c)the circumstances, stated in subsection (3), in which the commission must cancel the individual’s licence.

(3)The commission must cancel the individual’s licence, by written notice given to the individual, if—

(a)after considering any submission about the notice made by the individual within the reply period, the commission still considers the individual is an excluded individual for a relevant event; or

(b)the individual does not make a submission about the notice within the reply period.

(4)Section 49 does not apply to a cancellation under subsection (3).(5)In this section—reply period, for a written notice given under subsection (2), means 28 days after the commission gives an individual the written notice.s 56AF ins 1999 No. 43s 28amd 2003 No. 1s 29; 2013 No. 38s 14sch 1; 2014 No. 57s 2156AGProcedure if licensee is excluded company(1)This section applies if the commission considers that a company that is a licensee is an excluded company.(2)The commission must give the company a written notice stating the following—

(a)particulars identifying the individual (the relevant individual) who is a director or secretary of, or an influential person for, the company and who is an excluded individual for a relevant event;

(b)particulars identifying the relevant event;

(c)within 28 days after the commission gives the company the written notice, the relevant individual must stop being a director, secretary or influential person;

(d)the circumstances, stated in subsection (3), in which the commission must cancel the company’s licence.

(3)The commission must cancel the company’s licence by written notice given to the company if, within the 28 days mentioned in subsection (2)(c), the relevant individual does not stop being a director or secretary of, or an influential person for, the company.(4)Section 49 does not apply to a cancellation under subsection (3).s 56AG ins 1999 No. 43s 28amd 2003 No. 1s 30; 2013 No. 38s 14sch 1; 2014 No. 57s 22; 2020 No. 24s 12056AHReview by tribunal of commission’s opinion(1)This section applies if the commission considers under section 56AF or 56AG (the relevant section) that a person is an excluded individual or excluded company, or that an individual is still a director or secretary of, or an influential person for, a company.(2)If a person applies for a review of the commission’s decision, the application for review does not affect anything already done or in force under the relevant section, but periods of time mentioned in the relevant section are taken to stop running until the review is finished.s 56AH ins 1999 No. 43s 28amd 2000 No. 10s 183sch 1; 2013 No. 38s 14sch 1Division 4Publication of details of particular excluded individualspt 3A div 4 hdg ins 2020 No. 24s 14056AI Publication of relevant details about excluded individuals who are not licensees(1)The commission may publish the relevant details for an individual if—

(a)the individual is not a licensee; and

(b)the commission has decided under section 56AK to publish the details; and

(c)all periods for applying for a review of the decision, or appealing against a decision made on review, have ended; and

(d)any review or appeal mentioned in paragraph (c) is finally decided or is not proceeded with.

(2)The relevant details for the individual are—

(a)the individual’s full name and business address; and

(b)if the individual is or has been known by another name—all other names the individual is or has been known by; and

(c)that the individual is an excluded individual for a stated relevant event; and

(d)the date the 3-year period mentioned in section 56AC(1)(b) or (2)(b) ends; and

(e)any other particulars prescribed by regulation.

(3)The individual’s relevant details may be published under subsection (1) on the commission’s website.(4)Despite subsection (1)—

(a)if the individual’s business address is the same as the individual’s residential address, the only part of the address that may be published is the suburb or locality in which the individual’s business is located; and

(b)no details may be published about the individual after the day that is 10 years from the day the details were first published under this section.

s 56AI ins 2020 No. 24s 14056AJ Show cause notice(1)This section applies if the commission considers an individual who is not a licensee is an excluded individual for a relevant event.(2)The commission may give the individual a written notice (a show cause notice) identifying the relevant event and stating the following—

(a)why the commission considers the individual is an excluded individual for the relevant event;

(b)that, within 28 days after the commission gives the show cause notice, the individual may give the commission a written submission to show why the individual is not an excluded individual for the relevant event;

(c)that the commission may publish the individual’s relevant details if—

(i)the individual does not make a written submission mentioned in paragraph (b); or

(ii)after considering a written submission made by the individual, the commission is satisfied the individual is an excluded individual for the relevant event.

(3)The individual may, within 28 days after the show cause notice is given to the individual, give the commission a written submission to show why the individual is not an excluded individual for the relevant event.s 56AJ ins 2020 No. 24s 14056AK Decision by commission about whether to publish the individual’s relevant details(1)This section applies if—

(a)after considering a written submission made by an individual under section 56AJ(3), the commission is satisfied the individual is an excluded individual for the relevant event; or

(b)the individual does not make a written submission under section 56AJ(3).

(2)The commission may decide to publish the individual’s relevant details.(3)The commission must give the individual written notice of its decision.(4)If the decision is to publish the individual’s relevant details, the notice must inform the individual of the individual’s right to apply to the tribunal for a review of the decision.s 56AK ins 2020 No. 24s 140Part 3BPermanently excluded individualspt 3B hdg ins 2003 No. 1s 31Division 1Preliminarypt 3B div 1 hdg ins 2003 No. 1s 3157Operation of pt 3BThis part has effect despite anything in part 3, but does not apply to—

(a)a fire protection occupational licence; or

(b)a mechanical services occupational licence.

s 57 prev s 57 om 2000 No. 9s 104sch 1pres s 57 ins 2003 No. 1s 31amd 2007 No. 47s 33; 2018 No. 17s 190; 2020 No. 24s 14158Meaning of permanently excluded individual(1)A permanently excluded individual is an individual—

(a)who has twice been an excluded individual for a relevant event; and

(b)who for each relevant event has been given written notice by the commission stating—

(i)particulars identifying the relevant event; and

(ii)why the commission considers the individual is an excluded individual for the relevant event.

(2)Notice under subsection (1)(b)—

(a)must be given while the individual is an excluded individual for the relevant event to which the notice relates; and

(b)if the notice is the second or a subsequent notice the individual has been given about being an excluded individual for a relevant event—

(i)must state the effect of the individual becoming a permanently excluded individual including, if the individual is not a licensee, the effect of section 61A; and

(ii)may be given at any time after an earlier notice was given; and

(c)if the individual is not a licensee—must be a show cause notice under section 56AJ.

(3)An excluded individual who is a licensee is taken to have been given notice under subsection (1)(b) if—

(a)the individual has been given notice under section 56AF(2); and

(b)for a second or subsequent notice, the notice also includes the information required under subsection (2)(b)(i).

(4)A second or subsequent notice may be given for a relevant event whether the event happened before or after another event for which the commission has already given notice under subsection (1)(b).(5)However, subsection (1) applies only if an individual became an excluded individual for at least one of the relevant events after the commencement of this section, irrespective of when the circumstances resulting in the relevant event arose.(6)If a second or subsequent notice does not include the information required under subsection (2)(b)(i) another notice containing the information may be given.(7)It is declared that in deciding whether 2 relevant events as mentioned in subsection (1) have happened, a relevant event must be counted—

(a)whether the relevant event happened before or after the other relevant event; and

(b)whether or not the notices under subsection (1)(b) for the relevant events were given in the order the relevant events happened; and

(c)regardless of the length of time between the giving of the notices under subsection (1)(b) for the relevant events; and

(d)whether the relevant event happened before or after the commencement of this section, subject to subsection (5).

Example for subsection (2)(a)—The commission gives a licensee a notice under this section for a relevant event for which the licensee is currently an excluded individual. The commission later discovers that the licensee was, before the grant of the licensee’s licence, an excluded individual for a previous relevant event. However, the licensee is not currently an excluded individual for this relevant event because 5 years have elapsed since the event happened. It may not give the licensee a notice for this event.Example for subsection (7)(a), (b) and (d)—The commission gives a licensee a notice under this section for a relevant event that happened after the commencement of this section. It later discovers that the licensee is an excluded individual for another relevant event that happened before the grant of the licensee’s licence and before the commencement of this section. It may give the licensee a notice for this relevant event. Also, it is the later notice, about the earlier relevant event, that must state the effect of the individual becoming a permanently excluded individual.Examples for subsection (7)(c)—

1The commission becomes aware that a person who is an applicant for a contractor’s licence is currently an excluded individual for 2 relevant events one of which happened after the commencement of this section. The commission may give the person a notice for one of the relevant events and immediately give a notice for the other relevant event. Also, it is the later notice that must state the effect of the individual becoming a permanently excluded individual.

2A licensee becomes an excluded individual for a relevant event. The individual’s licence is cancelled under section 56AF and the individual is given notice complying with this section for the relevant event. More than 5 years later the licensee applies for and is granted a contractor’s licence. Ten years after this, the licensee becomes an excluded individual for another relevant event. The commission gives a notice complying with this section for the latest relevant event. This notice includes the information required for a second or subsequent notice under subsection (2)(b)(i) and the individual becomes a permanently excluded individual.

s 58 prev s 58 amd 1992 No. 36s 2sch 1sub 1994 No. 20s 20om 2000 No. 9s 104sch 1pres s 58 ins 2003 No. 1s 31amd 2013 No. 38s 14sch 1; 2014 No. 57s 23; 2020 No. 24s 142Division 2Licence exclusionpt 3B div 2 hdg ins 2003 No. 1s 3159Exclusion from licenceThe commission must not grant a person a licence if the person is—

(a)a permanently excluded individual; or

(b)a company for which a permanently excluded individual is a director, secretary, influential person or nominee.

s 59 prev s 59 amd 1994 No. 20s 21om 2000 No. 9s 104sch 1pres s 59 ins 2003 No. 1s 31amd 2013 No. 38s 14sch 160Permanently excluded individual not fit and properA permanently excluded individual is taken not to be a fit and proper person for part 3, division 2.s 60 prev s 60 om 2000 No. 9s 104sch 1pres s 60 ins 2003 No. 1s 3161When individual no longer permanently excluded individualIn deciding whether an individual is, or continues to be, a permanently excluded individual, a relevant event for which the individual has been given notice under section 58(1)(b) must not be counted if the individual applies to the tribunal under section 86(1)(k) for a review of the commission’s decision under section 56AF that a person is an excluded individual, and the tribunal reverses or annuls the commission’s decision.s 61 prev s 61 om 2000 No. 9s 104sch 1pres s 61 ins 2003 No. 1s 31amd 2003 No. 30s 169sch 1; 2013 No. 38s 14sch 1; 2014 No. 57s 24Division 3Publication of details of particular permanently excluded individualspt 3B div 3 hdg ins 2020 No. 24s 14361APublication of relevant details of permanently excluded individuals who are not licensees(1)The commission may publish the relevant details for an individual if the individual—

(a)is not a licensee; and

(b)is a permanently excluded individual; and

(c)all periods for applying for a review of a decision about a relevant event related to the exclusion, or making an appeal against a decision made on the review, have ended; and

(d)any review or appeal mentioned in paragraph (c) is finally decided or is not proceeded with.

(2)The relevant details for the individual are—

(a)the individual’s full name and business address; and

(b)if the individual is or has been known by another name—all other names the individual is or has been known by; and

(c)that the individual is a permanently excluded individual for a stated relevant event; and

(d)the day on which the individual became a permanently excluded individual; and

(e)any other particulars prescribed by regulation.

(3)The individual’s relevant details may be published under subsection (1) on the commission’s website.(4)Despite subsection (1)—

(b)no details may be published about the individual after the day that is 10 years from the day the details were first published under this section.

s 61A ins 2020 No. 24s 143Part 3CConvicted company officerspt 3C hdg ins 2003 No. 1s 32Division 1Preliminarypt 3C div 1 hdg ins 2003 No. 1s 32Division 2Licence exclusion and cancellationpt 3C div 2 hdg ins 2003 No. 1s 3263Exclusion from licenceThe commission must not grant a person a licence if the person is—

(a)a convicted company officer; or

(b)a company for which a convicted company officer is a director, secretary, influential person or nominee.

s 63 prev s 63 om 2000 No. 9s 104sch 1pres s 63 ins 2003 No. 1s 32amd 2013 No. 38s 14sch 164Procedure if commission considers individual a convicted company officer(1)This section applies if the commission considers that an individual is a convicted company officer.(2)The commission must give the individual a written notice stating—

(a)details of the conviction the commission considers makes the individual a convicted company officer; and

(b)the effect of the individual being a convicted company officer; and

(c)an invitation to the individual to make written submissions, within a stated period, to satisfy the commission that the individual is not a convicted company officer.

(3)The stated period must be at least 28 days after the written notice is given to the individual.(4)The commission must consider any submissions made by the individual.s 64 prev s 64 om 2000 No. 9s 104sch 1pres s 64 ins 2003 No. 1s 32amd 2013 No. 38s 14sch 165Ending procedure without further action(1)This section applies if, after considering submissions made by the individual, the commission is satisfied the individual is not a convicted company officer.(2)The commission must, as soon as practicable, advise the individual in writing that no further action under this part will be taken in relation to the notice given under section 64(2).s 65 prev s 65 om 2000 No. 9s 104sch 1pres s 65 ins 2003 No. 1s 32amd 2013 No. 38s 14sch 166Notice of cancellation and that not a fit and proper person to individual who is a licensee(1)For an individual who is a licensee, subsection (3) applies if, after considering submissions made by the individual for the notice under section 64(2), the commission still considers that the individual is a convicted company officer.(2)Subsection (3) also applies if there are no submissions for the notice under section 64(2).(3)The commission must, by written notice given to the individual—

(a)inform the individual that the commission still considers the individual is a convicted company officer; and

(b)cancel the individual’s licence; and

(c)inform the individual—

(i)that the individual is taken not to be a fit and proper person for part 3, division 2; and

(ii)of the individual’s right to apply to the tribunal for a review of the commission’s decision.Note—An individual may have the commission’s decision reviewed by the tribunal under section 86(1)(l).

(4)An individual given notice under subsection (3) is taken not to be a fit and proper person for part 3, division 2 as stated in the notice.(5)Section 49 does not apply to a cancellation under subsection (3).s 66 prev s 66 amd 1992 No. 36s 2sch 1om 2000 No. 9s 104sch 1pres s 66 ins 2003 No. 1s 32amd 2013 No. 38s 14sch 167Notice that not a fit and proper person to individual who is not a licensee(1)For an individual who is not a licensee, subsection (3) applies if, after considering submissions made by the individual for the notice under section 64(2), the commission still considers that the individual is a convicted company officer.(2)Subsection (3) also applies if there are no submissions for the notice under section 64(2).(3)The commission must, by written notice given to the individual, inform the individual—

(a)that the commission still considers the individual is a convicted company officer; and

(b)that the individual is taken not to be a fit and proper person for part 3, division 2; and

(c)of the individual’s right to apply to the tribunal for a review of the commission’s decision; and

(d)how, and the period within which, the individual may apply to the tribunal for the review; and

(e)any right the individual has to have the operation of the commission’s decision stayed by the tribunal.

(4)An individual given notice under subsection (3) is taken not to be a fit and proper person for part 3, division 2 as stated in the notice.s 67 prev s 67 om 2000 No. 9s 104sch 1pres s 67 ins 2003 No. 1s 32amd 2009 No. 24s 1673; 2013 No. 38s 14sch 167AANotice by commission to company for which a convicted company officer is a director, secretary, influential person or nominee(1)This section applies if the commission considers that a company that is a licensee has an individual who is a convicted company officer as a director or secretary of, or an influential person or nominee for, the company.(2)The commission must give the company a written notice stating—

(a)particulars identifying the individual (the relevant individual) the commission considers is a director or secretary of, or an influential person or nominee for, the company; andNote—A company may have the commission’s decision reviewed by the tribunal under section 86(1)(m).

(b)that the relevant individual must stop being a director, secretary, influential person or nominee within 28 days after the commission gives the individual the written notice; and

(c)the commission must cancel the licensee’s licence if the relevant individual does not stop being a director, secretary, influential person or nominee within the 28 days mentioned in paragraph (b).

(a)falls below the standard reasonably expected of a licensed contractor for the type of building work; and

(b)either—

(i)adversely affects the structural performance of a building to the extent that a person could not reasonably be expected to use the building for the purpose for which it was, or is being, erected or constructed; or

(ii)is likely to cause the death of, or grievous bodily harm to, a person.

Example for paragraph (b)(i)—A building is constructed and due to substandard building work all or a significant part of the building requires demolition or substantial reconstruction.Examples for paragraph (b)(ii)—A fire protection contractor installs fire protection equipment that does not meet the requirements of the Building Code of Australia for the equipment. In the event of fire, the noncompliance is likely to result in the death of, or grievous bodily harm to, a person.(2)Carry out tier 1 defective work means—

(a)carry out tier 1 defective work personally; or

(b)directly or indirectly, cause tier 1 defective work to be carried out; or

(c)provide advisory, administrative, management or supervisory services for carrying out tier 1 defective work.

s 67AB ins 2003 No. 1s 33amd 2020 No. 24s 120A67ACBanned individual(1)An individual is a banned individual if the individual is given notice under this part that the individual is taken not to be a fit and proper person for part 3, division 2.(2)The individual continues to be a banned individual for the term calculated under this part and stated in the notice.s 67AC ins 2003 No. 1s 3367ADOperation of pt 3DThis part has effect despite anything in part 3.s 67AD ins 2003 No. 1s 33Division 2Licence exclusion and cancellationpt 3D div 2 hdg ins 2003 No. 1s 3367AEExclusion from licenceThe commission must not grant a person a licence if the person is—

(a)a banned individual; or

(b)a company for which a banned individual is a director, secretary, influential person or nominee.

s 67AE ins 2003 No. 1s 33amd 2013 No. 38s 14sch 167AFProcedure if commission considers individual has carried out tier 1 defective work(1)This section applies if the commission considers that an individual has carried out tier 1 defective work after the commencement of this section.(2)The commission may give the individual a written notice stating—

(a)details of the tier 1 defective work; and

(b)the effect of the individual becoming a banned individual for the tier 1 defective work; and

(c)an invitation to the individual to make written submissions, within a stated period, to satisfy the commission that—

(i)the individual did not carry out the work stated in the notice; or

(ii)the work carried out by the individual was not tier 1 defective work; or

(iii)the individual exercised reasonable diligence to ensure that the work carried out was not defective.Example for subparagraph (iii)—An individual carried out tier 1 defective work in relation to the footings of a house. However, the individual had reasonably relied on plans for the footings drawn by an engineer and carried out the work in accordance with the plans. It was the reliance on the plans that caused the tier 1 defective work.

(3)The stated period must be at least 28 days after the written notice is given to the individual.(4)The commission must consider any submissions made by the individual.s 67AF ins 2003 No. 1s 33amd 2013 No. 38s 14sch 167AGEnding procedure without further action(1)This section applies if, after considering submissions made by the individual, the commission is satisfied that—

(a)the individual did not carry out the work stated in the notice; or

(b)the work carried out by the individual was not tier 1 defective work; or

(c)the individual exercised reasonable diligence to ensure that the work carried out was not defective.

(2)The commission must, as soon as practicable, advise the individual in writing that no further action under this part will be taken in relation to the written notice given under section 67AF(2).s 67AG ins 2003 No. 1s 33amd 2013 No. 38s 14sch 167AHNotice of cancellation and that not a fit and proper person to individual who is a licensee(1)For an individual who is a licensee, subsection (3) applies if, after considering the submissions made by the individual for the notice under section 67AF(2), the commission—

(a)still considers that—

(i)the individual carried out the work stated in the notice; and

(ii)the work carried out was tier 1 defective work; and

(b)is not satisfied that the individual exercised reasonable diligence to ensure that the work carried out was not defective.

(2)Subsection (3) also applies if there are no submissions for the notice under section 67AF(2).(3)The commission must, by written notice given to the individual—

(a)inform the individual that the commission—

(i)still considers—

(A)that the individual carried out the work stated in the notice; and

(B)the work carried out was tier 1 defective work; and

(ii)is not satisfied that the individual exercised reasonable diligence to ensure that the work carried out was not defective; and

(b)cancel the individual’s licence; and

(c)inform the individual—

(i)that the individual is taken not to be a fit and proper person for part 3, division 2, for the term calculated under section 67AO and stated in the notice; and

(ii)of the individual’s right to apply to the tribunal for a review of the commission’s decision; and

(iii)how, and the period within which, the individual may apply to the tribunal for the review; and

(iv)any right the individual has to have the operation of the commission’s decision stayed by the tribunal.Note—An individual who is given notice that they are taken not to be a fit and proper person (a banned individual) for a stated term may have the commission’s decision reviewed under section 86(1)(n).

(4)An individual given notice under subsection (3) is taken not to be a fit and proper person for part 3, division 2 as stated in the notice.(5)Section 49 does not apply to a cancellation under subsection (3).s 67AH ins 2003 No. 1s 33amd 2009 No. 24s 1674; 2013 No. 38s 14sch 167AINotice that not a fit and proper person to individual who is not a licensee(1)For an individual who is not a licensee, subsection (3) applies if, after considering the submissions made by the individual for the notice under section 67AF(2), the commission—

(a)still considers that—

(i)the individual carried out the work stated in the notice; and

(ii)the work carried out was tier 1 defective work; and

(b)is not satisfied that the individual exercised reasonable diligence to ensure that the work carried out was not defective.

(2)Subsection (3) also applies if there are no submissions for the notice under section 67AF(2).(3)The commission must, by written notice given to the individual, inform the individual—

(a)that the commission—

(i)still considers that—

(A)the individual carried out the work stated in the notice; and

(B)the work carried out was tier 1 defective work; and

(ii)is not satisfied that the individual exercised reasonable diligence to ensure that the work carried out was not defective; and

(b)that the individual is taken not to be a fit and proper person for part 3, division 2, for the term calculated under section 67AO and stated in the notice; and

(c)of the individual’s right to apply to the tribunal for a review of the commission’s decision; and

(d)how, and the period within which, the individual may apply to the tribunal for the review; and

(e)any right the individual has to have the operation of the commission’s decision stayed by the tribunal.Note—An individual who is given notice that they are taken not to be a fit and proper person (a banned individual) for a stated term may have the commission’s decision reviewed under section 86(1)(n).

(4)An individual given notice under subsection (3) is taken not to be a fit and proper person for part 3, division 2 as stated in the notice.s 67AI ins 2003 No. 1s 33amd 2009 No. 24s 1675; 2013 No. 38s 14sch 167AKEnding procedure without further action(1)This section applies if, after considering submissions made by the director, secretary, influential person or nominee, the commission is satisfied that—

(a)the company did not carry out the work stated in the notice; or

(b)the work carried out by the company was not tier 1 defective work; or

(c)the director, secretary, influential person or nominee exercised reasonable diligence to ensure that the work carried out was not defective; or

(d)the director, secretary, influential person or nominee was not in a position to influence the conduct of the company’s affairs in relation to the defective work.

(2)The commission must, as soon as practicable, advise the director, secretary, influential person or nominee in writing that no further action under this part will be taken in relation to the notice given under section 67AJ(2).s 67AK ins 2003 No. 1s 33amd 2013 No. 38s 14sch 167ALNotice of cancellation and that not a fit and proper person to director, secretary, influential person or nominee who is a licensee(1)For a director, secretary, influential person or nominee who is a licensee, subsection (3) applies if, after considering the submissions made by the director, secretary, influential person or nominee for the notice under section 67AJ(2), the commission—

(a)still considers—

(i)that the company carried out the work stated in the notice; and

(ii)that the work carried out was tier 1 defective work; and

(b)is not satisfied—

(i)that the director, secretary, influential person or nominee was not in a position to influence the conduct of the company’s affairs in relation to the defective work; or

(ii)that the director, secretary, influential person or nominee exercised reasonable diligence to ensure that the work carried out was not defective.

(2)Subsection (3) also applies if there are no submissions for the notice under section 67AJ(2).(3)The commission must, by written notice given to the director, secretary, influential person or nominee—

(a)inform the director, secretary, influential person or nominee that the commission—

(i)still considers—

(A)that the company carried out the work stated in the notice; and

(B)that the work carried out was tier 1 defective work; and

(ii)is not satisfied—

(A)that the director, secretary, influential person or nominee was not in a position to influence the conduct of the company’s affairs in relation to the defective work; or

(B)that the director, secretary, influential person or nominee exercised reasonable diligence to ensure that the work carried out was not defective; and

(b)cancel the director’s, secretary’s, influential person’s or nominee’s licence; and

(c)inform the director, secretary, influential person or nominee—

(i)that the director, secretary, influential person or nominee is taken not to be a fit and proper person for part 3, division 2, for the term calculated under section 67AO and stated in the notice; and

(ii)of the director’s, secretary’s, influential person’s or nominee’s right to apply to the tribunal for a review of the commission’s decision; and

(iii)how, and the period within which, the director, secretary, influential person or nominee may apply to the tribunal for the review; and

(iv)any right the director, secretary, influential person or nominee has to have the operation of the commission’s decision stayed by the tribunal.Note—A director, secretary, influential person or nominee who is given notice that they are taken not to be a fit and proper person (a banned individual) for a stated term may have the commission’s decision reviewed under section 86(1)(n).

(4)A director, secretary, influential person or nominee given notice under subsection (3) is taken not to be a fit and proper person for part 3, division 2 as stated in the notice.(5)Section 49 does not apply to a cancellation under subsection (3).s 67AL ins 2003 No. 1s 33amd 2009 No. 24s 1676; 2013 No. 38s 14sch 167AMNotice that not a fit and proper person to director, secretary, influential person or nominee who is not a licensee(1)For a director, secretary, influential person or nominee who is not a licensee, subsection (3) applies if, after considering the submissions made by the director, secretary, influential person or nominee for the notice under section 67AJ(2), the commission—

(a)still considers—

(i)that the company carried out the work stated in the notice; and

(ii)that the work carried out was tier 1 defective work; and

(b)is not satisfied—

(i)that the director, secretary, influential person or nominee was not in a position to influence the conduct of the company’s affairs in relation to the defective work; or

(ii)that the director, secretary, influential person or nominee exercised reasonable diligence to ensure that the work carried out was not defective.

Note—A nominee who is included in this provision as a person who was a licensed nominee when the company carried out the defective work may not be licensed when the notice is given.(2)Subsection (3) also applies if there are no submissions for the notice under section 67AJ(2).(3)The commission must, by written notice given to the director, secretary, influential person or nominee inform the director, secretary, influential person or nominee—

(a)that the commission—

(i)still considers—

(A)that the company carried out the work stated in the notice; and

(B)that the work carried out was tier 1 defective work; and

(ii)is not satisfied—

(A)that the director, secretary, influential person or nominee was not in a position to influence the conduct of the company’s affairs in relation to the defective work; or

(B)that the director, secretary, influential person or nominee exercised reasonable diligence to ensure that the work carried out was not defective; and

(b)that the director, secretary, influential person or nominee is taken not to be a fit and proper person for part 3, division 2, for the term calculated under section 67AO and stated in the notice; and

(c)of the director’s, secretary’s, influential person’s or nominee’s right to apply to the tribunal for a review of the commission’s decision; and

(d)how, and the period within which, the director, secretary, influential person or nominee may apply to the tribunal for the review; and

(e)any right the director, secretary, influential person or nominee has to have the operation of the commission’s decision stayed by the tribunal.Note—A director, secretary, influential person or nominee who is given notice that they are taken not to be a fit and proper person (a banned individual) for a stated term may have the commission’s decision reviewed under section 86(1)(n).

(4)A director, secretary, influential person or nominee given notice under subsection (3) is taken not to be a fit and proper person for part 3, division 2 as stated in the notice.s 67AM ins 2003 No. 1s 33amd 2009 No. 24s 1677; 2013 No. 38s 14sch 167ANNotice by commission to company for which a banned individual is a director, secretary, influential person or nominee(1)This section applies if the commission considers that a company that is a licensee has an individual who is a banned individual as a director or secretary of, or an influential person or nominee for, the company.(2)The commission must give the company a written notice stating—

(b)that the relevant individual must stop being a director, secretary, influential person or nominee within 28 days after the commission gives the company the written notice; and

(c)the commission must cancel the company’s licence if the relevant individual does not stop being a director, secretary, influential person or nominee within the 28 days mentioned in paragraph (b).

(3)The commission must cancel the company’s licence by written notice given to the company if the relevant individual does not stop being a director, secretary, influential person or nominee within the 28 days mentioned in subsection (2)(b).(4)Section 49 does not apply to a cancellation under subsection (3).s 67AN ins 2003 No. 1s 33amd 2013 No. 38s 14sch 167AOTerms of bans(1)This section states the term for which an individual given a notice under section 67AH, 67AI, 67AL or 67AM is taken not to be a fit and proper person for part 3, division 2 (the term of ban).(2)Only tier 1 defective work carried out after the commencement of this section may be taken into account in calculating the term of ban.(3)The term of ban for an individual given a notice for tier 1 defective work for the first time is 3 years.(4)The term of ban for an individual given a notice for tier 1 defective work a second time or subsequent time is the life of the individual.(5)A notice may be given to an individual a second time or subsequent time under section 67AH, 67AI, 67AL or 67AM if—

(a)a notice for tier 1 defective work has been given under one of the sections stating a ban of 3 years; and

(b)the second or subsequent notice relates to tier 1 defective work carried out after the notice stating a ban of 3 years is given.

(6)It is declared that, in deciding whether a notice for tier 1 defective work has been given to an individual a second time or subsequent time, a notice given to an individual for the first time under section 67AH, 67AI, 67AL or 67AM stating a ban of 3 years must be counted whether or not the individual has served the term of the ban.Example for subsections (5) and (6)—An individual who is a licensee is given a notice under section 67AH for tier 1 defective work carried out by the individual. The notice informs the individual that the individual is taken not to be a fit and proper person for part 3, division 2 for 3 years. After the notice under section 67AH is given, the individual carries out other tier 1 defective work. The commission may give the individual a second notice under section 67AH for the other tier 1 defective work whether or not the 3 years have passed. Also, it is the second notice under section 67AH that informs the individual that the individual is taken not to be a fit and proper person for part 3, division 2 for the life of the individual.(7)However, in deciding whether a notice for tier 1 defective work is given to an individual a second time or subsequent time, an earlier notice given to an individual under section 67AH, 67AI, 67AL or 67AM must not be counted if—

(a)the earlier notice was given more than 10 years before the second or subsequent notice; or

(b)the commission’s decision under the earlier notice was reversed or annulled on review by the tribunal.

(8)In this section a reference to tier 1 defective work carried out is—

(a)for an individual given notice under section 67AH(3) or 67AI(3)—a reference to tier 1 defective work carried out by the individual; or

(b)for an individual given notice under section 67AL(3) or 67AM(3)—a reference to tier 1 defective work carried out by the company for which the individual was a director, secretary, influential person or nominee.

s 67AO ins 2003 No. 1s 33amd 2013 No. 38s 14sch 167APs 67AP ins 2003 No. 1s 33amd 2003 No. 30s 169sch 1; 2009 No. 24s 1678; 2013 No. 38s 14sch 1om 2014 No. 57s 25Part 3EDisqualified individualspt 3E hdg ins 2003 No. 1s 34Division 1Preliminarypt 3E div 1 hdg ins 2003 No. 1s 3467AQDefinitions for pt 3EIn this part—accumulate—A person accumulates a demerit point when the demerit point takes effect if it is subsequently allocated to the person.administering authority see the State Penalties Enforcement Act 1999, schedule 2.building contract see section 67AAA.s 67AQ def building contract ins 2004 No. 6s 113sch 1conviction, of a person for a demerit offence, includes the following in relation to the offence—

(a)a court finding the person guilty or accepting the person’s plea of guilty, whether or not a conviction is recorded;

(b)the person paying a fine under an infringement notice, in full;

(c)the person starting to otherwise discharge a fine for an infringement notice under the State Penalties Enforcement Act 1999, section 149A;

(d)the registration of an infringement notice default under the State Penalties Enforcement Act 1999, section 34;

(c)the person paying the first instalment of a fine under an infringement notice;

(d)the registration by the registrar of a default certificate for an infringement notice given to the person;

(e)a decision of the commission to take disciplinary action against the person if the disciplinary action has taken effect under section 74G.

Editor’s note—Section 67AQ definition conviction incorporates an uncommenced amendment—see 2017 Act No. 13s 90sch 1.s 67AQ def conviction amd 2007 No. 47s 35; 2009 No. 24s 1679; 2014 No. 57s 26Editor’s note—Section 67AQ definition default certificate incorporates an uncommenced amendment—see 2017 Act No. 13s 90sch 1.default certificate see the State Penalties Enforcement Act 1999, schedule 2.demerit matter means—

(a)a conviction for a demerit offence; or

(b)an unsatisfied judgment debt.

demerit offence see section 67AR.demerit points means demerit points allocated by the commission under this part for a demerit matter.s 67AQ def demerit points amd 2013 No. 38s 14sch 1disqualified individual see section 67AU.infringement notice see the State Penalties Enforcement Act 1999, schedule 2.judgment debt see section 67AS.period of 3 years, in relation to the accumulation of demerit points, means a period of 3 years or less.~~registrar see the State Penalties Enforcement Act 1999, schedule 2.~~Editor’s note—Section 67AQ definition registrar incorporates an uncommenced amendment—see 2017 Act No. 13s 90sch 1.SPER see the State Penalties Enforcement Act 1999, schedule 2.unsatisfied, in relation to a judgment debt, see section 67AT.s 67AQ ins 2003 No. 1s 3467ARMeaning of demerit offenceA demerit offence is—

(a)an offence against a provision prescribed by regulation; or

(b)a contravention of a requirement imposed under this Act and prescribed by regulation.

s 67AR ins 2003 No. 1s 34amd 2004 No. 6s 113sch 1; 2007 No. 47s 36sub 2014 No. 57s 2767ASMeaning of judgment debt(1)A judgment debt is the amount, for which judgment has been entered in a court of competent jurisdiction, owing by a building contractor—

(a)in relation to a building contract or a domestic building contract; or

(b)for goods or services supplied for—

(i)building work to be carried out under a building contract; or

(ii)domestic building work to be carried out under a domestic building contract; or

(c)to the commission for a claim under the statutory insurance scheme.

(2)Judgment must be entered after the commencement of this section.(3)However, the circumstances giving rise to the judgment debt may have arisen before the commencement of this section.s 67AS ins 2003 No. 1s 34amd 2013 No. 38s 14sch 167ATMeaning of unsatisfied judgment debt(1)A judgment debt is unsatisfied if it has not been paid in full within—

(a)28 days after judgment is entered; or

(b)if a longer period is allowed by the court for payment—the longer period.

(2)A judgment debt is not unsatisfied if the judgment creditor has accepted and been paid an amount in full and final settlement within the relevant period mentioned in subsection (1).s 67AT ins 2003 No. 1s 3467AUDisqualified individual(1)An individual is a disqualified individual if the individual is given notice under this part that the individual is taken not to be a fit and proper person for part 3, division 2.(2)The individual continues to be a disqualified individual for the term calculated under this part and stated in the notice.s 67AU ins 2003 No. 1s 3467AVOperation of pt 3EThis part has effect despite anything in part 3, but does not apply to—

(a)a fire protection occupational licence; or

(b)a mechanical services occupational licence.

s 67AV ins 2003 No. 1s 34amd 2007 No. 47s 37; 2018 No. 17s 192; 2020 No. 24 s 145Division 2Calculation of demerit points and notification of unsatisfied judgment debtspt 3E div 2 hdg ins 2003 No. 1s 3467AWDemerit points for demerit matters(1)This section applies to a person who—

(a)has a conviction for a demerit offence; or

(b)is a judgment debtor for an unsatisfied judgment debt.

(2)The commission must allocate demerit points under this part to the person as follows—

(a)for a conviction for a demerit offence—the number of points allocated to the offence under a regulation;

(b)for an unsatisfied judgment debt—10 points.

(3)This section is subject to section 67AZB.s 67AW ins 2003 No. 1s 34amd 2013 No. 38s 14sch 1; 2014 No. 57s 2867AXWhen demerit points allocated for demerit offences(1)The commission must allocate demerit points to a person for a conviction for a demerit offence as soon as practicable after the points take effect.(2)Demerit points for a conviction for a demerit offence take effect—

(a)if a court finds a person guilty—on the day after the last day on which the person may appeal the finding; or

(b)if a court accepts a person’s plea of guilty—on the day the plea is accepted; or

(c)if a person pays the fine under an infringement notice, in full—on the day the fine is paid; or

(d)if a person begins to otherwise discharge the fine for an infringement notice offence under the State Penalties Enforcement Act 1999, section 149A—on the day the person begins to otherwise discharge the fine; or

(e)if the administering authority registers an infringement notice default under the State Penalties Enforcement Act 1999, section 34—on the day the default is registered; or

(d)if a person applies to the administering authority to pay the fine under an infringement notice, by instalments—on the day the administering authority receives the first instalment; or

(e)if the administering authority gives a default certificate to SPER for registration—on the day the default certificate is registered; or

(f)if the commission decides to take disciplinary action against the person—on the day the disciplinary action takes effect under section 74G.

Editor’s note—Section 67AX(2) incorporates an uncommenced amendment—see 2017 Act No. 13s 90sch 1.(3)However, if a conviction for a demerit offence is appealed, demerit points for the conviction must not be allocated until the appeal is finally dealt with or withdrawn.(4)Also, if a conviction for a demerit offence is appealed and after the appeal there is no conviction, demerit points stop having effect.(5)In this section—appeal includes a review of a decision of the commission by the tribunal under section 86.s 67AX ins 2003 No. 1s 34amd 2007 No. 47s 38; 2013 No. 38s 14sch 1; 2014 No. 57s 2967AYWhen demerit points allocated for unsatisfied judgment debts(1)The commission must allocate demerit points to a person for an unsatisfied judgment debt as soon as practicable after the points take effect.(2)Demerit points take effect when the judgment debt becomes an unsatisfied judgment debt.(3)However, if a decision relating to a judgment is appealed or an application is made to set the judgment aside, demerit points must not be allocated for the unsatisfied judgment debt until the appeal or application is finally dealt with or withdrawn.(4)Also, if a decision relating to a judgment is appealed or an application is made to set the judgment aside and after the appeal or application there is no unsatisfied judgment debt, demerit points stop having effect.s 67AY ins 2003 No.1 s 34amd 2013 No. 38s 14sch 167AZJudgment debtor must notify unsatisfied judgment debt(1)A judgment debtor for a judgment debt must notify the commission within 14 days after the judgment debt becomes an unsatisfied judgment debt.Maximum penalty—40 penalty units.(2)Notification under subsection (1) must include the following—
(a)particulars of the debt;
(b)the name and address of the judgment debtor;
(c)the name and address of the judgment creditor;
(d)the date judgment was entered and the amount for which it was entered;
(e)the court in which it was entered;
(f)the number of the proceeding for which it was entered sufficient to allow a search of the court registry;
(g)details of any payments made to reduce the judgment debt.
s 67AZ ins 2003 No. 1s 34amd 2013 No. 38s 14sch 167AZA Commission must notify person about demerit points(1)Subsection (2) applies if the commission allocates demerit points to a person.(2)The commission must, as soon as practicable after the demerit points are allocated, notify the person in writing of—
(a)the demerit points allocated; and
(b)the demerit matters for which they were allocated; and
(c)the date the points took effect.
s 67AZA ins 2003 No. 1s 34amd 2013 No. 38s 14sch 167AZAAs 67AZAA ins 2017 No. 43s 274om 2018 No. 17s 192A67AZB Limit on demerit points from single audit(1)This section applies if a licensee is convicted of demerit offences discovered by the commission as a result of a written notice given to a licensee under section 50C(2).(2)The maximum demerit points that may be allocated to the licensee for the convictions for the demerit offences is 20.(3)Nothing in this section prevents more demerit points being allocated to the licensee for convictions for demerit offences discovered by the commission as a result of a later written notice given under section 50C(2).(4)However, more demerit points must not be allocated—
(a)if the earlier notice and the later notice relate to—
(i)the same audit under an approved audit program; or
(ii)information received by the commission from the same source; or
(b)for convictions for demerit offences discovered by the commission as a result of a later notice if the offences—
(i)were committed before an earlier notice; and
(ii)demerit offences were discovered as a result of the earlier notice and resulted in the allocation of demerit points.
(5)In this section—approved audit program includes an approved audit program under the Building Industry Fairness (Security of Payment) Act 2017.s 67AZB ins 2003 No. 1s 34amd 2013 No. 38s 14sch 1; 2014 No. 57s 30; 2020 No. 24s 129Division 3Licence exclusion and cancellationpt 3E div 3 hdg ins 2003 No. 1s 3467AZC Exclusion from licenceThe commission must not grant a person a licence if the person is—
(a)a disqualified individual; or
(b)a company for which a disqualified individual is a director, secretary, influential person or nominee.
s 67AZC ins 2003 No. 1s 34amd 2013 No. 38s 14sch 167AZD Procedure if commission considers individual has accumulated 30 demerit points(1)This section applies if the commission considers that an individual has accumulated 30 demerit points in a period of 3 years.(2)The commission must give the individual a written notice stating—
(a)details of the demerit matters for which the demerit points have accumulated and the dates the points took effect; and
(b)the effect of the individual becoming a disqualified individual for accumulating 30 demerit points in a period of 3 years; and
(c)an invitation to the individual to make written submissions, within a stated period, to satisfy the commission that the individual has not accumulated 30 demerit points in a period of 3 years.
(3)The stated period must be at least 28 days after the written notice is given to the individual.(4)The commission must consider any submissions made by the individual.(5)In deciding whether an individual has accumulated 30 demerit points in a period of 3 years, demerit points must not be counted for an unsatisfied judgment debt paid in full before the end of the stated period.s 67AZD ins 2003 No. 1s 34amd 2013 No. 38s 14sch 167AZE Ending procedure without further action(1)This section applies if, after considering submissions made by the individual, the commission is satisfied the individual has not accumulated 30 demerit points in a period of 3 years.(2)The commission must, as soon as practicable, advise the individual in writing that no further action under this part will be taken in relation to the notice given under section 67AZD(2).s 67AZE ins 2003 No. 1s 34amd 2013 No. 38s 14sch 167AZF Notice of cancellation and that not a fit and proper person to individual who is a licensee(1)For an individual who is a licensee, subsection (3) applies if, after considering submissions made by the individual for the notice under section 67AZD(2), the commission still considers that the individual has accumulated 30 demerit points in a period of 3 years.(2)Subsection (3) also applies if there are no submissions for the notice under section 67AZD(2).(3)The commission must, by written notice given to the individual—
(a)inform the individual that the commission still considers the individual has accumulated 30 demerit points in a period of 3 years; and
(b)cancel the individual’s licence; and
(c)inform the individual—
(i)that the individual is taken not to be a fit and proper person for part 3, division 2 for the term calculated under section 67AZM and stated in the notice; and
(ii)of the individual’s right to apply to the tribunal for a review of the commission’s decision; and
(iii)how, and the period within which, the individual may apply to the tribunal for the review; and
(iv)any right the individual has to have the operation of the commission’s decision stayed by the tribunal.Note—An individual who is given notice that they are taken not to be a fit and proper person (a disqualified individual) for a stated term may have the commission’s decision reviewed under section 86(1)(p).
(4)An individual given notice under subsection (3) is taken not to be a fit and proper person for part 3, division 2 as stated in the notice.(5)Section 49 does not apply to a cancellation under subsection (3).s 67AZF ins 2003 No. 1s 34amd 2009 No. 24s 1680; 2013 No. 38s 14sch 167AZGs 67AZG ins 2003 No. 1s 34amd 2009 No. 24s 1681; 2013 No. 38s 14sch 1om 2014 No. 57s 3167AZH Notice by commission to director, secretary, influential person or nominee about demerit points(1)This section applies if the commission considers that a company has accumulated 30 demerit points in a period of 3 years.(2)The commission may give an individual who was a director or secretary of, or an influential person or nominee for, the company at the times the 30 demerit points were accumulated, a written notice stating—
(a)details of the demerit matters for which the demerit points have accumulated and the dates the points took effect; and
(b)the effect of the director, secretary, influential person or nominee becoming a disqualified individual because the company has accumulated 30 demerit points in a period of 3 years; and
(c)an invitation to the director, secretary, influential person or nominee to make written submissions, within a stated period, to satisfy the commission that—
(i)the company has not accumulated 30 demerit points in a period of 3 years; or
(ii)the director, secretary, influential person or nominee exercised reasonable diligence to ensure that some or all of the matters for which the demerit points accumulated did not happen; or
(iii)the director, secretary, influential person or nominee was not in a position to influence the conduct of the company’s affairs in relation to some or all of the matters for which the demerit points accumulated.
(3)The stated period must be at least 28 days after the written notice is given to the director, secretary, influential person or nominee.(4)The commission must consider any submissions made by the director, secretary, influential person or nominee.(5)In deciding whether a company has accumulated 30 demerit points in a period of 3 years, demerit points must not be counted for an unsatisfied judgment debt paid in full before the end of the stated period.s 67AZH ins 2003 No. 1s 34amd 2013 No. 38s 14sch 167AZJ Notice of cancellation and that not a fit and proper person to director, secretary, influential person or nominee who is a licensee(1)For a director, secretary, influential person or nominee who is a licensee, subsection (3) applies if, after considering the submissions made by the director, secretary, influential person or nominee for the notice under section 67AZH(2), the commission—
(a)still considers that the company has accumulated 30 demerit points in a period of 3 years; and
(b)is not satisfied, in relation to demerit matters for which at least 30 demerit points accumulated—
(i)that the director, secretary, influential person or nominee was not in a position to influence the conduct of the company’s affairs; or
(ii)that the director, secretary, influential person or nominee exercised reasonable diligence to ensure that the demerit matters did not happen.
(2)Subsection (3) also applies if there are no submissions for the notice under section 67AZH(2).(3)The commission must, by written notice given to the director, secretary, influential person or nominee—
(a)inform the director, secretary, influential person or nominee that the commission—
(i)still considers that the company has accumulated 30 demerit points in a period of 3 years; and
(ii)is not satisfied, in relation to demerit matters for which at least 30 demerit points accumulated—
(A)that the director, secretary, influential person or nominee was not in a position to influence the conduct of the company’s affairs; or
(B)that the director, secretary, influential person or nominee exercised reasonable diligence to ensure that the demerit matters did not happen; and
(b)cancel the director’s, secretary’s, influential person’s or nominee’s licence; and
(c)inform the director, secretary, influential person or nominee—
(i)that the director, secretary, influential person or nominee is taken not to be a fit and proper person for part 3, division 2, for the term calculated under section 67AZM and stated in the notice; and
(ii)of the director’s, secretary’s, influential person’s or nominee’s right to apply to the tribunal for a review of the commission’s decision; and
(iii)how, and the period within which, the director, secretary, influential person or nominee may apply to the tribunal for the review; and
(iv)any right the director, secretary, influential person or nominee has to have the operation of the commission’s decision stayed by the tribunal.Note—A director, secretary, influential person or nominee who is given notice that they are taken not to be a fit and proper person (a disqualified individual) for a stated term may have the commission’s decision reviewed under section 86(1)(p).
(4)A director, secretary, influential person or nominee given notice under subsection (3) is taken not to be a fit and proper person for part 3, division 2 as stated in the notice.(5)Section 49 does not apply to a cancellation under subsection (3).s 67AZJ ins 2003 No. 1s 34amd 2009 No. 24s 1682; 2013 No. 38s 14sch 167AZK Notice that not a fit and proper person to director, secretary, influential person or nominee who is not a licensee(1)For a director, secretary, influential person or nominee who is not a licensee, subsection (3) applies if, after considering the submissions made by the director, secretary, influential person or nominee for the notice under section 67AZH(2), the commission—
(a)still considers that the company has accumulated 30 demerit points in a period of 3 years; and
(b)is not satisfied, in relation to demerit matters for which at least 30 demerit points accumulated—
(i)that the director, secretary, influential person or nominee was not in a position to influence the conduct of the company’s affairs; or
(ii)that the director, secretary, influential person or nominee exercised reasonable diligence to ensure that the demerit matters did not happen.
(2)Subsection (3) also applies if there are no submissions for the notice under section 67AZH(2).(3)The commission must, by written notice given to the director, secretary, influential person or nominee inform the director, secretary, influential person or nominee—
(a)that the commission—
(i)still considers that the company has accumulated 30 demerit points in a period of 3 years; and
(ii)is not satisfied, in relation to demerit matters for which at least 30 demerit points accumulated—
(A)that the director, secretary, influential person or nominee was not in a position to influence the conduct of the company’s affairs; or
(B)that the director, secretary, influential person or nominee exercised reasonable diligence to ensure that the demerit matters did not happen; and
(b)that the director, secretary, influential person or nominee is taken not to be a fit and proper person for part 3, division 2, for the term calculated under section 67AZM and stated in the notice; and
(c)of the director’s, secretary’s, influential person’s or nominee’s right to apply to the tribunal for a review of the commission’s decision; and
(d)how, and the period within which, the director, secretary, influential person or nominee may apply to the tribunal for the review; and
(e)any right the director, secretary, influential person or nominee has to have the operation of the commission’s decision stayed by the tribunal.Note—A director, secretary, influential person or nominee who is given notice that they are taken not to be a fit and proper person (a disqualified individual) for a stated term may have the commission’s decision reviewed under section 86(1)(p).
(4)A director, secretary, influential person or nominee given notice under subsection (3) is taken not to be a fit and proper person for part 3, division 2 as stated in the notice.s 67AZK ins 2003 No. 1s 34amd 2009 No. 24s 1683; 2013 No. 38s 14sch 167AZL Notice by commission to company for which a disqualified individual is a director, secretary, influential person or nominee(1)This section applies if the commission considers that a company that is a licensee has an individual who is a disqualified individual as a director or secretary of, or an influential person or nominee for, the company.(2)The commission must give the company a written notice stating—
(a)particulars identifying the individual (the relevant individual) the commission considers is a director or secretary of, or an influential person or nominee for, the company; andNote—A company may have the commission’s decision reviewed under section 86(1)(q).
(b)that the relevant individual must stop being a director, secretary, influential person or nominee within 28 days after the commission gives the individual the written notice; and
(c)the commission must cancel the licensee’s licence if the relevant individual does not stop being a director, secretary, influential person or nominee within the 28 days mentioned in paragraph (b).
(3)The commission must cancel the company’s licence by written notice given to the company if the relevant individual does not stop being a director, secretary, influential person or nominee within the 28 days mentioned in subsection (2)(b).(4)Section 49 does not apply to a cancellation under subsection (3).s 67AZL ins 2003 No. 1s 34amd 2013 No. 38s 14sch 167AZM Terms of disqualifications(1)This section states the term for which an individual given a notice under section 67AZF, 67AZJ or 67AZK is taken not to be a fit and proper person for part 3, division 2 (the term of disqualification).(2)Only demerit points accumulated after the commencement of this section may be taken into account in calculating the term of disqualification.(3)The term of disqualification for an individual given a notice for accumulating 30 demerit points in a period of 3 years for the first time is 3 years.(4)The term of disqualification for an individual given a notice for accumulating 30 demerit points in a period of 3 years a second time or subsequent time is the life of the individual.(5)A notice may be given to an individual a second time or subsequent time under section 67AZF, 67AZJ or 67AZK if—
(a)a notice for accumulating 30 demerit points in a period of 3 years has been given under one of the sections stating a disqualification of 3 years; and
(b)the second or subsequent notice relates to 30 demerit points accumulated in a period of 3 years after the notice stating a disqualification of 3 years is given.
(6)It is declared that, in deciding whether a notice for accumulating 30 demerit points in a period of 3 years has been given to an individual a second time or subsequent time, a notice given to an individual for the first time under section 67AZF, 67AZJ or 67AZK stating a disqualification of 3 years must be counted whether or not the individual has served the term of the disqualification.Example for subsections (5) and (6)—An individual who is a licensee is given a notice under section 67AZF for accumulating 30 demerit points in a period of 3 years. The notice informs the individual that the individual is taken not to be a fit and proper person for part 3, division 2 for 3 years. After the notice under section 67AZF is given, the individual accumulates a further 30 demerit points in a period of 3 years that may include part of the term of disqualification. The commission may give the individual a second notice under section 67AZF for the further 30 demerit points whether or not the term of disqualification has ended. Also, it is the second notice under section 67AZF that informs the individual that the individual is taken not to be a fit and proper person for part 3, division 2 for the life of the individual.(7)However, in deciding whether a notice for accumulating 30 demerit points in a period of 3 years is given to an individual a second time or subsequent time, an earlier notice given to an individual under section 67AZF, 67AZJ or 67AZK must not be counted if—
(a)the earlier notice was given more than 10 years before the second or subsequent notice; or
(b)the commission’s decision under the earlier notice was reversed or annulled on review by the tribunal.
(8)In this section a reference to accumulating 30 demerit points in a period of 3 years is—
(a)for an individual given notice under section 67AZF(3)—a reference to the individual accumulating 30 demerit points in a period of 3 years; or
(b)for an individual given notice under section 67AZJ(3) or 67AZK(3)—a reference to the company for which the individual was a director, secretary, influential person or nominee accumulating 30 demerit points in a period of 3 years.
s 67AZM ins 2003 No. 1s 34amd 2013 No. 38s 14sch 1; 2014 No. 57s 32Part 4Domestic building contractspt 4 hdg prev pt 4 hdg om 2000 No. 9s 104sch 1pres pt 4 hdg ins 2014 No. 57s 3367AZNDomestic building contracts(1)Domestic building contracts are regulated under schedule 1B.(2)The provisions of schedule 1B apply to domestic building contracts and the parties to those contracts.s 67AZN ins 2014 No. 57s 33Part 4ABuilding contracts other than domestic building contractspt 4A hdg ins 1999 No. 43s 29Division 1Preliminarypt 4A div 1 hdg ins 1999 No. 43s 2967ADefinitions for pt 4AIn this part—approved security provider means a financial institution that is an approved security provider under the Financial Accountability Act 2009.s 67A def approved security provider amd 2009 No. 9s 136sch 1building contract see section 67AAA.s 67A def building contract sub 2004 No. 6s 113sch 1carry out building work means—
(a)carry out building work personally; or
(b)directly or indirectly, cause building work to be carried out; or
(c)provide advisory, administrative, management or supervisory services for carrying out building work.
commercial building contract means a building contract that is not a construction management trade contract or a subcontract.construction management trade contract means a building contract described in section 67B.contracted party, for a building contract, means the party to the contract who is to carry out the building work the subject of the contract.contracting party, for a building contract, means the party to the contract for whom the building work the subject of the contract is to be carried out.contract price...s 67A def contract price om 2017 No. 43s 275(1)defects liability period, for a building contract, means—
(a)the period worked out under the contract as being the period that—
(i)starts on the day of practical completion for the building work carried out under the contract; and
(ii)ends on the last day any omission or defect in the building work, carried out under the contract, may be required or directed to be rectified under the contract; or
(b)if the contract does not provide for a period mentioned in paragraph (a)—the statutory defects liability period under the Queensland Building and Construction Commission Act 1991, section 67NA(2).
s 67A def defects liability period ins 2017 No. 43s 275(2)payment claim see the Building Industry Fairness (Security of Payment) Act 2017, section 68.s 67A def payment claim ins 2004 No. 6s 113sch 1sub 2017 No. 43s 308sch 1practical completion, for building work carried out under a building contract, means—
(a)the day practical completion of the work is achieved, as worked out under the contract; or
(b)if the contract does not provide for the day practical completion of the work is achieved—the day the work is completed—
(i)in compliance with the contract, including all plans and specifications for the work and all statutory requirements applying to the work; and
(ii)without any defects or omissions, other than minor defects or minor omissions that will not unreasonably affect the intended use of the work.
s 67A def practical completion ins 2017 No. 43s 275(2)principal means a person who is the contracting party for a building contract and who—
(a)is not a building contractor; or
(b)is a building contractor, but did not enter into the building contract in the course of carrying on business as a building contractor.
progress payment see the Building Industry Fairness (Security of Payment) Act 2017, section 64.s 67A def progress payment sub 2004 No. 6s 113sch 1; 2017 No. 43s 308sch 1retention amount, for a building contract, means an amount described in section 67C.security, for a building contract, means something—
(a)given to, or for the direct or indirect benefit of, the contracting party for the contract by or for the contracted party for the contract; and
(b)intended to secure, wholly or partly, the performance of the contract; and
(c)in the form of either, or a combination of both, of the following—
(i)an amount, other than an amount held as a retention amount for the contract;
(ii)1 or more valuable instruments, whether or not exchanged for, or held instead of, a retention amount for the contract.
subcontract means a building contract described in section 67D.valuable instrument means any of the following—
(a)a banker’s undertaking;
(b)a bond;
(c)inscribed stock;
(d)a guarantee policy;
(e)an interest bearing deposit.
variation, of a building contract, means an addition to, or an omission from, the building work the subject of the contract.written form ...s 67A def written form om 2004 No. 6s 113sch 1s 67A ins 1999 No. 43s 2967AAA Meaning of building contract(1)For this part, a building contract means a contract or other arrangement for carrying out building work in Queensland but does not include—
(a)a domestic building contract; or
(b)a contract exclusively for construction work that is not building work.
(2)In this section—construction work see the Building Industry Fairness (Security of Payment) Act 2017, section 65.s 67AAA ins 2004 No. 6s 113sch 1 (amd 2005 No. 33s 13)sub 2017 No. 43s 308sch 167CMeaning of retention amount in pt 4AFor this part, an amount is a retention amount for a building contract if—
(a)the amount is payable as part of the contract price under the building contract, but, under the contract, may be withheld from payment to the contracted party for the building contract—
(i)during the progress of the building work the subject of the contract; or
(ii)for a period (a maintenance period) after the completion of the building work; or
(iii)both during the progress of the building work and for a maintenance period; and
(b)the purpose of withholding the amount is to give financial protection to the contracting party in relation to the need to correct defects in the building work, or otherwise to secure, wholly or partly, the performance of the contract.
s 67C ins 1999 No. 43s 2967DMeaning of subcontract in pt 4AFor this part, a building contract is a subcontract if—
(a)both the contracting party and the contracted party for the contract are building contractors; and
(b)for the contract, the contracted party is a subcontractor for the contracting party; and
(c)the building work the subject of the contract is the whole or a part of building work the subject of—
(i)another building contract, under which the contracting party mentioned in paragraphs (a) and (b) is the contracted party; or
(ii)a domestic building contract between the contracting party mentioned in paragraphs (a) and (b) and a consumer.
s 67D ins 1999 No. 43s 2967EOperation of pt 4A(1)Subject to any provision of this part that expressly provides that a building contract, or a provision of a building contract, is void, this part does not have effect to make void or voidable a building contract, or a provision of a building contract, even if—
(a)in entering into the building contract, or the building contract containing the provision, a party to the building contract commits an offence against this part; or
(b)the building contract or the provision of the building contract is inconsistent with a condition to which the building contract is subject under this part.
(2)However, if a building contract, or a provision of a building contract, is inconsistent with a provision (the Act provision) of this part applying to the building contract, the building contract, or the provision of the building contract, has effect only to the extent it is not inconsistent with the Act provision.(3)Without limiting subsection (2), a building contract is unenforceable against the contracted party for the contract to the extent that the contract provides for retention amounts or security in a way that is inconsistent with a condition to which the contract is subject under division 2.(4)This part—
(a)has effect in relation to a building contract despite anything in the building contract; and
(b)applies to a building contract even if—
(i)the contract was entered into outside Queensland; or
(ii)the parties to the contract have agreed that the law of Queensland does not apply to the contract or to a provision of the contract.
s 67E ins 1999 No. 43s 29Division 2All building contractspt 4A div 2 hdg ins 1999 No. 43s 2967FSuggested forms of contractThe commission may prepare and publish suggested forms for building contracts.s 67F ins 1999 No. 43s 29amd 2013 No. 38s 14sch 167GBuilding contracts to be in writing(1)A building contractor commits an offence if—
(a)the building contractor enters into a building contract, whether as the contracting party or the contracted party for the contract; and
(b)the building contract is not put into writing—
(i)if the reasonable cost of the building work the subject of the contract is more than $10,000—before carrying out the building work is started; or
(ii)if the reasonable cost of the building work the subject of the contract is $10,000 or less—before carrying out the building work is finished.
Maximum penalty—80 penalty units.(2)A building contractor commits an offence if—
(a)the building contractor enters into a building contract, whether as the contracting party or the contracted party for the contract; and
(b)the reasonable cost of the building work the subject of the building contract is $10,000 or less; and
(c)after the building contract is entered into but before the building contract has been put into writing, the reasonable cost of the building work the subject of the building contract becomes more than $10,000 because of a variation of the building contract, whether or not the variation is the first variation of the building contract; and
(d)the building contract, incorporating all variations, is not put into writing—
(i)if no building work has been carried out under the contract—before carrying out building work under the contract is started; or
(ii)otherwise—before there is further carrying out of building work under the contract.
Maximum penalty—80 penalty units.(3)A building contractor commits an offence if—
(a)the building contractor enters into a building contract, whether as the contracting party or the contracted party for the contract; and
(b)the building contract is put into writing; and
(c)the building contract, in writing, does not comply with the formal requirements for a building contract stated in subsection (4).
Maximum penalty—80 penalty units.(4)A building contract in writing complies with the formal requirements for a building contract if the contract states the following—
(a)the scope of the building work the subject of the contract;
(b)when the building work is to be completed;
(c)the amount to be paid for carrying out the building work or, if appropriate, how the amount to be paid for carrying out the building work is to be worked out;
(d)the parties’ agreement about retention amounts and securities to be held;
(e)the name of the building contractor who is the contracted party for the building contract;
(f)the licence number of the building contractor mentioned in paragraph (e), as it appears on the building contractor’s licence card;
(g)the address of the land where the building work is to be carried out.
(5)This section does not apply to a building contractor who enters into a building contract as a principal.(6)If, in contravention of subsection (1) or (2), a building contract is not put into writing, a building contractor who is a party to the contract is taken not to commit an offence against the provision if—
(a)building work the subject of the contract must be carried out urgently; and
(b)it is not reasonably practicable to enter into a written contract in the particular circumstances.
Example—a cyclone has caused considerable damage at a remote community, repairs are urgently needed, the parties to the building contract are not both present at the community and communications failure prevents transmission of written material between the partiess 67G ins 1999 No. 43s 29amd 2004 No. 6s 113sch 1; 2007 No. 47s 4067GABuilding contracts to include mandatory conditions(1)A building contractor must not enter into a building contract that does not include the conditions (mandatory conditions) prescribed by regulation for inclusion in that type of building contract.Maximum penalty—80 penalty units.(2)Subsection (1) does not apply to a building contractor who—
(a)enters into a building contract as a principal; or
(b)enters into a subcontract as the contracted party.
(3)A building contract is subject to the mandatory conditions regardless of whether the conditions are stated in the contract or not.(4)The mandatory conditions have effect despite any provision to the contrary in a building contract.(5)A provision of a building contract is of no effect to the extent to which it—
(a)is contrary to a mandatory condition; or
(b)purports to annul, exclude or change a mandatory condition; or
(c)may reasonably be construed as an attempt to deter a person from enforcing a mandatory condition.
(6)This section does not apply in relation to a condition of a building contract that imposes a greater or more onerous obligation on a building contractor than are imposed under the mandatory conditions.s 67GA ins 2017 No. 43s 27667GBParticular conditions void in building contracts(1)A building contractor must not enter into a building contract that includes a prohibited condition (prohibited conditions) prescribed by regulation.Maximum penalty—80 penalty units.(2)Subsection (1) does not apply to a building contractor who—
(a)enters into a building contract as a principal; or
(b)enters into a subcontract as the contracted party.
(3)A provision of a building contract is of no effect to the extent to which it—
(a)is or incorporates a prohibited condition; or
(b)may reasonably be construed as an attempt to enforce a prohibited condition.
(4)To remove any doubt, it is declared that this section does not apply to a building contract entered into before the commencement of this section but does apply to a provision of the contract included after the commencement to the extent the provision is a prohibited condition.s 67GB ins 2017 No. 43s 27667Hs 67H ins 1999 No. 43s 29om 2004 No. 6s 113sch 167IDirections given under building contracts(1)This section applies if under a building contract the contracting party for the contract, or another person authorised under the contract, may, without the agreement of the contracted party for the contract, give a direction to the contracted party.(2)Unless the building contract otherwise provides, a direction may initially be given other than in writing.(3)However, if a direction is given other than in writing, the contracted party—
(a)may ask for the direction to be given in writing; and
(b)is not required to comply with the direction until it is given in writing.
(4)If a direction is given other than in writing, the contracting party commits an offence if the direction is not given to the contracted party in writing within 3 business days after it was given other than in writing.Maximum penalty—80 penalty units.(5)In this section—direction includes agreement, approval, authorisation, certificate, decision, demand, determination, explanation, instruction, notice, order, permission, rejection, request or requirement.s 67I ins 1999 No. 43s 29amd 2004 No. 6s 113sch 1; 2007 No. 47s 4167JSet-offs under building contracts(1)The contracting party for a building contract may use a security or retention amount, in whole or in part, to obtain an amount owed under the contract, only if the contracting party has given notice in writing to the contracted party advising of the proposed use and of the amount owed.(2)The notice must be given within 28 days after the contracting party becomes aware, or ought reasonably to have become aware, of the contracting party’s right to obtain the amount owed.(3)If, because of subsections (1) and (2), the contracting party is stopped from using a security or retention amount, the contracting party for the contract is not stopped from recovering the amount owed in another way.(4)This section does not apply if, under the contract—
(a)work has been taken out of the hands of the contracted party or the contract has been terminated; or
(b)the security or retention amount is to be used to make a payment into court to satisfy a notice of claim of charge under the Building Industry Fairness (Security of Payment) Act 2017.
(5)In this section—amount owed, under a building contract, means an amount that, under the contract, is a debt due from the contracted party for the contract to the contracting party for the contract because of circumstances associated with the contracted party’s performance of the contract.use of security or retention amount includes the act of converting securities into cash where the securities are held as negotiable instruments.s 67J ins 1999 No. 43s 29sub 2004 No. 6s 113sch 1amd 2017 No. 43s 308sch 167KLimits for retention amounts and securities for building contracts other than subcontracts(1)This section applies to a building contract if the contracting party under the contract is a principal or a special purpose vehicle.(2)The building contract is subject to a condition that at any time before, under the contract, practical completion of building work is reached, the total value of the following is to be not more than 5% of the contract price for the contract—
(a)all retention amounts for the contract that are being withheld;
(b)all securities for the contract given and still held.
(3)Subsection (2) does not apply to retention amounts or securities to the extent that the retention amounts or securities are for the financial protection of the contracting party, having regard to amounts paid by the contracting party that relate to something that has not yet been installed in accordance with the requirements of the contract.(4)The building contract is not subject to the condition mentioned in subsection (2) if—
(a)the contract—
(i)is in writing; and
(ii)explains the condition; and
(iii)expressly provides that the contract is not subject to the condition; and
(b)the provision of the contract that expressly provides in the way mentioned in paragraph (a)(iii) is initialled by the parties to the contract.
s 67K ins 1999 No. 43s 29amd 2004 No. 6s 113sch 1; 2013 No. 58s 2667MLimits on deductions for retention amounts(1)This section applies if—
(a)an amount (the relevant amount) is payable by the contracting party for a building contract to the contracted party for the building contract; and
(b)the relevant amount relates to carrying out building work under the contract; and
(c)the relevant amount, except for a retention amount for the building contract that is withheld, is paid to the contracted party.
(2)The building contract is subject to a condition that the retention amount withheld is to be not more than 10% of the relevant amount.s 67M ins 1999 No. 43s 2967NLimits for retention amounts and securities for building contracts after practical completion(1)A building contract is subject to a condition that, at any time after, under the contract, practical completion of building work is reached, the total value of the following is to be not more than 2.5% of the contract price for the contract—
(a)all retention amounts for the contract that are being withheld;
(b)all securities for the contract given and still held.
(2)Subsection (1) does not apply to retention amounts or securities to the extent that the retention amounts or securities do not relate to the need to correct defects, identified in the defects liability period for the contract, in the building work for the contract.s 67N ins 1999 No. 43s 29amd 2017 No. 43s 27767NAStatutory defects liability period(1)This section applies to a building contract if—
(a)under the contract—
(i)a retention amount may be withheld; or
(ii)a security may be held after practical completion in relation to the need to correct defects in the building work under the contract; and
(b)the contract does not provide for the release of the retention amount or security at the end of an identifiable period.
(2)The building contract is subject to a condition that the retention amount or security must be released to the person entitled to it at the end of 12 months starting on the day of practical completion for the contract (the statutory defects liability period).s 67NA ins 2017 No. 43s 27867NBFailure to pay retention amount or other security(1)This section applies if a retention amount or other security is withheld under a building contract.(2)The contracting party must, unless the party has a reasonable excuse, release the retention amount or other security to the contracted party in accordance with the building contract, including, for example, releasing the retention amount or other security on or before the day the amount is due to be paid under the contract.Maximum penalty—200 penalty units or 1 year’s imprisonment.(3)Subsection (2) does not apply to that part of a retention amount or other security that is—
(a)paid into court to satisfy a notice of claim under the Building Industry Fairness (Security of Payment) Act 2017; or
(b)the subject of a dispute between the parties to the building contract unless, as an outcome of the dispute, the amount is to be paid to the contracted party.
s 67NB ins 2017 No. 43s 278amd 2020 No. 24s 13067NCNotice about end of defects liability period(1)This section applies if either of the following apply for a building contract—
(a)a retention amount is withheld;
(b)a security is held after practical completion in relation to the need to correct defects in the building work under the contract.
(2)Within 10 business days before the end of the defects liability period, the contracting party must give the contracted party a notice (the relevant notice), in the approved form, stating the following—
(a)the date that the defects liability period ends;
(b)for a retention amount—
(i)the amount to be paid to the contracted party at the end of the defects liability period, if no amount is required to correct defects in the building work under the contract; and
(ii)the date the retention amount is proposed to be paid to the contracted party.
Maximum penalty—100 penalty units.(3)However, subsection (4) applies if—
(a)the defects liability period relates to a subcontract; and
(b)the defects liability period is linked to the defects liability period (the other period) for another building contract; and
(c)the contracting party for the subcontract is only given a relevant notice for the other period after a day that would enable the party to comply with subsection (2).
(4)Within 5 business days after being given a relevant notice for the other period, the contracting party must give the contracted party for the subcontract a relevant notice for the defects liability period for the subcontract.Maximum penalty—100 penalty units.(5)This section does not apply to a contracting party who enters into a building contract as a principal.s 67NC ins 2017 No. 43s 27867OSuspension of works(1)This section applies if—
(a)the contracting party for a building contract has not complied with an order of a court or of the tribunal given in favour of the contracted party for the contract in relation to an issue arising under the contract; or
(b)all of the following apply—
(i)an amount is required to be paid to the contracted party for a building contract by a particular time;
(ii)the full amount is not paid, other than solely because of the retention of an amount lawfully permitted to be retained;
(iii)the requirement to pay the amount is not in dispute between the contracting party and the contracted party.
(2)The contracted party may give the contracting party a written notice stating—
(a)details of the circumstance mentioned in subsection (1)(a), or of the circumstances mentioned in subsection (1)(b)(i) to (iii); and
(b)that the contracted party intends to suspend building work the subject of the building contract if the order mentioned in subsection (1)(a) is not complied with, or if the amount mentioned in subsection (1)(b) is not paid, within the time stated in the written notice.
(3)The time stated in the written notice must be not less than 7 days after the written notice is given.(4)If the order is not complied with, or the amount is not paid, within the time stated in the written notice, the contracted party may—
(a)give the contracting party a further written notice that the contracted party is suspending the building work immediately; and
(b)suspend the building work immediately the further written notice is given.
(5)If the contracted party suspends building work under subsection (4), the contracted party—
(a)is not in breach of the building contract; and
(b)keeps the contracted party’s rights under the contract, including any right to terminate the contract; and
(c)may at any time lift the suspension, even if the order has not been complied with or the amount has not been paid.
(6)Subsection (7) applies if—
(a)the order is complied with, or the amount is paid; and
(b)the suspension is still in force; and
(c)the contracting party gives written notice to the contracted party—
(i)advising the order has been complied with or the amount has been paid; and
(ii)requiring the contracted party to recommence the building work under the contract.
(7)The building contract is subject to a condition that the contracted party must recommence carrying out building work under the contract within 7 days after the contracted party receives the written notice mentioned in subsection (6)(c), or at a later time agreed to between the contracting party and the contracted party.s 67O ins 1999 No. 43s 2967PLate progress payments(1)This section applies if—
(a)the contracting party for a building contract is required to pay an amount (the progress amount) to the contracted party for the building contract; and
(b)the progress amount is payable as the whole or a part of a progress payment; and
(c)the time (the payment time) by which the progress amount is required to be paid has passed, and the progress amount, or a part of the progress amount, has not been paid.
(2)For the period for which the progress amount, or the part of the progress amount, is still unpaid after the payment time, the contracting party is also required to pay the contracted party interest at the penalty rate, as applying from time to time, for each day the amount is unpaid.(3)In this section—penalty rate means—
(a)the rate made up of the sum of the following—
(i)10% a year;
(ii)the rate comprising the annual rate, as published from time to time by the Reserve Bank of Australia, for 90 day bills; or
(b)if the building contract provides for a higher rate of interest than the rate worked out under paragraph (a)—the higher rate.
s 67P ins 1999 No. 43s 29amd 2000 No. 10s 183sch 167Qs 67Q ins 1999 No. 43s 29om 2004 No. 6s 113sch 1Division 3Construction management trade contracts and subcontractspt 4A div 3 hdg ins 1999 No. 43s 2967RApplication of div 3This division applies to a building contract if the building contract is a construction management trade contract or a subcontract.s 67R ins 1999 No. 43s 2967SLodgement of security instead of retention amount or security in money form(1)This section applies if the contracted party for a building contract is under a lawful obligation to lodge a security in the form of an amount of money (the relevant amount).(2)The contracted party complies with the obligation if—
(a)the contracted party lodges with the contracting party a security, in the form of a government bond or a valuable instrument from an approved security provider, to take the place of the security in the form of money; and
(b)the value of the security is equal to the relevant amount.
(3)If the contracted party lodges a security in the form of a valuable instrument from an entity that is an approved security provider, and the entity stops being an approved security provider, the contracted party must, if asked by the contracting party, lodge a further security, in a form mentioned in subsection (2)(a), to take the place of the security in the form of money.s 67S ins 1999 No. 43s 2967UVoid payment provision in construction management trade contract or subcontract(1)A provision in a construction management trade contract or subcontract is void to the extent it provides for payment of a progress payment by a contracting party to a contracted party later than 25 business days after submission of a payment claim.(2)In this section—business day means a day that is not—
(a)a Saturday or Sunday; or
(b)a public holiday, special holiday or bank holiday in the place in which any relevant act is to be or may be done; or
(c)a day in the period from 22 December in a particular year to 10 January in the following year, both days inclusive.
s 67U ins 1999 No. 43s 29sub 2004 No. 6s 113sch 1amd 2020 No. 24s 131Division 4Warning for construction management trade contractspt 4A div 4 hdg ins 1999 No. 43s 29Division 5Commercial building contractspt 4 div 5 hdg ins 1999 No. 43s 2967WVoid payment provision in commercial building contract(1)A provision in a commercial building contract is void to the extent it provides for payment of a progress payment by a contracting party to a contracted party later than 15 business days after submission of a payment claim.(2)In this section—business day means a day that is not—
(a)a Saturday or Sunday; or
(b)a public holiday, special holiday or bank holiday in the place in which any relevant act is to be or may be done; or
(c)a day in the period from 22 December in a particular year to 10 January in the following year, both days inclusive.
s 67W ins 1999 No. 43s 29sub 2004 No. 6s 113sch 1amd 2020 No. 24s 132Part 5The statutory insurance schemept 5 hdg sub 2014 No. 57s 36Division 1Preliminarypt 5 div 1 hdg ins 2014 No. 57s 3667WADefinitions for pt 5In this part—appropriate insurance premium, for residential construction work, means the insurance premium set for the work under section 68D.assistance includes arranging and paying for the rectification or completion of residential construction work by a licensed contractor appointed by the commission.associated insurable work see section 67WD(1).consumer—
(a)for residential construction work—
(i)means a person who contracts with a licensed contractor to carry out the work; and
(ii)includes a person who purchases the work, once completed, if the work is primary insurable work; but
(b)does not include a licensed contractor for whom work mentioned in paragraph (a) is carried out by a subcontractor.Note—See also section 68H(1)(c) and (5).
consumer, for residential construction work—
(a)means a person who contracts with a licensed contractor to carry out the work; and
(b)includes a person who purchases the work, once completed, if the work is primary insurable work.
Note—See also section 68H(1)(c) and (5).s 67WA def consumer ins 2014 No. 57s 36 (amd 2016 No. 11s 23B(1))incomplete, in relation to residential construction work—
(a)means work that has not reached practical completion; but
(b)does not include—
(i)work that does not comply with the contract because of a cosmetic difference; orExample of a cosmetic difference—a different shade of paint
(ii)work that is defective.
insurable value, of residential construction work, means an amount representing the reasonable cost to the insurer of having the work carried out by a licensed contractor on the basis that all building and other materials are to be supplied by the contractor (whether or not the work is carried out by a licensed contractor on that basis).Examples of residential construction work the insurer may have to have carried out—
•relocating, transporting and resiting of an existing residence to another site
•the construction, off-site, of a residence or related roofed building and transportation of the residence or building to the relevant building site
•the erection of scaffolding required to carry out the residential construction work
•transporting labour and materials to the relevant building site.
optional additional cover see section 67Z(4).other materials, for residential construction work, includes appliances if included as part of the contract for carrying out the residential construction work.primary insurable work see section 67WC.related roofed building see section 67WF.residence see section 67WE.residential construction work is—
(a)primary insurable work; or
(b)associated insurable work.
speculative residential construction work means residential construction work carried out by a building contractor if—
(a)the work is not carried out under a contract with a consumer; and
(b)the work is carried out on land owned by the building contractor; and
(c)the work is a single detached dwelling or a multiple dwelling of not more than 3 storeys; and
(d)the dwelling has been sold, or is intended for sale, to another person.
s 67WA ins 2014 No. 57s 3667WBWork not covered under the statutory insurance scheme(1)The following work is not eligible for assistance from the statutory insurance ~~assistance~~ scheme—
(a)building work on, or on the site of, a building or proposed building that is or forms part of any of the following—
(i)a backpacker’s accommodation, boarding house, caravan park, guest house, holiday accommodation, hostel, hotel, lodging house or motel;
(ii)a correctional centre, lock-up, prison, reformatory or watch house;
(iii)a hospital, nursing home or other health care building;
(iv)an orphanage or children’s home;
(v)a retirement village under the Retirement Villages Act 1999;
(vi)an educational institution;
(vii)group accommodation for persons with a physical or mental disability;
(viii) commercial or industrial premises;
(b)building work carried out by a building contractor for a person who is the holder of an owner-builder permit covering the work;
(c)loading, unloading or transporting a building that, if it were fixed to land, could be a residence, or a related roofed building, regardless of whether the transport is within the boundaries of land where the building is located or otherwise;
(d)off-site prefabrication of the whole of a building that could be a residence, or a related roofed building, whether or not the building is in its final form or in parts;
(e)loading, unloading or transporting a completed prefabricated building that could be a residence or a related roofed building, whether the building is transported whole or in parts, regardless of whether the transport is within the boundaries of land where the building is prefabricated, or to be located, or otherwise;Example of a building transported in parts—A building is too large to be transported as a completed unit, and is transported on 3 trucks, then joined together on the land where it is to be used.
(f)other work prescribed by regulation.
(2)Any work mentioned in subsection (1) is taken not to be primary insurable work or associated insurable work.(3)Associated insurable work is not eligible for assistance from the statutory insurance ~~assistance~~ scheme unless carried out under a contract for primary insurable work and—
(a)for primary insurable work relating to a residence—the work is carried out on the site of the residence or proposed residence and is for residential purposes; or
(b)for primary insurable work relating to a related roofed building—the work is carried out on the site of the building or proposed building and is for residential purposes.
(4)In this section—completed prefabricated building includes a prefabricated building—
(a)that has not been placed on land where it is to be used; or
(b)to which services have not been connected, including, for example, electricity or plumbing and drainage.
s 67WB ins 2014 No. 57s 3667WCMeaning of primary insurable work(1)Primary insurable work is any of the following building work if carried out by a licensed contractor and the insurable value of the work is more than the regulated amount—
(a)the erection or construction of a residence or related roofed building;
(b)building work within the building envelope of a residence or related roofed building;
(c)building work for anything attached or connected to a residence or related roofed building that requires building development approval under the Building Act 1975 or a permit under the Plumbing and Drainage Act 2018;
(d)the erection, construction or installation of a swimming pool within the meaning of the Building Act 1975, schedule 2;
(e)other building work prescribed by regulation.
(2)However, the following is not primary insurable work, but may be associated insurable work—
(a)fencing;
(b)landscaping;
(c)electrical work under the Electrical Safety Act 2002;
(d)installation, renovation, repair or replacement of any of the following—
(i)air conditioning;
(ii)driveways or paths;
(iii)units for heating water regardless of the source of energy for heating, and including units for heating swimming pools;
(iv)refrigeration;
(v)roller shades and shutter screens;
(vi)security doors and grills;
(vii)solar power units and associated electrical components;
(viii)water tanks that are not part of a primary water supply for a residence or related roofed building;
(e)other work prescribed by regulation.
(3)In this section—building envelope, for a residence or related roofed building, means the outermost sides of the aggregation of the components of a building that have the primary function of separating the internal part of the residence or related roofed building from the external environment.Example of a building envelope—the slab and footings system, an external wall and a roofregulated amount means $3,300 or the higher amount, if any, prescribed by a regulation.s 67WC ins 2014 No. 57s 36amd 2018 No. 17s 197sch 267WDMeaning of associated insurable work(1)Associated insurable work is any additional work that may be contracted to be carried out under a contract for primary insurable work if—
(a)for primary insurable work relating to a residence—the work is carried out on the site of the residence or proposed residence and is for residential purposes; or
(b)for primary insurable work relating to a related roofed building—the work is carried out on the site of the building or proposed building and is for residential purposes.
(2)To remove any doubt, it is declared that associated insurable work may include work that is not building work.Examples for subsection (2)—electrical work under the Electrical Safety Act 2002, erecting scaffolding, or earthmoving and excavation works 67WD ins 2014 No. 57s 3667WEMeaning of residence(1)Each of the following structures is a residence if the structure is fixed to land and used for residential purposes—
(a)a single detached dwelling;
(b)1 or more attached dwellings that are separated by a common wall;Examples—a row house, terrace house, townhouse or villa unit
(c)a building, of not more than 3 storeys, containing 2 or more separate residential units.
(2)Part of a structure is also a residence if the structure is fixed to land and the part is designed to be used, and is used, for residential purposes.(3)A manufactured home fixed to land in a residential park (whether or not it is permanently fixed) is also a residence.(4)For subsection (1)(c), a regulation may prescribe how to calculate the number of storeys of a building.(5)Each of the following things is not a residence—
(a)boats, caravans, motor vehicles, tents, trailers, trains and similar things;
(b)a building designed as a temporary building, including, for example, a demountable building.
(6)In this section—manufactured home see the Manufactured Homes (Residential Parks) Act 2003, section 10.residential park see the Manufactured Homes (Residential Parks) Act 2003, section 12.storey means a space within a building which is situated between one floor level and the next floor level, or if there is no floor above, the ceiling or roof above, but is not a mezzanine or space that contains only—
(a)a lift, shaft, stairway or meter room; or
(b)a bathroom, shower room, laundry, water closet or other sanitary compartment; or
(c)accommodation intended for not more than 3 vehicles; or
(d)any combination of a thing mentioned in paragraphs (a) to (c).
s 67WE ins 2014 No. 57s 3667WFMeaning of related roofed building(1)A related roofed building means a building that—
(a)has a roof designed to be—
(i)part of the building; and
(ii)impervious to water or wind; and
(b)is, or is proposed to be, on the site of a residence or proposed residence; and
(c)is used, or proposed to be used, for a purpose related to the use of a residence or proposed residence.
Example of related roofed building—A private garage, shed, carport, toilet building or change room on, or proposed to be placed on, the site of an existing or proposed residence.(2)However, a building is not a related roofed building if—
(a)the building is a residence; or
(b)the roof of the building is a sail, umbrella or similar thing.
s 67WF ins 2014 No. 57s 36Division 2Statutory insurance schemept 5 div 2 hdg ins 2014 No. 57s 3667XStatutory insurance scheme(1)The statutory insurance scheme previously established under this Act is continued.(2)The purpose of the statutory insurance scheme is to provide assistance to consumers of residential construction work for loss associated with work that is defective or incomplete.(3)Assistance can not be provided under the scheme to a consumer unless the consumer has suffered loss as a consequence of residential construction that is defective or incomplete.(4)The statutory insurance scheme may operate under, and be referred to as, the name prescribed by regulation.s 67X ins 2007 No. 47s 43sub 2014 No. 57s 36Division 4Insurance premiumspt 5 div 4 hdg ins 2014 No. 57s 3668ALicensed contractor pays insurance premium on behalf of consumer(1)A licensed contractor who pays an insurance premium under this division pays the premium on behalf of a consumer.(2)A construction manager who pays an insurance premium under this division pays the premium on behalf of the principal who engages the manager.(3)The licensed contractor and construction manager are not entitled to assistance under the statutory insurance scheme because the contractor or manager pays the insurance premium under this division.s 68A ins 2007 No. 47s 45sub 2014 No. 57s 3668BWhen insurance premium is payable by licensed contractor(1)Subsection (2) applies to a licensed contractor who is to carry out residential construction work under a contract with a consumer unless the work is the subject of a construction management contract.(2)The licensed contractor must collect from the consumer, and pay to the commission, the appropriate insurance premium before the first of the following to happen—
(a)10 business days elapse from the day the contract was entered into;
(b)the residential construction work starts.
Maximum penalty—100 penalty units.(3)A licensed contractor who is to carry out residential construction work that is speculative residential construction work must pay the appropriate insurance premium for the work before the work starts.Maximum penalty—100 penalty units.s 68B ins 2007 No. 47s 45sub 2014 No. 57s 3668CWhen insurance premium is payable by construction manager(1)This section applies to a construction manager if a principal engages the manager under a construction management contract to manage the carrying out of residential construction work.(2)If the construction manager holds a contractor’s licence of the relevant class for the construction management contract, the manager must collect from the principal, and pay to the commission, the appropriate insurance premium before the first of the following to happen—
(a)10 business days elapse from the day the manager is engaged under the contract;
(b)the residential construction work starts.
Maximum penalty—100 penalty units.s 68C ins 2007 No. 47s 45sub 2014 No. 57s 3668DSetting of insurance premiums(1)This section provides for setting the different insurance premiums payable under the statutory insurance scheme.Note—Insurance premiums differ depending on the type of cover or type of work to which the premium relates.(2)The commission must state the insurance premiums, or the way the premiums are calculated, in the gazette.(3)Before stating the different insurance premiums, or the way the premiums are calculated, the commission must—
(a)have regard to the commission’s obligation under section 26A; and
(b)ensure insurance premiums are sufficient to meet the costs mentioned in section 26(3); and
(c)have regard to any regulation made under section 26(4); and
(d)obtain the Minister’s approval for the premium.
(4)The commission must review the different insurance premiums at least once every 12 months.(5)A regulation may prescribe the way the insurable value of residential construction work is calculated for stating an insurance premium.(6)Subsection (7) applies if a principal engages a construction manager under a construction management contract to provide building work services for the carrying out of residential construction work.(7)For calculating the insurance premium payable by the construction manager, the amount paid by the principal to the construction manager under the contract must be added to the insurable value of the residential construction work.s 68D ins 2007 No. 47s 45amd 2013 No. 38s 14sch 1sub 2014 No. 57s 3668EObligation of assessment manager in relation to insurance premiumAn assessment manager must not, under the Planning Act, give a development approval for building work in relation to residential construction work unless—
(a)the assessment manager has written information from the commission showing that the appropriate insurance premium has been paid; or
(b)the applicant produces satisfactory evidence that no insurance premium is payable.
Maximum penalty—20 penalty units.s 68E ins 2014 No. 57s 36amd 2016 No. 27s 372Division 5Notice and commencement of coverpt 5 div 5 hdg ins 2014 No. 57s 3668FNotice of cover(1)If the commission accepts an insurance premium for residential construction work, the commission must issue a notice of cover for the work.(2)The notice of cover must include the matters prescribed by regulation.(3)The notice of cover may be revoked by the commission if the commission becomes aware, after the issuing of the notice, that the work for which the notice was issued is not residential construction work.s 68F ins 2014 No. 57s 3668GRefund of insurance premium if notice of cover is revokedIf the commission revokes a notice of cover under section 68F, the commission must refund any insurance premium paid in relation to the work for which the notice was issued.s 68G ins 2014 No. 57s 3668HCover of residential construction work(1)Cover under the statutory insurance scheme comes into force if—
(a)a consumer enters into a contract for the carrying out of residential construction work and—
(i)the contract bears the licence number of a licensed contractor and, under the licensed contractor’s licence, the licensed contractor may enter into contracts with consumers to carry out residential construction work covered by the statutory insurance scheme; or
(ii)the contract is with a licensed contractor and, under the licensed contractor’s licence, the licensed contractor may enter into contracts with consumers to carry out residential construction work covered by the statutory insurance scheme; or
(b)a consumer enters into a contract for the carrying out of residential construction work with a building contractor and, at or before the time the contract is entered into, the building contractor makes a representation that would cause a reasonable person to believe that the residential construction work is covered by the statutory insurance scheme; or
(c)a person (the defrauded person) enters into a contract for the carrying out of residential construction work with a person (the fraudulent person) fraudulently claiming to hold a licence under which the fraudulent person may enter into contracts with consumers to carry out residential construction work covered by the statutory insurance scheme; or
(d)the work is speculative residential construction work carried out by a licensed contractor and, under the contractor’s licence, the contractor may carry out residential construction work covered by the statutory insurance scheme.
(2)Subsection (1) applies whether or not an insurance premium has been paid, or a notice of cover has been issued, for residential construction work under this part.(3)Subsection (1) does not apply to optional additional cover.(4)If cover under the statutory insurance scheme comes into force for particular residential construction work under subsection (1) and the insurance premium has not been paid for the cover under sections 68B or 68C, the commission may recover the amount of the premium, as a debt, from—
(a)if the premium was required to be paid under section 68B(2)—the consumer required to pay the premium; or
(b)if the premium was required to be paid under section 68B(3)—the licensed contractor required to pay the premium; or
(c)if the premium was required to be paid under section 68C—the principal required to pay the premium.
(5)For subsection (1)(c), this part applies as if—
(a)a reference to a consumer were a reference to a defrauded person; and
(b)a reference to a licensed contractor were a reference to a fraudulent person.
s 68H ins 2014 No. 57s 36 (amd 2016 No. 11s 23B(2)–(4))68ICommencement of cover(1)For residential construction work carried out under a contract with a consumer (other than work that is the subject of a construction management contract), cover under the statutory insurance scheme for the work comes into force on the earliest of the following to happen—
(a)a licensed contractor pays the appropriate insurance premium for the work under section 68B(2);
(b)the consumer enters into the contract with a licensed contractor for the carrying out of the work;
(c)a licensed contractor starts carrying out the work.
(2)For speculative residential construction work, cover under the statutory insurance scheme for the work comes into force on the earlier of the following to happen—
(a)the licensed contractor who is to carry out the work pays the appropriate insurance premium for the work under section 68B(3);
(b)the contractor starts carrying out the work.
(3)For residential construction work managed by a construction manager under a construction management contract, cover under the statutory insurance scheme for the work comes into force on the earlier of the following to happen—
(a)the construction manager pays the appropriate insurance premium for the work under section 68C(2);
(b)a licensed contractor starts carrying out the work.
(4)Optional additional cover comes into force when the appropriate insurance premium for the relevant residential construction work is paid under section 67Z(3).s 68I ins 2014 No. 57s 36Division 6Cancellation of coverpt 5 div 6 hdg ins 2014 No. 57s 3669Cancellation of cover and return of premium(1)Cover under the statutory insurance scheme for residential construction work, for which a licensed contractor paid the insurance premium on behalf of a consumer, may be cancelled by the contractor if—
(a)the contractor asks the commission in writing to cancel the cover; and
(b)the contract for the work has ended; and
(c)a deposit under the contract for the work has been refunded, less any amounts that may be lawfully deducted from the deposit; and
(d)the work covered has not started; and
(e)not more than 1 year has elapsed from the day the contract for the work was entered into.
(2)Cover under the statutory insurance scheme, including optional additional cover, for speculative residential construction work for which a licensed contractor paid the insurance premium on behalf of a consumer, may be cancelled by the contractor if—
(a)the contractor asks the commission in writing to cancel the cover; and
(b)development approval has not been granted for the work, or has been rescinded; and
(c)the work covered has not started; and
(d)not more than 1 year has elapsed from the day the premium was paid.
(3)Cover under the statutory insurance scheme for residential construction work, for which a construction manager paid the insurance premium on behalf of a principal, may be cancelled by the construction manager if—
(a)the construction manager asks the commission in writing to cancel the cover; and
(b)the relevant construction management contract and all the construction management trade contracts for the work have ended; and
(c)deposits paid under the relevant construction management contract and all the construction management trade contracts have been refunded, less any amounts that may be lawfully deducted from the deposits; and
(d)the work covered has not started; and
(e)not more than 1 year has elapsed from the day the construction management contract for the work was entered into.
(4)Optional additional cover obtained by a consumer may be cancelled by the consumer if—
(a)the consumer asks the commission in writing to cancel the cover; and
(b)the contract between the consumer and a licensed contractor relevant to the cover (the relevant contract) has ended; and
(c)a deposit under the relevant contract has been refunded, less any amounts that may be lawfully deducted from the deposit; and
(d)the work covered has not started; and
(e)not more than 1 year has elapsed from the day the relevant contract was entered into between the consumer and the licensed contractor.
(5)On cancellation of cover under this section, the commission must refund the insurance premium paid for the cover to—
(a)if the cover was cancelled under subsection (1), (2) or (3)—the licensed contractor or construction manager, or a person nominated in writing by the contractor or manager; or
(b)if the cover was cancelled under subsection (4)—the consumer.
(6)A fee, prescribed by regulation, may be deducted from any refund made under this section.s 69 amd 1994 No. 20s 23; 1999 No. 43s 31; 2000 No. 20s 29sch 3; 2003 No. 1s 36; 2007 No. 47s 46; 2013 No. 38s 14sch 1sub 2014 No. 57s 3669As 69A ins 2007 No. 47s 47om 2014 No. 57s 36Division 7Variationspt 5 div 7 hdg ins 2014 No. 57s 3670Residential construction work carried out under a contract with a consumer(1)This section applies if—
(a)the residential construction work to be carried out under a contract with a consumer is to be varied; and
(b)the commission is satisfied that the value of the residential construction work will change because of the variation.
(2)If the value of the residential construction work will increase by $5,000 or more because of the variation, the licensed contractor carrying out the work must pay an additional insurance premium on behalf of the consumer for the work to the commission before any work relating to the variation starts.Maximum penalty—100 penalty units.(3)If the value of the residential construction work will decrease because of the variation, the commission may refund part of the insurance premium paid for the work to the consumer.s 70 amd 2007 No. 47s 48; 2013 No. 38s 14sch 1sub 2014 No. 57s 3670ASpeculative residential construction work(1)This section applies if—
(a)a licensed contractor is carrying out residential construction work that is speculative residential construction work; and
(b)the residential construction work is to be varied after the licensed contractor paid the insurance premium for the work under section 68B(3); and
(c)the commission is satisfied that the value of the residential construction work will change because of the variation.
(2)If the value of the residential construction work will increase by $5,000 or more because of the variation, the licensed contractor must pay the additional insurance premium for the work to the commission before any work relating to the variation starts.Maximum penalty—100 penalty units.(3)If the value of the residential construction work will decrease because of the variation, the commission may refund part of the insurance premium paid for the work to the person who paid the premium.s 70A ins 2007 No. 47s 49sub 2014 No. 57s 3670BOptional additional cover(1)This section applies if—
(a)a consumer for a contract for the carrying out of residential construction work obtained optional additional cover for the work; and
(b)the residential construction work is to be varied after the consumer obtained the optional additional cover; and
(c)the commission is satisfied that the value of the residential construction work will change because of the variation.
(2)If the value of the residential construction work will increase by $5,000 or more because of the variation, the consumer must pay the additional insurance premium for the work to the commission before any work relating to the variation starts.(3)If the value of the residential construction work will decrease because of the variation, the commission may refund part of the insurance premium paid for the work to the consumer.(4)If the consumer fails to pay the additional insurance premium under subsection (2), the commission may recover the amount of the premium, as a debt, from the consumer.s 70B ins 2014 No. 57s 3670CPartial refunds of insurance premiumsA regulation may provide how part of an insurance premium refunded under this division is calculated.s 70C ins 2014 No. 57s 36Division 8Recovery from licensed contractorpt 5 div 8 hdg ins 2014 No. 57s 3671Recovery from licensed contractor etc.(1)If the commission makes any payment on a claim under the statutory insurance scheme, the commission may recover the amount of the payment, as a debt, from the building contractor by whom the relevant residential construction work was, or was to be, carried out or any other person through whose fault the claim arose.(2)For subsection (1)—
(a)a building contractor by whom the relevant residential construction work was, or was to be, carried out is taken to include—
(i)a licensed contractor whose licence card is imprinted on the contract for carrying out the work; and
(ii)a licensed contractor whose name, licence number and address are stated on the contract; and
(iii)a licensed contractor whose name is stated on the contract for carrying out the work; and
(iv)a licensed contractor whose name is stated on an insurance notification form for the work; and
(v)a licensed contractor whose licence number is stated on the contract for carrying out the work; and
(vi)a licensed contractor whose licence number is stated on an insurance notification form for the work; and
(vii)a licensed contractor whose PIN was used for putting in place, for the work, insurance under the statutory insurance scheme; and
(viii)a building contractor by whom the work was, or was to be, carried out; and
(ix)a person who, for profit or reward, carried out the work; and
(b)a person through whose fault the claim arose is taken to include a person who performed services for the work if the services were performed without proper care and skill.
(3)The commission is subrogated, to the extent of any payment that the commission has made, or has undertaken to make, to the rights of a person to whom, or for whose benefit, the payment has been, or is to be, made in respect of the matter out of which the insurance claim arose.(4)In a proceeding brought by the commission under subsection (1) against a licensed contractor mentioned in subsection (2)(a)(i), it is a defence for the licensed contractor to prove that—
(a)the licensed contractor’s licence card was imprinted on the contract for carrying out the work without the licensed contractor’s authority; and
(b)the licensed contractor took all reasonable steps to ensure that the licence card was imprinted on contracts only with the licensed contractor’s authority.
(5)In a proceeding brought by the commission under subsection (1) against a licensed contractor mentioned in subsection (2)(a)(ii), it is a defence for the licensed contractor to prove that—
(a)the licensed contractor’s name, licence number and address were stated on the contract for carrying out the work without the licensed contractor’s authority; and
(b)the licensed contractor took all reasonable steps to ensure that the licensed contractor’s name, licence number and address were stated in contracts only with the licensed contractor’s authority.
(6)In a proceeding brought by the commission under subsection (1) against a licensed contractor mentioned in subsection (2)(a)(iii), (iv), (v), (vi) or (vii), it is a defence for the licensed contractor to prove—
(a)for a licensed contractor mentioned in subsection (2)(a)(iii)—that the licensed contractor’s name was stated on the contract for carrying out the work without the licensed contractor’s authority; and
(b)for a licensed contractor mentioned in subsection (2)(a)(iv)—that the licensed contractor’s name was stated on the insurance notification form for the work without the licensed contractor’s authority; and
(c)for a licensed contractor mentioned in subsection (2)(a)(v)—that the licensed contractor’s licence number was stated on the contract for carrying out the work without the licensed contractor’s authority; and
(d)for a licensed contractor mentioned in subsection (2)(a)(vi)—that the licensed contractor’s licence number was stated on the insurance notification form for the work without the licensed contractor’s authority; and
(e)for a licensed contractor mentioned in subsection (2)(a)(vii)—
(i)that the licensed contractor’s PIN was used for putting in place, for the work, insurance under the statutory insurance scheme without the licensed contractor’s authority; and
(ii)that the licensed contractor took all reasonable steps to ensure the licensed contractor’s PIN was kept and used in accordance with the commission’s requirements for the keeping and use of the PIN.
s 71 amd 1994 No. 20s 24; 2000 No. 20s 29sch 3; 2013 No. 38s 14sch 1sub 2014 No. 57s 3671AAs 71AA ins 2007 No. 47s 50amd 2013 No. 38s 14sch 1om 2014 No. 57s 3671ABs 71AB ins 2013 No. 38s 7om 2014 No. 57s 3671ACs 71AC ins 2014 No. 57s 34om 2014 No. 57s 36Division 9Rectification workpt 5 div 9 hdg ins 2014 No. 57s 3671ATenders for rectification work(1)The commission may seek tenders for carrying out building work if the commission is of the opinion that a person may be entitled to assistance under the statutory insurance scheme.(2)The commission may accept any tender that it considers appropriate, whether or not the tender was for the lowest cost.(3)Tenders for carrying out the building work must be sought from the number of licensed contractors considered by the commission to be reasonable in the circumstances.(4)If the estimate to rectify the building work is less than the amount prescribed by regulation, the commission need only seek a tender for carrying out the building work from 1 licensed contractor.(5)The commission may authorise any of the following persons to act for the commission in seeking the tenders for carrying out building work—
(a)the person for whom the building work requiring rectification was, or was to be, carried out;
(b)a claims management consultant.
(6)The commission may only have work carried out under this section to the extent that the cost of the work is covered by the assistance under the statutory insurance scheme that the person may be entitled to.s 71A prev s 71A ins 2003 No. 1s 37amd 2013 No. 38s 14sch 1om 2014 No. 57s 37pres s 71A ins 2014 No. 57s 36Division 10Otherpt 5 div 10 hdg ins 2014 No. 57s 3671BStatutory insurance scheme not to affect licensing decisionsIn deciding the action to be taken in relation to a licensee’s licence, the commissioner must not have regard to the implications for the statutory insurance scheme.s 71B ins 2014 No. 57s 3671CNotice of entitlement to assistance under the statutory insurance schemeA person claiming to be entitled to assistance under the statutory insurance scheme must give notice of the claim to the commission in compliance with the requirements prescribed by regulation.s 71C ins 2014 No. 57s 3671DMultiple contracts for the same residential construction work(1)This section applies if a licensed contractor and a consumer enter into 2 or more separate contracts that—
(a)could be the subject of a single contract to carry out residential construction work; and
(b)if they were the subject of a single contract, would be a contract to carry out residential construction work.
(2)For this part, the separate contracts are taken to be a single contract for which the contract price is the sum of the contract prices for the separate contracts.Example of separate contracts—A licensed contractor that manufactures and installs kitchens enters into one contract with a building owner for the manufacture of a kitchen and a second contract for its installation.s 71D ins 2014 No. 57s 3671EProtection of expressions associated with statutory insurance scheme(1)A person must not use a declared expression in connection with selling the right to participate in any warranty or insurance scheme unless—
(a)the scheme is that to which this Act relates; and
(b)the person does so on behalf of the commission.
Maximum penalty—100 penalty units.(2)A person must not—
(a)use any variation of a declared expression; or
(b)use any word (either alone or in conjunction with any other word) similar in sight or sound to a declared expression;
in connection with selling the right to participate in any insurance or warranty scheme, being a use likely to afford reasonable grounds for believing the scheme is or is associated with the scheme to which this Act relates, unless—
(c)the scheme in question is one to which this Act relates; and
(d)the person does so on behalf of the commission.
Maximum penalty—100 penalty units.(3)In this section—declared expression means the name prescribed under section 67X or another name prescribed by regulation.s 71E ins 2014 No. 57s 3671FWhen work is taken to have startedA regulation may prescribe when residential construction work is taken to start for the purpose of this part.s 71F ins 2014 No. 57s 36Part 6Rectification of building work and remediation of consequential damagept 6 hdg sub 2014 No. 57s 37Division 1Preliminarypt 6 div 1 hdg ins 2014 No. 57s 3771Gs 71G ins 2014 No. 57s 37om 2017 No. 43s 27971HWhat is consequential damage(1)Consequential damage is damage—
(a)caused by, or as a consequence of, carrying out building work at a building site (the relevant site), regardless of any intention, negligence or recklessness of the person carrying out the work; and
(b)to a residential property at the relevant site, containing the relevant site or adjacent to the relevant site.
(2)In this section—building work includes any work prescribed by regulation.damage, to a residential property, includes any of the following—
(a)the impairment of drainage at the property;
(b)the undermining of a fence, retaining wall or other structure along the boundary of the property;
(c)the compromising of the structural integrity of a building, swimming pool or wall on the property;
(d)the cracking, lifting or cratering of a driveway or pathway on the property;
(e)water penetration of the property;
(f)infestation of the property by termites.
residential property includes—
(a)a single detached dwelling or a duplex; or
(b)a lot or the common property for a community titles scheme under the Body Corporate and Community Management Act 1997; or
(c)a lot or the common property for a building units plan or a group titles plan under the Building Units and Group Titles Act 1980.
s 71H ins 2014 No. 57s 3771IWho is taken to carry out building work for this part(1)A person who carries out building work is taken, for this part, to include—
(a)a building contractor whose licence card is imprinted on the contract for carrying out the building work; and
(b)a building contractor whose name, licence number and address are stated on the contract; and
(c)a building contractor whose name is stated on the contract for carrying out the building work; and
(d)a building contractor whose name is stated on an insurance notification form for the building work; and
(e)a building contractor whose licence number is stated on the contract for carrying out the building work; and
(f)a building contractor whose licence number is stated on an insurance notification form for the building work; and
(g)a building contractor whose PIN was used for putting in place, for the building work, a term of cover under the statutory insurance scheme; and
(h)a building contractor by whom the building work was carried out; and
(i)a person who, for profit or reward, carried out the building work; and
(j)a person who is a building contractor under a domestic building contract who managed the carrying out of the building work; and
(k)a construction manager engaged under a construction management contract to provide building work services for the building work; and
(l)a principal who was the contracting party for a building contract for building work for a building, or part of a building, intended for sale if—
(i)the building, or part of a building, is not, and has never been, the principal place of residence of the principal; and
(ii)the principal engages a building contractor or a construction manager to carry out the building work in a way, or using materials, likely to result in the work being defective or incomplete; and
(iii)the principal knew, or ought to have known, that the way the work was to be carried out, or the materials to be used, was likely to result in the work being defective or incomplete; andExample of principal knowing that work or materials were likely to result in defective or incomplete building work—A principal may know materials are likely to result in work being defective because of advice received from a building contractor or construction manager.
(m)a person who was the nominee for a licensed contractor that is a company, for work carried out by the company while the person was the company’s nominee.
(2)For the purposes of subsection (1)(h) and (i)—
(a)a person carries out building work whether the person—
(i)carries it out personally; or
(ii)directly or indirectly causes it to be carried out; and
(b)a person is taken to carry out building work if the person provides administration services, advisory services, management services or supervisory services for the work.
s 71I ins 2014 No. 57s 37Division 2Direction to rectify or remedypt 6 div 2 hdg ins 2014 No. 57s 3771JRequests for rectification of building work or remediation of consequential damage(1)A consumer may ask the commission to give a direction to rectify building work the consumer considers is defective or incomplete.(2)The owner or occupier of a residential property adjacent to a building site may ask the commission to give a direction to remedy any consequential damage to the property.(3)A person making a request under subsection (1) or (2) must give the commission—
(a)details of—
(i)for a request under subsection (1)—the building work the consumer considers is defective or incomplete; or
(ii)for a request under subsection (2)—the consequential damage to the property; and
(b)other details the commission reasonably requires to consider the request; and
(c)the fee prescribed by regulation.
(4)Also, a request under subsection (1) or (2) must be made within 12 months after the person becomes aware of—
(a)for a request under subsection (1)—the building work the person considers is defective or incomplete; or
(b)for a request under subsection (2)—the consequential damage to the property.
s 71J ins 2014 No. 57s 37amd 2017 No. 43s 28072Power to require rectification of building work and remediation of consequential damage(1)This section applies if the commission is of the opinion that—
(a)building work is defective or incomplete; or
(b)consequential damage has been caused by, or as a consequence of, carrying out building work.
(2)The commission may direct the person who carried out the building work to do the following within the period stated in the direction—
(a)for building work that is defective or incomplete—rectify the building work;
(b)for consequential damage—remedy the damage.
(2AA)A regulation may prescribe a period within which the commission must make the direction.(2A)If a period is prescribed under subsection (2AA), the commission must make the direction during the prescribed period.(3)In deciding whether to give the direction, the commission may take into consideration all the circumstances it considers are reasonably relevant and, in particular, is not limited to a consideration of the terms of the contract for carrying out the building work (including the terms of any warranties included in the contract).(4)The period stated in the direction must be the period prescribed by regulation unless the commission is satisfied that, if the direction is not required to be complied with within a shorter period—
(a)a substantial loss will be incurred by, or a significant hazard will be caused to the health or safety of, a person because of the defective or incomplete building work or consequential damage; or
(b)the defective or incomplete building work, or consequential damage, will cause a significant hazard to public safety or the environment generally.
(5)The commission is not required to give the direction if the commission is satisfied that, in the circumstances, it would be unfair to the person to give the direction.Example for subsection (5)—The commission might decide not to give a direction for the rectification of building work because an owner refuses to allow a building contractor to return to the owner’s home or because an owner’s failure to properly maintain a home has exacerbated the extent of defective building work carried out on the home.(6)The commission may, before it considers whether building work is defective or incomplete, require the consumer for the building work comply with a process established by the commission to attempt to resolve the matter with the person who carried out the work.(7)In subsection (3), a reference to a contract for carrying out building work includes a reference to a domestic building contract for managing the carrying out of building work.(8)To remove any doubt, it is declared that the commission may act under this section in relation to consequential damage whether or not an owner or occupier has made a request under section 71J.s 72 amd 1994 No. 20s 25; 1999 No. 43s 32; 2000 No. 9s 104sch 1; 2000 No. 10s 183sch 1; 2000 No. 20s 29sch 3; 2007 No. 47s 51; 2013 No. 38s 14sch 1sub 2014 No. 57s 37amd 2017 No. 43s 281; 2021 No. 23s 56B72APowers and limitations of directions to rectify or remedy(1)A direction to rectify or remedy may be given to more than 1 person for the same building work.(2)A direction to rectify or remedy may require that a building, or part of a building, be demolished and building work be recommenced if, in order to rectify building work, it is necessary to do so.(3)If a direction to rectify or remedy is given to a person who is not currently licensed to carry out the required work, the person must have the work carried out by a licensed contractor.(4)A direction to rectify or remedy cannot be given more than 6 years and 6 months after the building work to which the direction relates was completed or left in an incomplete state unless the tribunal is satisfied, on application by the commission, that there is in the circumstances of a particular case sufficient reason for extending the time for giving the direction and extends the time accordingly.(5)The fact that a direction is given under section 72(2) does not prevent the commission from taking additional action against a person under this Act for the building work to which the direction relates.s 72A ins 2014 No. 57s 37amd 2017 No. 43s 28272BExtending time to rectify or remedy(1)A person given a direction to rectify or remedy may apply to the commission for an extension of the period for compliance with the direction.(2)The application must—
(a)be made before the end of the period stated in the direction; and
(b)state the reasons the extension is needed.
(3)The commission must decide whether or not to grant the extension, and inform the applicant of the decision, within 10 business days after receiving the application.(4)The commission may grant the extension only if satisfied it is likely to be impracticable for the applicant to comply with the direction within the period stated in the direction.(5)Also, the commission must grant the extension if satisfied the person affected by the building work the subject of the direction has agreed to the extension being applied for.(6)If the commission grants the extension, the commission must give the applicant a written notice stating the period within which the applicant must rectify the work or remedy the damage.(7)If the commission refuses to grant the extension, the commission must give the applicant written notice of the refusal.(8)If the commission fails to comply with subsection (3), the commission is taken to have decided to refuse the application.(9)The direction to rectify or remedy is stayed while the commission considers the application.s 72B ins 2017 No. 43s 283Division 3Offences and defencespt 6 div 3 hdg ins 2014 No. 57s 3772CDelaying or obstructing compliance with direction to rectify or remedy(1)A person must not, without reasonable excuse, delay rectifying building work that is defective or incomplete, or remedying consequential damage, as required by a direction given to the person under section 72(2).Maximum penalty—250 penalty units.(2)A person must not, without reasonable excuse, obstruct another person rectifying building work that is defective or incomplete, or remedying consequential damage, as required by a direction given to the other person under section 72(2).Maximum penalty—250 penalty units.Note—Contravention of subsection (1) or (2) is proper grounds for taking disciplinary action against a licensee or former licensee, see section 74B(1)(a).s 72C (prev s 72AA) ins 2017 No. 43s 282Aamd 2020 No. 24s 121(1)–(2)renum 2020 No. 24s 121(3)73Offence to fail to comply with direction to rectify or remedyA person must not fail to rectify building work that is defective or incomplete, or to remedy consequential damage, as required by a direction to rectify or remedy given to the person, subject to any extension of time granted under section 72B.Maximum penalty—250 penalty units.s 73 prev s 73 amd 2013 No. 38s 14sch 1om 2014 No. 57s 35pres s 73 ins 2014 No. 57s 37amd 2017 No. 43s 28474Defences for failure to comply with direction to rectify or remedy(1)This section applies for—
(a)a prosecution of a licensed contractor for an offence against section 73; or
(b)taking disciplinary action against a licensed contractor under part 6A on the ground that the contractor failed to comply with a direction given to the contractor under section 72(2).
(2)It is a defence for the licensed contractor to prove that—
(a)for a licensed contractor mentioned in section 71I(1)(a)—
(i)the contractor’s licence card was imprinted on the contract for carrying out the building work without the contractor’s authority; and
(ii)the contractor took all reasonable steps to ensure that the licence card was imprinted on contracts only with the contractor’s authority; or
(b)for a licensed contractor mentioned in section 71I(1)(b)—
(i)the contractor’s name, licence number and address were stated on the contract for carrying out the building work without the contractor’s authority; and
(ii)the contractor took all reasonable steps to ensure that the contractor’s name, licence number and address were stated in contracts only with the contractor’s authority; or
(c)for a licensed contractor mentioned in section 71I(1)(c)—the contractor’s name was stated on the contract for carrying out the building work without the contractor’s authority; or
(d)for a licensed contractor mentioned in section 71I(1)(d)—the contractor’s name was stated on the insurance notification form for the building work without the contractor’s authority; or
(e)for a licensed contractor mentioned in section 71I(1)(e)—the contractor’s licence number was stated on the contract for carrying out the building work without the contractor’s authority; or
(f)for a licensed contractor mentioned in section 71I(1)(f)—the contractor’s licence number was stated on the insurance notification form for the building work without the contractor’s authority; or
(g)for a licensed contractor mentioned in section 71I(1)(g)—
(i)the contractor’s PIN was used for putting in place, for the building work, insurance under the statutory insurance scheme without the contractor’s authority; and
(ii)the contractor took all reasonable steps to ensure the contractor’s PIN was kept and used in accordance with the commission’s requirements for the keeping and use of the PIN.
s 74 prev s 74 amd 1999 No. 43s 33; 2013 No. 38s 14sch 1om 2014 No. 57s 35pres s 74 ins 2014 No. 57s 37Part 6AABuilding productspt 6AA hdg ins 2017 No. 29s 11Division 1Preliminarypt 6AA div 1 hdg ins 2017 No. 29s 1174AADefinitions for partIn this part—associated with, in relation to a building, means incorporated into, or connected to, a building by the carrying out of relevant work.building means a building or other structure within the meaning of the Building Act 1975.building product see section 74AB(1).building product undertaking see section 74AO(1).code of practice means a code of practice in force under section 74ADA.install and installer—A person installs a building product in a building, and is an installer of the building product, if the person—
(a)personally installs the product in the building; or
(b)supervises the installation of the product in the building; or
(c)carries out the relevant work in relation to which the product is installed in the building; or
(d)engages a person to do an activity mentioned in paragraph (a), (b) or (c).
s 74AA def install and installer ins 2018 No. 17s 192Bintended use, for a building product, means a use for which the building product is intended to be, or is reasonably likely to be, associated with a building.non-compliance risk means a risk that the association of a building product with a building for an intended use does not, or will not, comply with the relevant regulatory provisions.non-conforming building product see section 74AB(2).person in the chain of responsibility, for a building product, see section 74AE.reasonably practicable, in relation to a duty under division 2, means that which is, or was at a particular time, reasonably able to be done in relation to the duty, taking into account and weighing up all relevant matters including—
(a)the likelihood of a safety risk or non-compliance risk happening; and
(b)the harm that could result from the safety risk or non-compliance risk; and
(c)what the person concerned knows, or ought reasonably to know, about—
(i)the safety risk or non-compliance risk; and
(ii)ways of removing or minimising the risk; and
(d)the availability and suitability of ways to remove or minimise the safety risk or non-compliance risk; and
(e)the cost associated with available ways of removing or minimising the safety risk or non-compliance risk, including whether the cost is grossly disproportionate to the risk.
recall order see section 74AW(1).relevant regulatory provisions means—
(a)in relation to relevant work mentioned in the definition relevant work, paragraph (a)—the building assessment provisions under the Building Act 1975; or
(b)in relation to relevant work mentioned in the definition relevant work, paragraph (b) or (c)—the Plumbing and Drainage Act 2018.
s 74AA def relevant regulatory provisions amd 2018 No. 17s 197sch 2relevant work means—
(a)building work under the Building Act 1975 other than work mentioned in section 5(2) of that Act; or
(b)plumbing work under the Plumbing and Drainage Act 2018 directly connected to a building; or
(c)drainage work under the Plumbing and Drainage Act 2018 directly connected to a building.
s 74AA def relevant work amd 2018 No. 17s 197sch 2representation means a claim, promise, publication, statement or other representation made in any way, including, for example, in advertising material or packaging.responsible person, for a building product, means—
(a)a person who designed, manufactured, imported or supplied the product; or
(b)if the product has been associated with a building—a person who installed the product in the building; or
(c)an architect or engineer who, in designing a building, specified that the product be associated with the building.
s 74AA def responsible person ins 2018 No. 17s 192Bsafe means—
(a)all risks of injury or illness to a person have been removed, so far as reasonably practicable; or
(b)if it is not reasonably practicable to remove a risk of injury or illness to a person, the risk has been minimised so far as reasonably practicable.
safety risk means a risk that the association of a building product with a building for an intended use is not, or will not be, safe.warning statement see section 74AZC(1).s 74AA ins 2017 No. 29s 1174ABAExtraterritorial application of part(1)This part applies both within and outside Queensland.(2)This part applies outside Queensland to the full extent of the extraterritorial legislative power of the Parliament.s 74ABA ins 2017 No. 29s 11Division 2Duties relating to building productspt 6AA div 2 hdg ins 2017 No. 29s 11Subdivision 1General provisions about dutiespt 6AA div 2 sdiv 1 hdg ins 2017 No. 29s 1174ADPrinciples applying to duties(1)This section sets out principles applying to duties persons have under subdivision 2.(2)A person may have more than 1 duty because of the functions the person performs or is required to perform.(3)More than 1 person can concurrently have the same duty.(4)Each person must comply with the duty to the standard required under subdivision 2 even if another person has the same duty.(5)If more than 1 person has a duty for the same matter, each person—
(a)is responsible for the person’s duty in relation to the matter; and
(b)must discharge the person’s duty to the extent to which the person—
(i)has the capacity to influence and control the matter; or
(ii)would have the capacity but for an agreement or arrangement purporting to limit or remove that capacity.
(6)A person’s duty can not be transferred to another person.s 74AD ins 2017 No. 29s 1174ADACode of practice about discharging duties(1)The Minister may make a code of practice that states a way of discharging a duty a person has under this division.(2)A code of practice, or an instrument amending or repealing a code of practice, has no effect unless the Minister gives notice of its making.(3)A notice under subsection (2) is subordinate legislation.(4)A code of practice, or an instrument amending or repealing a code of practice, commences on the later of the following—
(a)the day the notice under subsection (2) commences;
(b)the day the code or instrument provides that it commences.
(5)A code of practice expires 10 years after its commencement.(6)The Minister must ensure a copy of each code of practice as in force from time to time, and any document applied, adopted or incorporated by the code of practice, is made available on the department’s website.s 74ADA ins 2017 No. 29s 1174ADBUse of code of practice in proceedings(1)This section applies in a proceeding for an offence against this part.(2)A code of practice is admissible in the proceeding as evidence of whether or not a duty under this division has been complied with.(3)Nothing in this section prevents a person from introducing evidence of compliance with the duty in a way that is different from the code.s 74ADB ins 2017 No. 29s 11Subdivision 2Dutiespt 6AA div 2 sdiv 2 hdg ins 2017 No. 29s 1174AEWho is a person in the chain of responsibility for a building productA person is a person in the chain of responsibility for a building product if—
(a)the person—
(i)designs, manufactures, imports or supplies the building product; and
(ii)knows, or is reasonably expected to know, the product will or is likely to be associated with a building; or
(b)the person installs the product in a building in connection with relevant work; or
(c)the person is an architect or engineer who, in designing a building, specifies that the product be associated with the building.
s 74AE ins 2017 No. 29s 11amd 2018 No. 17s 192C74AFPrimary duty of person in the chain of responsibilityEach person in the chain of responsibility for a building product must, so far as reasonably practicable, ensure that the product is not a non-conforming building product for an intended use.s 74AF ins 2017 No. 29s 1174AGAdditional duty relating to accompanying information(1)A person in the chain of responsibility for a building product who designs the product must ensure, so far as reasonably practicable, that, if the person gives the design to another person who is to give effect to the design, the design is accompanied by the required information for the product.(2)A person in the chain of responsibility for a building product who manufactures, imports or supplies the product must ensure, so far as reasonably practicable, that when the person gives the product to another person the product is accompanied by the required information for the product.(3)For subsection (2), a person gives a building product to another person if the person—
(a)sells, supplies or otherwise transfers the building product to the other person; or
(b)facilitates the sale, supply or transfer of the building product to the other person.
(4)A person who installs a building product in a building must ensure, so far as reasonably practicable, that the owner of the building is given information about the product prescribed by regulation for this subsection.(5)An architect or engineer who, in designing a building, specifies that a building product be associated with the building must ensure, so far as reasonably practicable, that when the architect or engineer gives the design to another person the design is accompanied by the information prescribed by regulation for this subsection.(6)A regulation, for subsection (4) or (5) or subsection (7), definition required information, may prescribe the following requirements for information about a building product—
(a)matters that must be included or provided for in the information;
(b)matters that must not be included or provided for in the information;
(c)the form in which the information must be given.
(7)In this section—required information, for a building product, means information about the product that—
(a)for each intended use of the product, states or otherwise communicates the following—
(i)the suitability of the product for the intended use and, if the product is suitable for the intended use only in particular circumstances or subject to particular conditions, the particular circumstances or conditions;
(ii)instructions about how the product must be associated with a building to ensure it is not a non-conforming building product for the intended use;
(iii)instructions about how the product must be used to ensure it is not a non-conforming building product for the intended use; and
(b)complies with the requirements for the information, if any, prescribed by regulation for this definition.
s 74AG ins 2017 No. 29s 11amd 2018 No. 17s 192D74AHAdditional duties relating to recalls(1)A person who designs, manufactures, imports, supplies or installs a building product must comply with the requirements of a recall order, or corresponding recall order, that applies to the person.(2)A person must not supply, or install in a building, a building product the person knows, or ought reasonably to know, is the subject of a recall order or corresponding recall order.(3)An architect or engineer must not, in designing a building, specify a building product be associated with the building that the architect or engineer knows, or ought reasonably to know, is the subject of a recall order or corresponding recall order.(4)Subsection (5) applies if—
(a)a building product becomes the subject of a recall order or corresponding recall order after an architect or engineer, in designing a building, specifies the building product be associated with the building; and
(b)the architect or engineer knows, or ought reasonably to know, the building product has become the subject of the recall order or corresponding recall order.
(5)The architect or engineer must, at the architect’s or engineer’s own expense—
(a)inform each person to whom the architect or engineer has given the design of the recall order or corresponding recall order; and
(b)either—
(i)amend the design to remove the specification; or
(ii)give each person to whom the architect or engineer has given the design a written notice specifying an alternative building product to be associated with the building.
(6)In this section—corresponding recall order means an order, however called, under a law of another State providing for the recall of a building product from use.s 74AH ins 2017 No. 29s 11amd 2018 No. 17s 192E74AIDuty of executive officer of company(1)If a company has a duty under a provision of this subdivision, an executive officer of the company must exercise due diligence to ensure the company complies with the duty.Maximum penalty—the penalty for a contravention of the provision by an individual.(2)The executive officer may be proceeded against for, and convicted of, an offence under this Act relating to the officer’s duty under subsection (1) whether or not the company has been proceeded against for, or convicted of, an offence under this Act relating to the company’s duty under this division.(3)In this section, due diligence includes taking reasonable steps—
(a)to acquire, and keep up to date, knowledge of matters about the safe use of building products; and
(b)to gain an understanding of—
(i)the nature of the company’s business activities relating to building products; and
(ii)safety risks and non-compliance risks associated with the building products; and
(c)to ensure the company has, and uses, appropriate resources to remove or minimise the risks mentioned in paragraph (b)(ii); and
(d)to ensure the company has, and implements, appropriate processes—
(i)to remove or minimise the risks mentioned in paragraph (b)(ii); and
(ii)for receiving, considering and responding in a timely way to, information about the risks mentioned in paragraph (b)(ii) and any incidents arising from the risks; and
(iii)for complying with the company’s duties under this Act; and
(e)to verify the resources and processes mentioned in paragraphs (c) and (d) are being provided, used and implemented.
s 74AI ins 2017 No. 29s 11Subdivision 3Offences relating to dutiespt 6AA div 2 sdiv 3 hdg ins 2017 No. 29s 1174AKDuty about representations about building products(1)This section applies if a person in the chain of responsibility for a building product knows, or ought reasonably to know, that the association of the product with a building for an intended use does not, or will not, comply with the relevant regulatory provisions.(2)The person must not make a representation, or permit a representation to be made, that the association of the product with a building for the use complies, or will comply, with the relevant regulatory provisions.Maximum penalty—1,000 penalty units.s 74AK ins 2017 No. 29s 1174ALDuty to notify non-conforming building product(1)Subsection (2) applies if a person in the chain of responsibility for a building product becomes aware, or reasonably suspects, that the building product is a non-conforming building product for an intended use.(2)As soon as practicable but within 2 days after becoming aware or reasonably suspecting, the person must give the commission notice of the matter in the approved form, unless the person has a reasonable excuse.Maximum penalty—50 penalty units.(3)If the person is aware of a notifiable incident that was or may have been caused by the use of the building product for the intended use, the notice under subsection (2) must also include notice of the notifiable incident.(4)Subsection (5) applies if the commission is satisfied—
(a)the building product is or may be a non-conforming building product for an intended use; and
(b)there are safety risks arising from the product being a non-conforming building product for the intended use.
(5)The commission may, by written notice given to a person in the chain of responsibility for the building product, direct the person to take stated action within a stated period to remove or minimise the safety risks.(6)A person given a direction under subsection (5) must comply with the direction.Maximum penalty for subsection (6)—50 penalty units.s 74AL ins 2017 No. 29s 1174AMDuty to notify notifiable incident(1)This section applies if—
(a)a building product is a non-conforming building product for an intended use; and
(b)a person in the chain of responsibility for the building product becomes aware, or reasonably suspects, that a notifiable incident was or may have been caused by the use of the building product for the intended use.
(2)As soon as practicable but within 2 days after becoming aware or reasonably suspecting, the person must give the commission notice of the notifiable incident in the approved form, unless the person has a reasonable excuse.Maximum penalty—100 penalty units.s 74AM ins 2017 No. 29s 1174ANCommission may require remedial action(1)This section applies if the commission reasonably believes a person—
(a)is contravening a duty under subdivision 2; or
(b)has contravened a duty under subdivision 2 in circumstances that make it likely the contravention will continue or be repeated.
(2)The commission may, by written notice given to the person, direct the person to do the following within the period stated in the direction—
(a)remedy the contravention;
(b)take stated steps to prevent the contravention from continuing or being repeated.
(3)The period stated in the direction must be at least 28 days unless the commission is satisfied that, if the direction is not required to be complied with within a shorter period—
(a)a substantial loss will be incurred by, or a significant hazard will be caused to the health or safety of, a person because of the contravention; or
(b)the contravention will cause a significant hazard to public safety or the environment generally.
(4)A person given a direction under subsection (2) must comply with the direction.Maximum penalty—1,000 penalty units.s 74AN ins 2017 No. 29s 11Division 3Enforceable undertakings relating to building productspt 6AA div 3 hdg ins 2017 No. 29s 1174APNotice of decision and reasons for decision(1)The commission must give the person seeking to make a building product undertaking written notice of the commission’s decision to accept or not accept the undertaking and the reasons for the decision.(2)The commission must publish, on the commission’s website, notice of a decision to accept a building product undertaking and the reasons for the decision.s 74AP ins 2017 No. 29s 1174AQWhen building product undertaking is enforceableA building product undertaking takes effect and becomes enforceable when written notice of the commission’s decision to accept the undertaking is given to the person who made the undertaking or at any later date stated by the commission in the notice.s 74AQ ins 2017 No. 29s 1174ARCompliance with building product undertakingA person must not contravene a building product undertaking made by the person that is in effect.Maximum penalty—500 penalty units.s 74AR ins 2017 No. 29s 1174ASContravention of building product undertaking(1)If the commission considers that a person who made a building product undertaking has contravened the undertaking, the commission may apply to a Magistrates Court for an order under this section.(2)If the court is satisfied that the person has contravened the building product undertaking, the court, in addition to the imposition of any penalty, may make 1 or both of the following orders—
(a)an order directing the person to comply with the undertaking;
(b)an order discharging the undertaking.
(3)In addition to the orders mentioned in subsection (2), the court may make any other order the court considers appropriate in the circumstances, including orders directing the person to pay to the State—
(a)the costs of the proceeding, including legal costs; and
(b)the reasonable costs of the commission in—
(i)investigating the contravention of the building product undertaking; or
(ii)monitoring compliance with the building product undertaking in the future.
(4)Nothing in this section prevents proceedings being taken for a contravention or alleged contravention of this part to which the building product undertaking relates.s 74AS ins 2017 No. 29s 1174ATWithdrawal or variation of building product undertaking(1)A person who has made a building product undertaking may at any time, with the written agreement of the commission—
(a)withdraw the undertaking; or
(b)vary the undertaking.
(2)However, the provisions of the undertaking can not be varied to provide for a matter relating to a different contravention or alleged contravention of this part.(3)The commission must publish, on the commission’s website, notice of the withdrawal or variation of a building product undertaking.s 74AT ins 2017 No. 29s 1174AUProceeding for contravention(1)This section applies to a contravention or alleged contravention of this part.(2)No proceedings for the contravention may be taken or continued against a person if a building product undertaking is in effect in relation to the contravention.(3)No proceedings may be taken for the contravention against a person who has made a building product undertaking for the contravention and has completely discharged the undertaking.(4)The commission may accept a building product undertaking for the contravention before proceedings for the contravention have been finalised.(5)If the commission accepts a building product undertaking as stated in subsection (4), the commission must take all reasonable steps to have the proceedings discontinued as soon as practicable.(6)In this section—proceedings includes proceedings for disciplinary action under part 6A.s 74AU ins 2017 No. 29s 11Division 4Ministerial recall orderspt 6AA div 4 hdg ins 2017 No. 29s 1174AVApplication of division(1)This division applies to a building product if—
(a)the Minister is satisfied the product—
(i)is a non-conforming building product for all intended uses; and
(ii)is not reasonably expected to be used for any other use; or
(b)the Minister is satisfied—
(i)the product has been, or is proposed to be, associated with a building for an intended use; and
(ii)the product is a non-conforming building product for the intended use; and
(iii)there are safety risks arising from the product being a non-conforming building product for the intended use.
(2)The Minister may act under this division for a particular batch or type of building product and, for that purpose, a reference in this division to a building product includes a reference to a batch or type of building product.s 74AV ins 2017 No. 29s 1174AWMinister may make recall order(1)The Minister may make an order (a recall order) that—
(a)is directed to a responsible person for the building product; and
(b)requires a stated building product be recalled from use.
(2)The Minister may make a recall order for a building product whether or not—
(a)the responsible person, or another responsible person, has already undertaken a recall of the building product; or
(b)the building product has been associated with a building.
Note—See section 74AH for duties relating to the recall order.(3)A recall order for a building product may be made in relation to 2 or more responsible persons for the product.s 74AW ins 2017 No. 29s 11amd 2018 No. 17s 192F74AXNotice required before making recall order(1)Before making the recall order, the Minister must—
(a)give each responsible person to whom the order is to apply written notice of the Minister’s intention to make the order and the reasons for making the order; and
(b)give the responsible person a copy of the proposed order; and
(c)ask the responsible person to show cause why the Minister should not make the proposed order.
(2)If a responsible person wishes to show cause why the recall order should not be made, the person may make written submissions to the Minister within 7 days after receiving the notice and copy of the proposed order.(3)The Minister must consider any written submissions made by a responsible person within the period mentioned in subsection (2) before making the recall order.(4)This section does not apply to a responsible person in relation to a building product if an order, however called, directing the person to recall the building product from use is in force under the law of another State.s 74AX ins 2017 No. 29s 1174AZNature of recall order(1)A recall order must state—
(a)the reasons for the recall of the building product from use; and
(b)what each responsible person to whom the order applies must do to recall the building product from use including, for example, the following—
(i)the way in which, and the period for which, a responsible person must inform other persons about the reason for the recall order;
(ii)the information a responsible person must give other persons about the reason for the recall order, including the action the other persons should take to mitigate any risk of injury or illness;
(iii)the action a responsible person must take in relation to other persons to whom the building product has been sold or supplied, for example, replacing the building product or providing a refund for the building product;
(iv)for a building product associated with a building—the action a responsible person must take to remove the building product from the building;
(v)for a building product that an architect or engineer has, in designing a building, specified be associated with the building—the action the architect or engineer must take to ensure the specification is removed from the design;Examples of action for (v)—
•amending the design to remove the specification
•giving written notice to persons to whom the design has been given specifying an alternative building product to be associated with the building
(vi)the action a responsible person must take to stop the building product from being a non-conforming building product for an intended use, for example, by repair or modification;
(vii)the action a responsible person must take to help another responsible person to whom the recall order applies to comply with the order;
(viii)the information a responsible person must give to the commission about the progress of the recall.
(2)Each responsible person to whom the recall order applies is liable for any cost incurred in relation to complying with the order, including costs incurred by an architect, engineer, installer or supplier giving reasonable help in relation to the recall order under section 74AZA.(3)The recall order remains in force until the end of 2 years after the order is made unless sooner revoked by the Minister.(4)Subsection (3) does not prevent a further recall order being made for the same building product to which the recall order applied while it was in force.s 74AZ ins 2017 No. 29s 11amd 2018 No. 17s 192G74AZASuppliers, installers and particular architects and engineers(1)This section applies if a responsible person to whom a recall order applies—
(a)produces a copy of the recall order to any of the following persons—
(i)a supplier or installer of a building product the subject of the order;
(ii)an architect or engineer who, in designing a building, specifies that a building product the subject of the order be associated with the building; and
(b)asks the supplier, installer, architect or engineer for help in relation to the recall order.
(2)The supplier, installer, architect or engineer must give the responsible person reasonable help in relation to the recall order.Examples of reasonable help by supplier—
•ceasing the supply of the recalled building product
•putting up a sign about the recall at the supplier’s place of business
•providing a collection point for recalled building products
•identifying or contacting persons supplied with the recalled building product
•giving the responsible person information about the number of items of recalled building products sold, in stock or returned by customers
Examples of reasonable help by installer—
•identifying or contacting owners of the buildings in which the building product has been installed
•giving the responsible person information about the building products the installer has removed from buildings
Examples of reasonable help by architect or engineer—
•ceasing to specify the recalled building product in designs
•identifying or contacting persons to whom the architect or engineer gave a design specifying the recalled building product be associated with a building
Maximum penalty—50 penalty units.s 74AZA ins 2017 No. 29s 11amd 2018 No. 17s 192HDivision 5Warning statementspt 6AA div 5 hdg ins 2017 No. 29s 1174AZBApplication of division(1)This division applies to a building product if the Minister is satisfied—
(a)the product is a non-conforming building product for an intended use; or
(b)that associating the product with a building in a particular way will make the product a non-conforming building product for an intended use; or
(c)that, if the product is associated with a building for a particular use, using the product in a particular way will make the product a non-conforming building product for the use.
(2)The Minister may act under this division for a particular batch or type of building product and, for that purpose, a reference in this division to a building product includes a reference to a batch or type of building product.s 74AZB ins 2017 No. 29s 1174AZCMinister may publish warning statement(1)The Minister may publish a statement (a warning statement) stating—
(a)if section 74AZB(1)(a) applies—that a stated building product is a non-conforming building product for a stated use; or
(b)if section 74AZB(1)(b) applies—that associating a stated building product with a building in a stated way will make the building product a non-conforming building product for a stated use; or
(c)if section 74AZB(1)(c) applies—that, if a stated building product is associated with a building for a stated use, using the product in a stated way will make the product a non-conforming building product for the use.
(2)The Minister may publish a warning statement for a building product whether or not—
(a)the Minister has made a recall order for the building product; or
(b)a responsible person for the building product has already undertaken a recall of the building product; or
(c)the building product has been associated with a building.
(3)A warning statement may be published—
(a)in a newspaper circulating generally in the State; and
(b)on the commission’s website; and
(c)in any other way the Minister considers appropriate.
s 74AZC ins 2017 No. 29s 11amd 2018 No. 17s 192I74AZDNotice required before publishing warning statement(1)Before publishing the warning statement, the Minister must—
(a)give each person in the chain of responsibility for the building product whose identity is known or reasonably ascertainable by the Minister written notice of the following—
(i)the Minister’s intention to publish the warning statement;
(ii)the reasons for publishing the statement; and
(b)give the person a copy of the proposed warning statement; and
(c)ask the person to show cause why the Minister should not publish the warning statement.
(2)If the person wishes to show cause why the warning statement should not be published, the person may make written submissions to the Minister within 7 days after receiving the notice and copy of the proposed warning statement.(3)The Minister must consider any written submissions made by the person within the period mentioned in subsection (2) before publishing the warning statement.s 74AZD ins 2017 No. 29s 11Part 6ADisciplinary proceedingspt 6A hdg ins 2014 No. 57s 3874ACommission may investigate grounds for taking disciplinary action(1)The commission may investigate whether proper grounds exist for taking disciplinary action against a person under this part.(2)An investigator may exercise powers under part 9 for an investigation under this part.(3)Also, for an investigation under this part, the commission may use information obtained under this Act from any entity, including, for example—
(a)a department or agency of the Commonwealth or a State; and
(b)participants in the building industry and its consumers.
s 74A ins 2014 No. 57s 38amd 2017 No. 29s 12; 2018 No. 17s 192J74BProper grounds for taking disciplinary action against a licensee and former licensees(1)Proper grounds exist for taking disciplinary action against a licensee or former licensee if—
(a)the licensee contravenes an offence provision of, or a requirement imposed under, this Act, the Building Act 1975 or the Building Industry Fairness (Security of Payment) Act 2017; or
(a)the licensee contravenes a requirement imposed under this Act or the Building Act 1975; or
(b)the licensee is convicted of an indictable offence; or
(c)if the licensee is a corporation—a director or secretary of, or an influential person for, the company is not a fit and proper person to exercise control or influence of the company’s affairs; or
(d)the licensee is carrying on business under the licence in partnership with a person who is not a fit and proper person to have an interest in the business; or
(e)the licensee is bankrupt or insolvent; or
(f)the licensee has committed an offence involving fraud or dishonesty relating to the business carried on under the licence; or
(g)the licensee knowingly helps a person to carry out building work in contravention of this Act; or
(h)the licensee contravenes or is taken to have contravened a relevant Act in relation to building work carried out under the licence; or
(ha)building or other work on a building site under the licensee’s control may have—
(i)caused the death of, or grievous bodily harm to, a person; or
(ii)involved a serious risk to the health or safety of a person; or
(i)the licensee is negligent or incompetent in carrying out building work under the licence; or
(j)the licensee fails to comply with—
(i)a direction of the commission to rectify building work that is defective or incomplete, or to remedy consequential damage; or
(ii)a direction given by the commission under section 74AN; or
(k)the licensee contravenes a condition of the licence; or
(l)the licensee owes an amount to the commission and fails to comply with a demand by the commission to pay the amount; or
(m)the licensee fails to comply with an order of the tribunal; or
(n)the licensee fails to pay a subcontractor in compliance with a building contract that is a subcontract under section 67D; or
(o)the licensee contravenes an offence provision of the Building Industry Fairness (Security of Payment) Act 2017; or
(r)the licensee contravenes section 67NC.
(2)However, proper grounds exist for taking disciplinary action against a former licensee only if the former licensee was a licensee at the time the grounds first existed.(3)In this section—former licensee means a person who was a licensee.grievous bodily harm see the Criminal Code, section 1.offence provision means a provision creating an offence or civil penalty.relevant Act means—
(a)the Fair Trading Act 1989; orNote—The Australian Consumer Law (Queensland) forms part of the Fair Trading Act 1989.
(b)the Plumbing and Drainage Act 2018; or
(c)the Work Health and Safety Act 2011; or
(d)the Electrical Safety Act 2002; or
(e)the Public Health Act 2005; or
(f)another Act prescribed by regulation.
s 74B ins 2014 No. 57s 38amd 2017 No. 29s 13; 2017 No. 43s 285; 2018 No. 17s 197sch 274CProper grounds for taking disciplinary action against person not a licensee(1)Proper grounds exist for taking disciplinary action against a person who is not a licensee if the person—
(a)carries out, or undertakes to carry out, building work for which a licence is required without holding a licence of the appropriate class; or
(b)has committed an offence involving fraud or dishonesty relating to the performance of building work; or
(c)contravenes or is taken to have contravened the Fair Trading Act 1989 in relation to building work carried out by the person; orNote—A contravention of the Fair Trading Act 1989 includes a contravention of the Australian Consumer Law (Queensland) which forms part of that Act.
(d)is negligent or incompetent in carrying out building work for which a licence is required; or
(e)fails to comply with—
(i)a direction of the commission to rectify building work that is defective or incomplete, or to remedy consequential damage; or
(ii)a direction given by the commission under section 74AN; or
(f)contravenes a duty under part 6AA, division 2, subdivision 2; or
(g)fails to comply with a direction or requirement of an investigator under part 9 relating to a building product that is, or is suspected to be, a non-conforming building product for an intended use.
(2)In this section—undertakes to carry out, building work, means enters into a contract to carry out building work or submits a tender or makes an offer to carry out building work, unless the contract, submission or offer is conditional on the person obtaining a licence of the appropriate class.s 74C ins 2014 No. 57s 38amd 2017 No. 29s 14; 2018 No. 17s 192K74DTypes of disciplinary action that may be takenThe types of disciplinary action the commission may take against a person are—
(a)for defective or incomplete building work carried out by the person for a building owner—directing the person pay, within a stated period, the building owner an amount sufficient to rectify the work; or
(b)for consequential damage caused by, or as a consequence of, building work carried out by the person—directing the person pay, within a stated period, the owner of the residence affected by the consequential damage an amount sufficient to remedy the damage; or
(c)directing the person to pay, within a stated period, compensation to someone else who has suffered loss or damage because of the act or omission that resulted in the disciplinary action; or
(d)imposing a penalty on the person of not more than—
(i)for an individual—an amount equivalent to 200 penalty units; or
(ii)for a corporation—an amount equivalent to 1,000 penalty units; or
(e)if the person is a licensee—
(i)reprimanding the licensee; or
(ii)suspending the licence; or
(iii)imposing conditions on the licence; or
(iv)cancelling the licence.
s 74D ins 2014 No. 57s 3874ENotice of proposed disciplinary actionIf, after conducting an investigation, the commission believes that appropriate grounds exist for taking disciplinary action against a person, the commission must give the person a written notice of—
(a)the grounds the commission believe exist for taking disciplinary action against the person; and
(b)the disciplinary action the commission proposes to take against the person; and
(c)that the person may, within the period stated in the notice, make written submissions to the commission about the matters mentioned in paragraphs (a) and (b).
s 74E ins 2014 No. 57s 3874FTaking disciplinary action(1)If the commission has given a person a notice under section 74E, the commission must consider all submissions made by the person within the period stated in the notice and decide to—
(a)take no further action; or
(b)take 1 or more of the types of disciplinary action mentioned in section 74D.
(2)Subsection (3) applies if—
(a)the decision is to take disciplinary action of a type mentioned in section 74D(a), (b) or (c); and
(b)the disciplinary action takes effect under section 74G; and
(c)the person does not comply with the disciplinary action as required.
(3)The commission may immediately decide to take another type of disciplinary action against the person.(4)As soon as practicable after making a decision to take no further action under subsection (1), the commission must give the person written notice of the decision.(5)As soon as practicable after making a decision to take disciplinary action against the person under subsection (1) or (3), the commission must give the person written notice of the decision that—
(a)complies with the QCAT Act, section 157(2); and
(b)informs the person of their option of applying to the commission for an internal review of the decision under section 86A.
s 74F ins 2014 No. 57s 3874GWhen disciplinary action takes effect(1)If the commission decides to take disciplinary action against a person under section 74F, the action takes effect from the later of the following days—
(a)the day that is 29 days after the person is given notice of the decision under section 74F(5);
(b)the day stated in the notice of the decision under section 74F(5).
(2)However, the decision to take the disciplinary action is stayed if—
(a)the disciplinary action relates to any matter other than a matter mentioned in section 74B(1)(j) or 74C(1)(e); and
(b)the person applies to the commission to have the decision reviewed under section 86A.
(3)The stay under subsection (2) is only for the period of a proceeding to decide the review.(4)The person need not comply with the disciplinary action if—
(a)the person applied to the tribunal for a review of the decision under section 87; and
(b)the tribunal orders a stay of the decision.
(5)The commission may recover an amount imposed as a penalty, as a debt, from the person on whom the penalty is imposed.(6)Subsection (7) applies if the decision to take the disciplinary action is stayed under subsection (2) or the tribunal orders a stay of the decision.(7)The decision to take the disciplinary action is taken not to have taken effect for the duration of the stay.s 74G ins 2014 No. 57s 3874HFiling of certificate as judgment debt(1)This section applies if—
(a)the commission decides to take disciplinary action, against a person, of a type mentioned in section 74D(a), (b) or (c); and
(b)the disciplinary action takes effect under section 74G.
(2)The commission may prepare a certificate stating the following matters—
(a)the name of the person entitled to the payment of an amount (the claimant);
(b)the name of the person who is liable to pay the amount (the respondent);
(c)the amount;
(d)the date on which payment of the amount was required to be paid to the claimant.
(3)The certificate may be filed by the commission as a judgment for a debt for the claimant, and the judgment may be enforced by the claimant, in a court of competent jurisdiction.(4)The certificate can not be filed under this section unless it is accompanied by an affidavit by the commission stating that the whole or a part of the amount has not been paid at the time the certificate is filed.(5)If the affidavit states that part of the amount has been paid, the judgment is for the unpaid part of the amount only.(6)If the respondent commences proceedings to have the judgment set aside, the respondent—
(a)is not, in those proceedings, entitled—
(i)to bring any counterclaim against the commission or claimant; or
(ii)to challenge the commission’s decision to take disciplinary action against the respondent; and
(b)is required to pay into the court as security the unpaid portion of the amount pending the final decision in those proceedings.
s 74H ins 2014 No. 57s 38Part 7Jurisdiction of tribunalpt 7 hdg prev pt 7 hdg om 2000 No. 10s 183sch 1pres pt 7 hdg ins 2003 No. 30s 169sch 1Division 1Meaning of central termspt 7 div 1 hdg prev div 1 hdg om 2000 No. 10s 183sch 1pres div 1 hdg ins 2003 No. 30s 169sch 175Tribunal work defined(1)The following is tribunal work—
(a)the erection or construction of a building;
(b)the renovation, alteration, extension, improvement or repair of a building;
(c)the provision of electrical work, water supply, sewerage or drainage or other like services for a building;
(d)the demolition, removal or relocation of a building;
(e)any site work (including the construction of retaining structures, driveways, landscaping and the construction of a swimming pool) related to tribunal work of a kind mentioned in paragraphs (a) to (d);
(f)the preparation of plans, specifications or bills of quantity for the carrying out of tribunal work;
(fa)fire protection work;
(fb)mechanical services work;
(g)the inspection of a completed building;
(h)subject to subsection (3), work prescribed under a regulation.
(2)To remove doubt, it is declared that reviewable domestic work is tribunal work.(3)A person carries out tribunal work whether the person carries it out personally, or directly or indirectly causes it to be carried out.(4)A person is taken to carry out tribunal work if the person provides advisory services, administration services, management services or supervisory services relating to the tribunal work.(5)A person undertakes to carry out tribunal work if the person enters into a contract to carry it out or submits a tender or makes an offer to carry it out.s 75 prev s 75 om 2000 No. 10s 183sch 1pres s 75 ins 2003 No. 30s 169sch 1amd 2007 No. 47s 52; 2018 No. 17s 19376What is not tribunal work(1)The following is not tribunal work—
(a)the construction, extension, repair or replacement of a water reticulation system, sewerage system or storm water drain, outside the boundaries of private property;
(b)the building or maintenance of a road as defined under the Land Act 1994;
(c)the construction, maintenance or repair of a bridge, other than a bridge on private property;
(d)the construction, maintenance or repair of railway tracks, signals or associated structures, unless the structures are buildings for residential purposes, or are storage or service facilities;
(e)the construction, maintenance or repair of airport runways, taxiways and aprons;
(f)the construction, maintenance or repair of ports or ports infrastructure, unless the structures are buildings for residential purposes, or are storage or service facilities;
(g)the construction, maintenance or repair of a dam;
(h)the construction, maintenance or repair of communications installations performed for a public company or public body engaged in radio or television broadcasting or in some other form of communications business or undertaking;
(i)the installation of manufacturing equipment or equipment for hoisting, conveying or transporting materials or products (including primary produce), other than the installation of fixed structures providing shelter for the equipment;
(j)construction work in mining;
(k)work consisting of monumental masonry, sculpture, or the erection or construction of statues, fountains or other works of art, other than work affecting the way in which a building is constructed;
(l)tribunal work carried out by the State for the State or for an entity representing the State;
(m)tribunal work carried out by a local government for a local government, the State or an entity representing a local government or the State;
(n)tribunal work carried out outside Queensland.
(2)For subsection (1)(l), tribunal work is not carried out by the State if the work is carried out for the State by an independent contractor.(3)For subsection (1)(m), tribunal work is not carried out by a local government if the work is carried out for the local government by an independent contractor.s 76 prev s 76 amd 1996 No. 37s 147sch 2om 2000 No. 10s 183sch 1pres s 76 ins 2003 No. 30s 169sch 1amd 2007 No. 47s 53Division 2Building disputespt 7 div 2 hdg prev div 2 hdg om 2000 No. 10s 183sch 1pres div 2 hdg ins 2003 No. 30s 169sch 177Tribunal may decide building dispute(1)A person involved in a building dispute may apply, as provided under the QCAT Act, to the tribunal to have the tribunal decide the dispute.(2)However, the person may not apply to the tribunal unless the person has complied with a process established by the commission to attempt to resolve the dispute.(3)Without limiting the tribunal’s powers to resolve the dispute, the tribunal may exercise 1 or more of the following powers—
(a)order the payment of an amount found to be owing by 1 party to another;
(b)order relief from payment of an amount claimed by 1 party from another;
(c)award damages, and interest on the damages at the rate, and calculated in the way, prescribed under a regulation;
(d)order restitution;
(e)declare any misleading, deceptive or otherwise unjust contractual term to be of no effect, or otherwise vary a contract to avoid injustice;
(f)avoid a policy of insurance under the statutory insurance scheme;
(g)order rectification or completion of defective or incomplete tribunal work;
(h)award costs.
s 77 prev s 77 om 2000 No. 10s 183sch 1pres s 77 ins 2003 No. 30s 169sch 1amd 2007 No. 47s 54; 2009 No. 24s 1684; 2014 No. 57s 3978When major commercial building dispute may be heard by tribunalA major commercial building dispute may be decided by the tribunal only if the tribunal is satisfied all parties to the dispute consent to it doing so.s 78 prev s 78 amd 1996 No. 37s 147sch 2om 2000 No. 10s 183sch 1pres s 78 ins 2003 No. 30s 169sch 1amd 2007 No. 47s 5579Procedure to decide whether all parties consent(1)An application to start a proceeding for a major commercial building dispute must be accompanied by the written consent of all parties to the dispute.(2)The written consent must include an acknowledgement by the consenting party that the consent can not be withdrawn.(3)The tribunal may, before another step is taken in the proceeding, conduct a pre-hearing conference to decide whether there is another person who should be joined as a party to the dispute.(4)If the tribunal decides that there is another person who should be joined as a party to the dispute, the tribunal—
(a)must give the consenting parties an opportunity to obtain the written consent of the other person; and
(b)may hear the dispute only if the other person consents.
(5)If the consenting parties obtain the consent of the other person, the tribunal must join the other person as a party to the dispute.(6)The consent of all parties to the dispute must be obtained before another step is taken in the proceeding.s 79 prev s 79 om 2000 No. 10s 183sch 1pres s 79 ins 2003 No. 30s 169sch 1amd 2007 No. 47s 5680Procedure if another party discovered(1)This section applies if the tribunal becomes aware that there is another person who should be joined as a party to a major commercial building dispute (other than at a pre-hearing conference under section 79).(2)The tribunal does not have jurisdiction to decide the dispute.(3)The tribunal must order that the proceeding be removed to a court under section 94.s 80 prev s 80 om 2000 No. 10s 183sch 1pres s 80 ins 2003 No. 30s 169sch 1amd 2007 No. 47s 5781Consent may not be withdrawnA party that gives written consent to have a major commercial building dispute heard and decided by the tribunal can not withdraw the consent.s 81 prev s 81 om 2000 No. 10s 183sch 1pres s 81 ins 2003 No. 30s 169sch 1amd 2007 No. 47s 5883Proceeding in tribunal does not affect action by commission(1)If a proceeding about a building dispute is started in, or removed from, a court to the tribunal, the commission is not prevented from acting in relation to the dispute.(2)Without limiting subsection (1), the commission may—
(a)decide whether or not to give a direction to rectify or remedy; or
(b)decide to allow or disallow a claim under the statutory insurance scheme.
s 83 prev s 83 om 2000 No. 10s 183sch 1pres s 83 ins 2003 No. 30s 169sch 1amd 2007 No. 47s 60; 2013 No. 38s 14sch 1; 2013 No. 58s 28sub 2014 No. 57s 4084s 84 prev s 84 om 2000 No. 10s 183sch 1pres s 84 ins 2003 No. 30s 169sch 1amd 2007 No. 47s 61; 2009 No. 24s 1685; 2013 No. 38s 14sch 1; 2013 No. 58s 29om 2014 No. 57s 4185Tribunal may hear dispute while contract still in operationThe tribunal may make an order to resolve a building dispute even though the contract under which the dispute arose has not been terminated or finalised.s 85 prev s 85 om 2000 No. 10s 183sch 1pres s 85 ins 2003 No. 30s 169sch 1amd 2007 No. 47s 62Division 3Proceedings for reviewpt 7 div 3 hdg prev div 3 hdg om 2000 No. 10s 183sch 1pres div 3 hdg ins 2003 No. 30s 169sch 1Subdivision 1Internal reviewpt 7 div 3 sdiv 1 hdg ins 2014 No. 56s 6285ADefinitions for sdiv 1In this subdivision—internal review application means an application for review under this subdivision.internal review decision see section 86C(1).internal reviewer, for an internal review application, means—
(a)if the application is for a decision of the commissioner under the Plumbing and Drainage Act 2018, section 51—the Service Trades Council; or
(b)if the application is for a reviewable decision not mentioned in paragraph (a)—the commission.
s 85A def internal reviewer ins 2016 No. 11s 16amd 2018 No. 17s 197sch 2reviewable decision see section 86.s 85A ins 2014 No. 56s 6286Reviewable decisions(1)Each of the following decisions of the commission under this Act is a reviewable decision—
(a)a decision to refuse an application for a licence or a permit;
(aa)a decision to refuse an application for renewal of a licence;
(b)a decision to impose or vary a condition of a licence;
(c)a decision to suspend or cancel a licence or permit;
(d)a decision that there are reasonable grounds for concern that a licensee does not satisfy the minimum financial requirements;
(e)a decision to give a direction to rectify or remedy or not to give the direction;
(f)a decision that building work undertaken at the direction of the commission is or is not of a satisfactory standard;
(g)a decision about the scope of works to be undertaken under the statutory insurance scheme to rectify or complete tribunal work;
(h)a decision to disallow a claim under the statutory insurance scheme wholly or in part;
(i)a decision that a domestic building contract has been validly terminated having the consequence of allowing a claim for non-completion under the statutory insurance scheme;
(j)a decision of the commission to take disciplinary action against a person under section 74F;
(ja)a decision under section 50CB to give a person an exclusion notice;
(k)a decision under section 56AF or 56AG that—
(i)a person is an excluded individual or excluded company; or
(ii)an individual is still a director or secretary of, or an influential person for, a company;
(ka)if the commission gives an individual a notice under section 56AK(3)—
(i)the commission’s decision that the individual is an excluded individual for a relevant event; or
(ii)the commission’s decision under section 56AK(2) to publish the individual’s relevant details;
(l)a decision under section 66 or 67 that a person is a convicted company officer;
(m)a decision under section 67AA that a company that is a licensee has an individual who is a convicted company officer as a director or secretary of, or an influential person or nominee for, the company;
(n)a decision under section 67AH, 67AI, 67AL or 67AM that an individual is a banned individual for a stated term;
(o)a decision under section 67AN that a company that is a licensee has an individual who is a banned individual as a director or secretary of, or an influential person or nominee for, the company;
(p)a decision under section 67AZF, 67AZJ or 67AZK that an individual is a disqualified individual for a stated term;
(q)a decision under section 67AZL that a company that is a licensee has an individual who is a disqualified individual as a director or secretary of, or an influential person or nominee for, the company;
(r)a decision to direct a person in the chain of responsibility for a building product to take stated action under section 74AL(5);
(s)a decision to give a direction under section 74AN;
(t)a decision not to accept a building product undertaking under part 6AA, division 3;
(u)a decision not to agree to a withdrawal or variation of a building product undertaking under section 74AT.
(2)Also, a decision of the commission or commissioner under any of the following provisions is a reviewable decision—
(a)the Building Act 1975, section 157, 169, 177, 204, 214K, 245O, 245Q, 246BJ, 246BP, 246BT, 246BZ or 246CY;
(aa)the Building Industry Fairness (Security of Payment) Act 2017, section 54E;
(b)the Plumbing and Drainage Act 2018, section 19, 29, 32, 34, 38 or 51;
(c)section 106J(4)(a), 106K or 108AI.
(3)Further, a decision of the commissioner relating to the accumulation of demerit points by a pool safety inspector under the Building Act 1975 is a reviewable decision.(4)In addition, each of the following decisions of an investigator is a reviewable decision—
(a)a decision to seize a place, part of a place, building, structure or other thing under part 9, division 6;
(b)a decision to require information or attendance before the investigator under section 105T;
(c)a decision to give a direction under section 106P or 106Q.
s 86 prev s 86 om 2000 No. 10s 183sch 1pres s 86 ins 2003 No. 30s 169sch 1amd 2007 No. 47s 63; 2013 No. 38s 14sch 1; 2014 No. 56s 63; 2014 No. 57s 42; 2017 No. 29s 15; 2018 No. 17s 193A; 2017 No. 43s 286; 2018 No. 17s 197sch 2; 2020 No. 24ss 122, 133, 14686AWho may apply for internal review(1)A person who is given, or is entitled to be given, notice of a reviewable decision may apply to the internal reviewer to have the decision reviewed.(2)However, subsection (1) does not apply if the person has applied to the tribunal for a review of the reviewable decision under subdivision 2.(3)Also, if—
(a)the person applies for an internal review of the reviewable decision; and
(b)before the application is decided, the person applies to the tribunal for review of the reviewable decision under subdivision 2;
the application for internal review of the decision lapses.s 86A ins 2014 No. 56s 64amd 2016 No. 11s 1786BRequirements for making applicationAn internal review application must—
(a)be made within the following period—
(i)28 days after the applicant is given notice of the reviewable decision to which the application relates or otherwise becomes aware of the decision; or
(ii)a longer period allowed by the internal reviewer, whether before or after the end of the 28-day period mentioned in subparagraph (i); and
(b)be lodged at an office of the commission.
s 86B ins 2014 No. 56s 64amd 2016 No. 11s 1886CInternal review decision(1)If an internal review application is made under section 86B, the internal reviewer must, as soon as practicable but within the required period, make a new decision (the internal review decision) as if the reviewable decision the subject of the application had not been made.(2)For subsection (1), the required period is—
(a)28 days after the internal review application is made; or
(b)a longer period agreed to by the applicant.
(3)However, if the internal reviewer does not decide the application within the required period, the internal reviewer is taken to have made an internal review decision at the end of the required period that is the same as the reviewable decision.(4)If the internal reviewer is the commission, the application must not be dealt with by—
(a)the person who made the reviewable decision; or
(b)a person in a less senior office than the person who made the reviewable decision.
(5)Subsection (4)—
(a)applies despite the Acts Interpretation Act 1954, section 27A; and
(b)does not apply to a reviewable decision made by the commissioner personally.
s 86C ins 2014 No. 56s 64amd 2016 No. 11s 1986DNotice of internal review decision(1)As soon as practicable after an internal review decision is made, or is taken to have been made, under section 86C, the internal reviewer must give the applicant and any other person affected by the decision written notice (the review notice) of the decision.(2)The review notice must state—
(a)the decision; and
(b)the reasons for the decision; and
(c)that the person may, if dissatisfied with the internal review decision, within 28 days after the person is given the notice apply to the tribunal for external review of the decision under subdivision 2; and
(d)how to apply for review of the decision.
s 86D ins 2014 No. 56s 64amd 2016 No. 11s 20Subdivision 2External reviewpt 7 div 3 sdiv 2 hdg ins 2014 No. 56s 6286EDefinition for sdiv 2In this subdivision—reviewable decision means—
(a)a reviewable decision within the meaning of subdivision 1, other than a decision that was the subject of an internal review under subdivision 1; or
(b)an internal review decision within the meaning of subdivision 1.
s 86E ins 2014 No. 56s 6286FDecisions that are not reviewable decisions(1)The following decisions of the commission under this Act are not reviewable decisions under this subdivision—
(a)a decision to recover an amount under section 71;
(b)a decision to give a person a direction to rectify or remedy, and any finding by the commission in arriving at the decision if—
(i)28 days have elapsed from the date the direction was served on a person and the person has not, within that time, applied to the tribunal for a review of the decision; and
(ii)the commission has—
(A)started a disciplinary proceeding against the person under part 6A; or
(B)served a notice on the person advising a claim under the statutory insurance scheme has been approved in relation to the building work relevant to the direction; or
(C)started a prosecution, or served an infringement notice, for an offence against section 73 in relation to the direction;
(c)a decision about the scope of works to be undertaken under the statutory insurance scheme to rectify or complete tribunal work if 28 days have elapsed since the decision was served on the building contractor and the contractor has not, within that time, applied to the tribunal for a review of the decision;
(d)a decision to give information to a health or safety regulator under section 28A.
(2)Also, a decision of the commissioner to issue an infringement notice for an offence against this Act, the Building Act 1975 or the Plumbing and Drainage Act 2018 is not a reviewable decision under this subdivision.s 86F ins 2014 No. 56s 62amd 2014 No. 57s 43; 2017 No. 29s 16; 2018 No. 17s 197sch 287Application for reviewA person affected by a reviewable decision of the commission may apply, as provided under the QCAT Act, to the tribunal for a review of the decision.s 87 prev s 87 om 2000 No. 10s 183sch 1pres s 87 ins 2003 No. 30s 169sch 1amd 2007 No. 47s 64; 2009 No. 24s 1686; 2013 No. 38s 14sch 187ANo stay by QCAT of particular decisions(1)This section applies if a person applies to the tribunal for a review under section 87 of any of the following decisions of the commission—
(a)a decision to give a direction to rectify or remedy or not to give the direction;
(b)a decision that building work undertaken at the direction of the commission is or is not of a satisfactory standard;
(c)a decision about the scope of works to be undertaken under the statutory insurance scheme to rectify building work that is defective or incomplete;
(d)a decision to disallow a claim under the statutory insurance scheme wholly or in part;
(e)a decision that a domestic building contract has been validly terminated having the consequence of allowing a claim for non-completion under the statutory insurance scheme;
(f)a decision to direct a person in the chain of responsibility for a building product to take stated action under section 74AL(5);
(g)a decision to direct a person to take remedial action under section 74AN.
(1A)This section also applies if a person applies to the tribunal for a review under section 87 of any of the following decisions—
(a)a decision of the commissioner to issue a stop work notice under section 108AI;
(b)a decision of an investigator to seize a place, part of a place, building, structure or other thing under part 9, division 6;
(c)a decision of an investigator to give a direction under section 106P or 106Q.
(2)QCAT must not grant a stay of the decision.s 87A ins 2014 No. 57s 44amd 2017 No. 29s 17; 2018 No. 17s 193B87AADecision of tribunal on review of particular reviewable decisions(1)Subsection (2) applies if—
(a)an application is made to the tribunal for a review of a reviewable decision mentioned in section 86(1)(n); and
(b)the tribunal is, after reviewing the matters mentioned in section 67AH(1)(a) and (b), 67AI(1)(a) and (b), 67AL(1)(a) and (b) or 67AM(1)(a) and (b), satisfied that an individual is a banned individual.
(2)The tribunal may not vary the term of ban applying to the individual if it has been correctly calculated under section 67AO.(3)Subsection (4) applies if—
(a)an application is made to the tribunal for a review of a reviewable decision mentioned in section 86(1)(p); and
(b)the tribunal is, after reviewing the matters mentioned in section 67AZF(1), 67AZG(1), 67AZJ(1)(a) and (b) or 67AZK(1)(a) and (b), satisfied that an individual is a disqualified individual.
(4)The tribunal may not vary the term of disqualification applying to the individual if it has been correctly calculated under section 67AZM.s 87AA ins 2014 No. 56s 65Division 4pt 7 div 4 hdg prev div 4 hdg om 2000 No. 10s 183sch 1pres div 4 hdg ins 2003 No. 30s 169sch 1om 2014 No. 57s 4588s 88 prev s 88 om 2000 No. 10s 183sch 1pres s 88 ins 2003 No. 30s 169sch 1amd 2007 No. 47s 65; 2009 No. 24s 1687; 2013 No. 38s 14sch 1om 2014 No. 57s 4589s 89 prev s 89 amd 1994 No. 20s 26om 2000 No. 10s 183sch 1pres s 89 ins 2003 No. 30s 169sch 1amd 2007 No. 47s 66; 2010 No. 54s 67sch; 2013 No. 38s 14sch 1om 2014 No. 57s 4590s 90 prev s 90 om 2000 No. 10s 183sch 1pres s 90 ins 2003 No. 30s 169sch 1amd 2007 No. 47s 67; 2010 No. 54s 67sch; 2013 No. 38s 14sch 1om 2014 No. 57s 4591s 91 prev s 91 sub 1992 No. 68s 3sch 1om 2000 No. 10s 183sch 1pres s 91 ins 2003 No. 30s 169sch 1amd 2007 No. 47s 68sub 2009 No. 24s 1688amd 2013 No. 38s 14sch 1om 2014 No. 57s 45Division 5Public examinationspt 7 div 5 hdg prev div 5 hdg om 2000 No. 10s 183sch 1pres div 5 hdg ins 2003 No. 30s 169sch 192Tribunal may conduct public examinationThe tribunal may, on application by the commission, conduct a public examination—
(a)that investigates the conduct or competence of a person who has carried out tribunal work or undertaken to carry out tribunal work; or
(b)that investigates whether a person—
(i)satisfies the minimum financial requirements for the licence held by the person; or
(ii)has the qualifications and experience required for the licence held by the person; or
(iii)if the person is the nominee for a corporation that holds a licence—has the qualifications and experience required for the licence held by the corporation; or
(iv)is a fit and proper person to hold a licence; or
(v)if the person exercises control over a corporation that holds a licence—is a fit and proper person to exercise control over the corporation; or
(vi)has breached a condition imposed on the person’s licence; or
(c)that investigates whether a person has contravened—
(i)a duty under part 6AA, division 2; or
(ii)a direction or requirement of an investigator under part 9 relating to a building product that is, or is suspected to be, a non-conforming building product for an intended use.
s 92 prev s 92 amd 1994 No. 20s 27om 2000 No. 10s 183sch 1pres s 92 ins 2003 No. 30s 169sch 1amd 2007 No. 47s 69; 2013 No. 38s 14sch 1; 2017 No. 29s 18; 2018 No. 17s 193C; 2017 No. 43s 28792AProcedure before public examination starts(1)Before the start of a public examination, the tribunal must be satisfied each person to be examined has received written grounds for the public examination.(2)On being satisfied under subsection (1), the tribunal must—
(a)decide a time and place for the public examination; and
(b)issue an attendance notice to each person to be examined.
(3)If a person to be examined is a corporation, the tribunal must issue the attendance notice requiring the executive officer of the corporation to attend the tribunal for examination.(4)The attendance notice must state—
(a)the time and place for the public examination decided by the tribunal; and
(b)that the person may make oral and written submissions at the examination.
(5)The commission must serve the attendance notice on the person to whom it was issued.s 92A ins 2009 No. 24s 1689amd 2013 No. 38s 14sch 1Division 6Decisions about debts arising from statutory insurance schemept 7 div 6 hdg prev div 6 hdg om 2000 No. 10s 183sch 1pres div 6 hdg ins 2003 No. 30s 169sch 193Decisions about debts arising from statutory insurance scheme(1)The commission may recover a debt under section 71 by application to the tribunal under this section.(2)The tribunal may exercise 1 or more of the following powers—
(a)order the payment of an amount the tribunal has found to be owing to the commission;
(b)order the payment of interest on the amount mentioned in paragraph (a);
(c)order the payment of costs;
(d)order that amounts mentioned in paragraphs (a), (b) and (c) be paid by instalments or another way directed by the tribunal.
s 93 prev s 93 om 2000 No. 10s 183sch 1pres s 93 ins 2003 No. 30s 169sch 1amd 2007 No. 47s 70; 2013 No. 38s 14sch 1Division 7Tribunal proceedingspt 7 div 7 hdg ins 2003 No. 30s 169sch 1sub 2009 No. 24s 169093ARepresentation of parties(1)This section applies to a party in a proceeding before the tribunal relating to a matter under this Act.(2)The party may be represented by a lawyer if—
(a)the proceeding relates to an application under section 93; or
(b)the proceeding is a public examination.
s 93A ins 2009 No. 24s 169094Transfer of proceedings between tribunal and the courtsIf proceedings relating to a major commercial building dispute are brought in a court, the court may order that the proceeding be transferred to the tribunal only if all parties to the dispute apply for the order.s 94 prev s 94 om 2000 No. 10s 183sch 1pres s 94 ins 2003 No. 30s 169sch 1amd 2007 No. 47s 71sub 2009 No. 24s 169095Expedited hearing of domestic building disputes or reviews(1)The tribunal must decide a minor domestic building dispute at an expedited hearing if the dispute has been to mediation but has not been settled, unless the tribunal considers the dispute is too complex to be properly dealt with at an expedited hearing.Example of too complex to be properly dealt with—The dispute involves complex legal and contractual issues for which the tribunal is unaware of any authoritative precedent.(2)Subject to subsection (3), the tribunal may decide a domestic building dispute that is not a minor domestic building dispute at an expedited hearing only if—
(a)all parties to the proceeding apply, as provided under the QCAT Act, to the tribunal for the matter to be dealt with at an expedited hearing; and
(b)the tribunal considers it appropriate for the dispute to be decided at an expedited hearing.
(3)The tribunal may decide a domestic building dispute between a building owner and a building contractor at an expedited hearing if—
(a)the building contractor applied to the tribunal to have the tribunal decide the dispute; and
(b)prior to the proceedings the building owner applied under section 71A for the commission to consider whether to direct the following rectification of building work—
(i)to complete incomplete domestic building work;
(ii)to remedy defective domestic building work relating to a building that—
(A)adversely affects the structural performance of the building; or
(B)adversely affects the health or safety of a person occupying the building; or
(C)adversely affects the functional use of the building; or
(D)allows water penetration into the building; and
(c)the tribunal considers the building owner may suffer undue hardship if the matter is not dealt with by expedited hearing; and
(d)having regard to the complexity of the dispute, the tribunal considers that it may properly be dealt with at an expedited hearing.
(4)The tribunal may decide a review of a decision of the commission at an expedited hearing if—
(a)a building contractor applied to the tribunal for the review; and
(b)the review is of a decision of the commission—
(i)to direct or not to direct rectification or completion of tribunal work in relation to domestic building work; or
(ii)that a domestic building contract has been validly terminated having the consequence of allowing a claim for non-completion under the statutory insurance scheme; and
(c)prior to the review being commenced, the relevant building owner for the decision applied under section 71A for the commission to consider whether to direct the following rectification of building work—
(i)to complete incomplete domestic building work;
(ii)to remedy defective domestic building work relating to a building that—
(A)adversely affects the structural performance of the building; or
(B)adversely affects the health or safety of a person occupying the building; or
(C)adversely affects the functional use of the building; or
(D)allows water penetration into the building; and
(d)the tribunal considers the relevant building owner for the decision may suffer undue hardship if the matter is not dealt with by expedited hearing; and
(e)having regard to the complexity of the review the tribunal considers that it may properly be dealt with at an expedited hearing.
(5)The tribunal may decide a review of a decision of the commission, the commissioner or an investigator at an expedited hearing if—
(a)the review is of—
(i)a decision of the commission to give a direction to a person in the chain of responsibility for a building product under section 74AL(5) or 74AN; or
(ii)a decision of the commissioner to issue a stop work notice under section 108AI; or
(iii)a decision of an investigator to seize a place, part of a place, building, structure or other thing under part 9, division 6; or
(iv)a decision of an investigator to give a direction under section 106P or 106Q; and
(b)the tribunal considers the applicant for review, or another person, may suffer undue hardship if the matter is not dealt with at an expedited hearing; and
(c)having regard to the complexity of the review the tribunal considers that it may properly be dealt with at an expedited hearing.
s 95 prev s 95 om 2000 No. 10s 183sch 1pres s 95 ins 2003 No. 30s 169sch 1amd 2007 No. 47s 72; 2009 No. 24s 1692; 2009 No. 48s 178; 2013 No. 38s 14sch 1; 2017 No. 29s 19; 2018 No. 17s 193D96Certain minor commercial building disputes may be expedited(1)The tribunal may conduct an expedited hearing for a minor commercial building dispute between a subcontractor and another person if—
(a)neither the claim nor any counterclaim exceeds $10,000; and
(b)the dispute relates only to a claim for moneys owing by a person to the subcontractor for tribunal work completed by the subcontractor under a written contract; and
(c)the subcontractor files an application for an expedited hearing, a copy of the contract and an affidavit by the subcontractor stating that—
(i)the tribunal work under the contract has been completed by the subcontractor to the standard required under the contract; and
(ii)a claim for payment payable under the contract has been given to the other person by the subcontractor; and
(iii)the amount claimed by the subcontractor has not been paid by the other person; and
(iv)no complaint about the tribunal work under the contract has been made to the subcontractor by the other person.
(2)A hearing under this section may proceed only if the subcontractor has given the other person a copy of the application and all documents filed by the subcontractor at least 5 days before the hearing.s 96 prev s 96 amd 1994 No. 20s 28om 2000 No. 10s 183sch 1pres s 96 ins 2003 No. 30s 169sch 1amd 2007 No. 47s 73Division 8Other powers of the tribunalpt 7 div 8 hdg prev div 8 hdg ins 2003 No. 30s 169sch 1om 2009 No. 24s 1691pres div 8 hdg ins 2009 No. 24s 169497Entry and inspection of property by member of tribunal(1)A member of the tribunal may, if it is necessary to do so for the purposes of a proceeding before the tribunal—
(a)enter and inspect a building or land relevant to the proceeding accompanied by the parties to the proceeding; or
(b)authorise a person in writing to take the following action and report to the tribunal on the action taken—
(i)enter and inspect a building or land relevant to the proceeding;
(ii)take photographs, video film or an image of the building or land or anything relevant to the proceeding;
(iii)carry out tests approved by the tribunal.Examples of building or land relevant to the proceeding—
•a display home mentioned in a contract as the model to be followed by a building contractor if the display home is occupied by a third party
•land adjoining other land on which is situated building work the subject of a proceeding to better inspect the building work from the adjoining land
(2)A person must not obstruct a member of the tribunal, or a person authorised under subsection (1)(b), in the exercise of a power mentioned in subsection (1).Maximum penalty—200 penalty units.s 97 orig s 97 amd 1996 No. 58s 4om 2000 No. 10s 183sch 1prev s 97 ins 2003 No. 30s 169sch 1amd 2007 No. 47s 74om 2009 No. 24s 1693pres s 97 ins 2009 No. 24s 169497Bs 97B ins 2009 No. 24s 1694amd 2013 No. 38s 14sch 1; 2014 No. 57s 46om 2017 No. 29s 2097CSuspension orders(1)If the tribunal is satisfied, on application by the commission, that a licence should be suspended, the tribunal may, by order, suspend the licence—
(a)for the period the tribunal considers reasonable; or
(b)until the holder of the licence (the suspended person) complies with a condition imposed on the licence by the tribunal.
(2)The order may direct the suspended person to deliver the licence to the commission and include any other directions the tribunal considers necessary or convenient to give effect to the order.(3)The tribunal may make an order under this section on application made without notice to the suspended person but, in that case, the tribunal must allow the suspended person a reasonable opportunity to show cause why the order should be rescinded.(4)If the tribunal after considering the suspended person’s evidence and submissions, if any, and any further evidence or submissions of the commission, is not satisfied the order should continue in force, the tribunal must rescind the order.(5)The holder of a licence who contravenes a direction under subsection (2) commits an offence.Maximum penalty—80 penalty units.s 97C ins 2009 No. 24s 1694amd 2013 No. 38s 14sch 1Part 8Registerspt 8 hdg prev pt 8 hdg om 2000 No. 10s 183sch 1pres pt 8 hdg ins 2007 No. 47s 75pt 8 div 1 hdg om 2000 No. 10s 183sch 1pt 8 div 2 hdg om 2000 No. 10s 183sch 1pt 8 div 3 hdg om 2000 No. 10s 183sch 1pt 8 div 4 hdg sub 1994 No. 20s 31om 2000 No. 10s 183sch 1pt 8 div 5 hdg sub 1994 No. 20s 33om 2000 No. 10s 183sch 198Definitions for pt 8In this part—developer register see section 103B.licensee register see section 99.owner-builder register see section 103.s 98 prev s 98 om 2000 No. 10s 183sch 1pres s 98 ins 2007 No. 47s 7599Licensee register(1)A register of licensees (the licensee register) must be kept by the commission.(2)The register must include the following particulars in relation to each licensee—
(a)the licensee’s full name, business address and licence number;
(b)if the licensee is a company—the full name and business address of the nominee and each director;
(c)the class of licence held by the licensee and any conditions to which the licence is, or has been, subject;
(d)any disciplinary action taken against the licensee that has taken effect under section 74G and is not the subject of an internal review or review by the tribunal;
(e)any particulars required by regulation.
(3)The register must also contain against the name of each licensee a note of—
(a)each direction of the commission requiring the licensee to rectify building work or to remedy consequential damage; and
(d)each time the licensee is convicted of an offence against this Act, or the Building Industry Fairness (Security of Payment) Act 2017, and the provision of the Act that was contravened; and
(e)each offence for which the licensee has for this Act been served with an infringement notice and—
(i)the licensee has paid the fine in full or in part; or
(ii)a default certificate has been registered for the infringement notice; and
(ii)an infringement notice default has been registered for the notice under the State Penalties Enforcement Act 1999, section 34; and
(f)any demerit points allocated to the licensee, the demerit matters for which they were allocated and the dates the points took effect; and
(g)any cancellation or suspension of the licensee’s licence including the circumstances that led to the cancellation or suspension; and
(h)if the licensee has been a permanently excluded individual, an excluded individual, a banned individual or a disqualified individual—the details of the circumstances that led to the exclusion, ban or disqualification; and
(i)if the licensee is a company that has a director, secretary, influential person or nominee that became a permanently excluded individual, an excluded individual, a banned individual or a disqualified individual in the last 10 years—the details of the circumstances that led to the exclusion, ban or disqualification; and
(j)the number and cost of claims approved under the statutory insurance scheme that relate to residential construction work for which the licensee paid, or ought to have paid, an insurance premium.
Editor’s note—Section 99(3) incorporates an uncommenced amendment—see 2017 Act No. 13s 90sch 1.(4)A reference in subsection (3) to something happening in relation to a person who is a licensee includes something happening—
(a)in relation to the person before the person became a licensee; and
(b)before the commencement of this section.
(5)In this section—licensee includes a person who was previously a licensee.s 99 prev s 99 amd 1994 No. 20s 29om 2000 No. 10s 183sch 1pres s 99 ins 2007 No. 47s 75amd 2009 No. 24s 1695; 2013 No. 38s 14sch 1; 2014 No. 57s 47; 2018 No. 17s 193E99As 99A ins 1994 No. 20s 30om 2000 No. 10s 183sch 1100When information may be included in the licensee register(1)No information may be included in the register under section 99(3)(a) until—
(a)all periods for seeking a review of the direction, and for making any appeal arising out of review of the direction, have ended; and
(b)any review or appeal about the direction is finally decided or is not proceeded with.
(2)No information may be included in the register under section 99(3)(b) or (c) until—
(a)all periods for making an appeal arising out of the tribunal’s order or decision have ended; and
(b)any appeal about the order or decision is finally decided or is not proceeded with.
(3)No information may be included in the register under section 99(3)(d) until—
(a)all periods for making an appeal arising out of the conviction have ended; and
(b)any appeal about the conviction is finally decided or is not proceeded with.
(4)No information may be included in the register under section 99(3)(e)(ii) if a licensee has applied for cancellation of the enforcement order and the application for cancellation has not been finally decided.s 100 prev s 100 om 2000 No. 10s 183sch 1pres s 100 ins 2007 No. 47s 75101Licensees must advise change of circumstances(1)If circumstances change so that the particulars recorded in the licensee register in relation to a particular licensee no longer reflect the current position, the licensee must, within 14 days after the date of the change, give the commission particulars of the change.Maximum penalty—20 penalty units.(2)Particulars may be given under subsection (1)—
(a)by written notice; or
(b)in another way approved by the commission, and advised generally to licensees, as a suitable way for advising particulars to the commission.
s 101 prev s 101 amd 1992 No. 68s 3sch 1; 1995 No. 58s 4sch 1; 1999 No. 43s 34om 2000 No. 10s 183sch 1pres s 101 ins 2007 No. 47s 75amd 2013 No. 38s 14sch 1; 2014 No. 57s 48102When notes must be removed from the licensee register(1)A note made in the register under section 99(3) must be taken off—
(a)for information mentioned in section 99(3)(g) and (h), 10 years after it is made; or
(b)for information mentioned in section 99(3)(f), 3 years after it is made; or
(c)for information mentioned in section 99(3)(i), the earlier of—
(i)when the director, secretary, influential person or nominee is no longer a director, secretary, influential person or nominee for the company; or
(ii)10 years from the time the director, secretary, influential person or nominee became a permanently excluded individual, excluded individual, banned individual or a disqualified individual; or
(d)otherwise, 5 years after it is made.
(2)However, details of demerit points and the demerit matters for which points were allocated must be removed from the register—
(a)if the points stop having effect; or
(b)if the points relate to an unsatisfied judgment debt, when the commission is satisfied the judgment debt has been paid.
(3)Also, for section 99(3)(e), details of an offence must be removed from the register if—
(a)the infringement notice for the offence is withdrawn by the commission; or
(b)the enforcement order stops having effect, other than because the amount owing under the enforcement order has been paid or the order has been otherwise discharged.
(4)Also, a note that states that an individual is prevented, for the life of the individual, from obtaining a licence under this Act must not be removed from the register.s 102 prev s 102 om 2000 No. 10s 183sch 1pres s 102 ins 2007 No. 47s 75amd 2013 No. 38s 14sch 1102As 102A ins 1994 No. 20s 32om 2000 No. 10s 183sch 1103Register of holders of owner-builder permits(1)A register of persons holding owner-builder permits (the owner-builder register) must be kept by the commission.(2)The register must include the following particulars in relation to each permittee—
(a)the permittee’s full name, or if the permittee is a company the full name and business address of each of the directors of the company;
(b)the location of the land on which the owner-builder work is to be carried out;
(c)the real property description of the land;
(d)a description of the owner-builder work to be carried out on the land;
(e)the date of issue of the permit;
(f)the term of the permit;
(g)the permit number;
(h)the conditions of the permit;
(i)any particulars required by regulation.
(3)If circumstances change so that the particulars recorded in the register in relation to a particular permittee no longer reflect the current position, the permittee must, within 14 days after the date of the change, give the commission particulars of the change.(4)Particulars under subsection (3) may be given—
(a)by written notice; or
(b)in another way approved by the commission.
s 103 prev s 103 sub 1994 No. 20s 33om 2000 No. 10s 183sch 1pres s 103 ins 2007 No. 47s 75amd 2013 No. 38s 14sch 1103AWhen particulars must be removed from owner-builder registerParticulars relating to a permittee must be removed from the owner-builder register when the term of the permittee’s permit ends.s 103A ins 2007 No. 47s 75103BDeveloper register(1)A register (the developer register) containing details about each principal (the relevant developer) mentioned in section 71I(l) given a direction under section 72(1) must be kept by the commission.(2)The register must contain against the name of a relevant developer a note of—
(a)each direction of the commission requiring the relevant developer to rectify building work; and
(b)each time the relevant developer is convicted of an offence against section 73.
(3)However, no information may be included in the register under subsection (2)(a) until—
(a)all periods for seeking a review of the direction, and for making any appeal arising out of a review of the direction, have ended; and
(b)any review or appeal about the direction is finally decided or is not proceeded with.
(4)Also, no information may be included in the register under subsection (2)(b) until—
(a)all periods for making an appeal arising out of the conviction have ended; and
(b)any appeal about the conviction is finally decided or is not proceeded with.
(5)Subsection (6) applies if—
(a)the register contains the name of a relevant developer that is a company because the company has been convicted of an offence against section 73; and
(b)an executive officer of the company is convicted of an offence under section 111B in relation to the offence under section 73; and
(c)all periods for making an appeal arising out of the conviction of the executive officer have ended; and
(d)any appeal about the conviction by the executive officer is finally decided or is not proceeded with.
(6)A note of the conviction of the executive officer must be included in the register.s 103B ins 2007 No. 47s 75amd 2013 No. 38s 14sch 1; 2017 No. 43s 288103CWhen notes must be removed from developer registerA note made in the developer register must be taken off the register 5 years after it is made.s 103C ins 2007 No. 47s 75103DInspection of registersA person may, on payment of the fee, and subject to the conditions, prescribed by regulation, inspect a register at the commission’s offices at any time the offices are open to the public.s 103D ins 2007 No. 47s 75amd 2013 No. 38s 14sch 1103EPublication of registersThe commission may publish a register on the commission’s internet site.s 103E ins 2007 No. 47s 75amd 2013 No. 38s 14sch 1; 2014 No. 57s 49103FCertificates(1)The commission may, on application by any person and payment of the fee fixed by regulation, issue a certificate certifying any matter contained in a register kept under this Act.(2)A certificate under this section is admissible in legal proceedings as evidence of any matter stated in the certificate.s 103F ins 2007 No. 47s 75amd 2013 No. 38s 14sch 1Part 9Investigatorspt 9 hdg amd 2017 No. 43s 289Division 1Preliminarypt 9 div 1 hdg ins 2017 No. 29s 21103GDefinitions for partIn this part—compliance purpose means any of the following purposes—
(a)ascertaining whether a relevant Act is being complied with;
(b)determining whether building work at or on a place has been, or is being, properly carried out;
(c)determining whether a building product associated with, or proposed to be associated with, a building or other structure, or a proposed building or other structure, for a particular use is a non-conforming building product for that use.
document certification requirement see section 105Q(6).document production requirement see section 105Q(2).electronic document means a document of a type under the Acts Interpretation Act 1954, schedule 1, definition document, paragraph (c).examine includes analyse, test, account, measure, weigh, grade, gauge and identify.general power see section 105L(1).help requirement see section 105M(1).identity card, for a provision about investigators, means an identity card issued under section 104F.s 103G def identity card sub 2017 No. 43s 290(1)information notice, for a decision, means a written notice stating—
(a)the decision; and
(b)the reasons for the decision; and
(c)the rights of review under this Act for the decision; and
(d)how, and the period within which, a review under this Act for the decision may be started; and
(e)if applicable, how a stay of the operation of the decision may be applied for under the QCAT Act.
occupier, of a place, includes the following—
(a)if there is more than 1 person who apparently occupies the place—any 1 of the persons;
(b)any person at the place who is apparently acting with the authority of a person who apparently occupies the place;
(c)if no-one apparently occupies the place—any person who is an owner of the place.
offence warning, for a direction or requirement by an investigator, means a warning that, without a reasonable excuse, it is an offence for the person to whom the direction or requirement is made not to comply with it.s 103G def offence warning amd 2017 No. 43s 290(2)owner, of a seized thing, includes a person who would be entitled to possession of the seized thing had it not been seized.personal details requirement see section 105O(5).person in control, of a place or thing, includes anyone who reasonably appears to be, claims to be, or acts as if he or she is, the person in control or possession of the place or thing.place includes the following—
(a)premises;
(b)vacant land;
(c)a place in Queensland waters;
(d)a place held under more than 1 title or by more than 1 owner;
(e)the land or water where a building or other structure, or a group of buildings or other structures, is situated.
premises includes—
(a)a building or other structure; and
(b)a part of a building or other structure; and
(c)premises held under more than 1 title or by more than 1 owner.
public place means a place, or part of a place—
(a)that the public is entitled to use, that is open to members of the public or that is used by the public, whether or not on payment of money; orExamples of a place that may be a public place under paragraph (a)—a beach, a park, a road
(b)the occupier of which allows, whether or not on payment of money, members of the public to enter.Examples of a place that may be a public place under paragraph (b)—a saleyard, a showground
reasonably suspects means suspects on grounds that are reasonable in the circumstances.relevant Act means—
(a)this Act; or
(b)the Building Act 1975; or
(c)the Building Industry Fairness (Security of Payment) Act 2017; or
(d)the Plumbing and Drainage Act 2018.
s 103G def relevant Act sub 2017 No. 43s 290(3)amd 2018 No. 17s 197sch 2seized thing means a place, part of a place, building, structure or other thing seized under division 6.s 103G ins 2017 No. 29s 21103HReferences to exercise of powersIf—
(a)a provision of this part refers to the exercise of a power by an investigator; and
(b)there is no reference to a specific power;
the reference is to the exercise of all or any investigators’ powers under this part or a warrant, to the extent the powers are relevant.s 103H ins 2017 No. 29s 21amd 2017 No. 43s 291103IReference to document includes reference to reproductions from electronic documentA reference in this part to a document includes a reference to an image or writing—
(a)produced from an electronic document; or
(b)not yet produced, but reasonably capable of being produced, from an electronic document, with or without the aid of another article or device.
s 103I ins 2017 No. 29s 21Division 3Entry of places by investigatorspt 9 div 3 hdg ins 2017 No. 29s 22amd 2017 No. 43s 294(2)Subdivision 1Power to enterpt 9 div 3 sdiv 1 hdg ins 2017 No. 29s 22105General power to enter places(1)An investigator may, for a compliance purpose, enter a place if—
(a)an occupier at the place consents under subdivision 2 to the entry and section 105C has been complied with for the occupier; or
(b)it is a public place and the entry is made when the place is open to the public; or
(c)the entry is authorised under a warrant and, if there is an occupier of the place, section 105J has been complied with for the occupier; or
(d)it is a place of business of a licensee or a person in the chain of responsibility for a building product and is—
(i)open for carrying on the business; or
(ii)otherwise open for entry; or
(e)it is a building site and building work is being carried out on the site.
(2)For subsection (1)(d), a place of business does not include a part of the place where a person resides.(3)If the power to enter arose only because an occupier of the place consented to the entry—
(a)the power is subject to any conditions of the consent and ceases if the consent is withdrawn; and
(b)the consent may include consent for re-entry and paragraph (a) applies to the power to re-enter.
(4)If the power to enter is under a warrant—
(a)the power is subject to the terms of the warrant; and
(b)the warrant may confer a power to re-enter the place and paragraph (a) applies to the power to re-enter.
s 105 sub 2007 No. 47s 76amd 2014 No. 57s 50sub 2017 No. 29s 22amd 2017 No. 43s 294(1)Subdivision 2Entry by consentpt 9 div 3 sdiv 2 hdg ins 2017 No. 29s 22105AApplication of subdivisionThis subdivision applies if an investigator intends to ask an occupier of a place to consent to the investigator or another investigator entering the place under section 105(1)(a).s 105A ins 2017 No. 29s 22amd 2017 No. 43s 294(1)105BIncidental entry to ask for accessFor the purpose of asking the occupier for the consent, an investigator may, without the occupier’s consent or a warrant—
(a)enter land around premises at the place to an extent that is reasonable to contact the occupier; or
(b)enter part of the place the investigator reasonably considers members of the public ordinarily are allowed to enter when they wish to contact an occupier of the place.
s 105B ins 2017 No. 29s 22amd 2017 No. 43s 294(1)105CMatters investigator must tell occupierBefore asking for the consent, the investigator must give a reasonable explanation to the occupier—
(a)about the purpose of the entry, including the powers intended to be exercised; and
(b)that the occupier is not required to consent; and
(c)that the consent may be given subject to conditions and may be withdrawn at any time.
s 105C ins 2017 No. 29s 22amd 2017 No. 43s 294(1)105DConsent acknowledgement(1)If the consent is given, the investigator may ask the occupier to sign an acknowledgement of the consent.(2)The acknowledgement must state—
(a)the purpose of the entry, including the powers to be exercised; and
(b)the following has been explained to the occupier—
(i)the purpose of the entry, including the powers intended to be exercised;
(ii)that the occupier is not required to consent;
(iii)that the consent may be given subject to conditions and may be withdrawn at any time; and
(c)the occupier gives the investigator or another investigator consent to enter the place and exercise the powers; and
(d)the time and day the consent was given; and
(e)any conditions of the consent.
(3)If the occupier signs the acknowledgement, the investigator must immediately give a copy to the occupier.(4)If—
(a)an issue arises in a proceeding about whether the occupier consented to the entry; and
(b)a signed acknowledgement complying with subsection (2) for the entry is not produced in evidence;
the onus of proof is on the person relying on the lawfulness of the entry to prove the occupier consented.s 105D ins 2017 No. 29s 22amd 2017 No. 43s 294(1)Subdivision 3Entry under warrantpt 9 div 3 sdiv 3 hdg ins 2017 No. 29s 22105EApplication for warrant(1)An investigator may apply to a magistrate for a warrant for a place.(2)The investigator must prepare a written application that states the grounds on which the warrant is sought.(3)The written application must be sworn.(4)The magistrate may refuse to consider the application until the investigator gives the magistrate all the information the magistrate requires about the application in the way the magistrate requires.Example—The magistrate may require additional information supporting the written application to be given by statutory declaration.s 105E ins 2017 No. 29s 22amd 2017 No. 43s 294(1)105FIssue of warrant(1)The magistrate may issue the warrant for the place only if the magistrate is satisfied there are reasonable grounds for—
(a)entering the place for a compliance purpose; or
(b)suspecting there is at the place, or will be at the place within the next 7 days, a particular thing or activity that may provide evidence of an offence against a relevant Act.
(2)The warrant must state—
(a)the place to which the warrant applies; and
(b)that a stated investigator or any investigator may with necessary and reasonable help and force—
(i)enter the place and any other place necessary for entry to the place; and
(ii)exercise the investigator’s powers; and
(c)the purpose for which the warrant is issued and, if it is issued in relation to an offence—
(i)particulars of the offence that the magistrate considers appropriate; and
(ii)the name of the person suspected of having committed the offence unless the name is unknown or the magistrate considers it inappropriate to state the name; and
(d)the evidence that may be seized under the warrant; and
(e)the hours of the day or night when the place may be entered; and
(f)the magistrate’s name; and
(g)the day and time of the warrant’s issue; and
(h)the day, within 14 days after the warrant’s issue, the warrant ends.
s 105F ins 2017 No. 29s 22amd 2017 No. 43s 294(1), (3)105GElectronic application(1)An application under section 105F may be made by phone, fax, email, radio, videoconferencing or another form of electronic communication if the investigator reasonably considers it necessary because of—
(a)urgent circumstances; or
(b)other special circumstances, including, for example, the investigator’s remote location.
(2)The application—
(a)may not be made before the investigator prepares the written application under section 105F(2); but
(b)may be made before the written application is sworn.
s 105G ins 2017 No. 29s 22amd 2017 No. 43s 294(1), (3)105HAdditional procedure if electronic application(1)For an application made under section 105G, the magistrate may issue the warrant (the original warrant) only if the magistrate is satisfied—
(a)it was necessary to make the application under section 105G; and
(b)the way the application was made under section 105G was appropriate.
(2)After the magistrate issues the original warrant—
(a)if there is a reasonably practicable way of immediately giving a copy of the warrant to the investigator, including, for example, by sending a copy by fax or email, the magistrate must immediately give a copy of the warrant to the investigator; or
(b)otherwise—
(i)the magistrate must tell the investigator the information mentioned in section 105F(2); and
(ii)the investigator must complete a form of warrant, including by writing on it the information mentioned in section 105F(2) provided by the magistrate.
(3)The copy of the warrant mentioned in subsection (2)(a), or the form of warrant completed under subsection (2)(b) (in either case the duplicate warrant), is a duplicate of, and as effectual as, the original warrant.(4)The investigator must, at the first reasonable opportunity, send to the magistrate—
(a)the written application complying with section 105E(2) and (3); and
(b)if the investigator completed a form of warrant under subsection (2)(b), the completed form of warrant.
(5)The magistrate must keep the original warrant and, on receiving the documents under subsection (4)—
(a)attach the documents to the original warrant; and
(b)give the original warrant and documents to the clerk of the court of the relevant magistrates court.
(6)Despite subsection (3), if—
(a)an issue arises in a proceeding about whether an exercise of a power was authorised by a warrant issued under this section; and
(b)the original warrant is not produced in evidence;
the onus of proof is on the person relying on the lawfulness of the exercise of the power to prove a warrant authorised the exercise of the power.(7)This section does not limit section 105E.(8)In this section—relevant magistrates court, in relation to a magistrate, means the court that the magistrate constitutes under the Magistrates Act 1991.s 105H ins 2017 No. 29s 22amd 2017 No. 43s 294(1)105IDefect in relation to a warrant(1)A warrant is not invalidated by a defect in—
(a)the warrant; or
(b)compliance with this subdivision;
unless the defect affects the substance of the warrant in a material particular.(2)In this section—warrant includes a duplicate warrant mentioned in section 105H(3).s 105I ins 2017 No. 29s 22105JEntry procedure(1)This section applies if an investigator is intending to enter a place under a warrant issued under this subdivision.(2)Before entering the place, the investigator must do or make a reasonable attempt to do the following things—
(a)identify himself or herself to a person who is an occupier of the place and is present by producing the investigator’s identity card or another document evidencing the investigator’s appointment;
(b)give the person a copy of the warrant;
(c)tell the person the investigator is permitted by the warrant to enter the place;
(d)give the person an opportunity to allow the investigator immediate entry to the place without using force.
(3)However, the investigator need not comply with subsection (2) if the investigator believes on reasonable grounds that entry to the place without compliance is required to ensure the execution of the warrant is not frustrated.(4)In this section—warrant includes a duplicate warrant mentioned in section 105H(3).s 105J ins 2017 No. 29s 22amd 2017 No. 43s 294(1), (3)Division 5Other information-obtaining powers of investigatorspt 9 div 5 hdg ins 2017 No. 29s 22amd 2017 No. 43s 294(2)105OPower to require name and address(1)This section applies if an investigator reasonably suspects a person has committed an offence against a relevant Act.(2)The investigator may require the person to state the person’s name, date and place of birth and residential address.(3)The investigator may also require the person to give evidence of the correctness of the stated name or address if, in the circumstances, it would be reasonable to expect the person to—
(a)be in possession of evidence of the correctness of the stated name or address; or
(b)otherwise be able to give the evidence.
(4)When making a personal details requirement, the investigator must give the person an offence warning for the requirement.(5)A requirement under this section is a personal details requirement.s 105O ins 2017 No. 29s 22amd 2017 No. 43s 294(1)105POffence to contravene personal details requirement(1)A person of whom a personal details requirement has been made must comply with the requirement unless the person has a reasonable excuse.Maximum penalty—50 penalty units.(2)A person may not be convicted of an offence under subsection (1) unless the person is found guilty of the offence in relation to which the personal details requirement was made.s 105P ins 2017 No. 29s 22105ROffence to contravene document production requirement(1)A person of whom a document production requirement has been made must comply with the requirement unless the person has a reasonable excuse.Maximum penalty—200 penalty units.(2)It is not a reasonable excuse for a person to fail to comply with a document production requirement on the basis that complying with the requirement might—
(a)tend to incriminate the person or expose the person to a penalty; or
(b)disclose commercial in confidence information or expose the person to a risk of financial loss.
(3)The investigator must inform the person, in a way that is reasonable in the circumstances, that the person must comply with the document production requirement even though complying with the requirement might—
(a)tend to incriminate the person or expose the person to a penalty; or
(b)disclose commercial in confidence information or expose the person to a risk of financial loss.
(4)If the person fails to comply with the document production requirement and the investigator has failed to comply with subsection (3), the person can not be convicted of the offence against subsection (1).(5)If a court convicts a person of an offence against subsection (1), the court may, as well as imposing a penalty for the offence, order the person to comply with the document production requirement.s 105R ins 2017 No. 29s 22amd 2017 No. 43s 294(1)105SOffence to contravene document certification requirement(1)A person of whom a document certification requirement has been made must comply with the requirement unless the person has a reasonable excuse.Maximum penalty—100 penalty units.(2)It is not a reasonable excuse for a person to fail to comply with a document certification requirement on the basis that complying with the requirement might—
(a)tend to incriminate the person or expose the person to a penalty; or
(b)disclose commercial in confidence information or expose the person to a risk of financial loss.
(3)The investigator must inform the person, in a way that is reasonable in the circumstances, that the person must comply with the document certification requirement even though complying with the requirement might—
(a)tend to incriminate the person or expose the person to a penalty; or
(b)disclose commercial in confidence information or expose the person to a risk of financial loss.
(4)If the person fails to comply with the document certification requirement and the investigator has failed to comply with subsection (3), the person can not be convicted of the offence against subsection (1).s 105S ins 2017 No. 29s 22amd 2017 No. 43s 294(1)105TPower to require information or attendance(1)This section applies if an investigator reasonably believes—
(a)an offence against a relevant Act has been committed; and
(b)a person may be able to give information about the offence.
(2)The investigator may, by notice given to the person, require the person to—
(a)give the investigator information related to the offence by a stated reasonable time; or
(b)attend before the investigator at a stated reasonable time and place to answer questions, or produce documents, related to the offence.
(3)For information that is an electronic document, compliance with the requirement requires the giving of a clear image or written version of the electronic document.(4)In this section—information includes a document.s 105T ins 2017 No. 29s 22amd 2017 No. 43s 294(1)105UOffence to contravene information or attendance requirement(1)A person of whom a requirement is made under section 105T(2)(a) must comply with the requirement unless the person has a reasonable excuse.Maximum penalty—50 penalty units.(2)For subsection (1), it is not a reasonable excuse for a person to fail to comply with the requirement on the basis that complying with the requirement might tend to incriminate the person or expose the person to a penalty.Note—See, however, section 107.(3)A person of whom a requirement is made under section 105T(2)(b) must not fail, without reasonable excuse, to—
(a)attend as required by the notice; and
(b)answer a question the person is required to answer by the investigator; and
(c)produce a document the person is required to produce by the notice.
Maximum penalty—50 penalty units.(4)For subsection (3), it is not a reasonable excuse for a person to fail to answer a question or produce a document on the basis that answering the question or producing the document might tend to incriminate the person or expose the person to a penalty.Note—See, however, section 107.s 105U ins 2017 No. 29s 22amd 2017 No. 43s 294(1)Division 6Seizure by investigators and forfeiturept 9 div 6 hdg ins 2017 No. 29s 22amd 2017 No. 43s 294(2)Subdivision 1Power to seizept 9 div 6 sdiv 1 hdg ins 2017 No. 29s 22106Seizing evidence at a place that may be entered without consent or warrantAn investigator who enters a place the investigator may enter under this part without the consent of an occupier of the place and without a warrant may seize a thing at the place if the investigator reasonably believes the thing is evidence of an offence against a relevant Act.s 106 amd 2014 No. 57s 51sub 2017 No. 29s 22amd 2017 No. 43ss 294(1), 308sch 1 (amdt 6 could not be given effect)106ASeizing evidence at a place that may be entered only with consent or warrant(1)This section applies if—
(a)an investigator is authorised to enter a place only with the consent of an occupier of the place or a warrant; and
(b)the investigator enters the place after obtaining the consent or under a warrant.
(2)If the investigator enters the place with the occupier’s consent, the investigator may seize a thing at the place only if—
(a)the investigator reasonably believes the thing is evidence of an offence against a relevant Act; and
(b)seizure of the thing is consistent with the purpose of entry as explained to the occupier when asking for the occupier’s consent.
(3)If the investigator enters the place under a warrant, the investigator may seize the evidence for which the warrant was issued.(4)The investigator may also seize anything else at the place if the investigator reasonably believes—
(a)the thing is evidence of an offence against a relevant Act; and
(b)the seizure is necessary to prevent the thing being hidden, lost or destroyed.
(5)The investigator may also seize a thing at the place if the investigator reasonably believes it has just been used in committing an offence against a relevant Act.s 106A ins 2003 No. 1s 38amd 2014 No. 57s 52sub 2017 No. 29s 22amd 2017 No. 43ss 294(1), 308sch 1 (amdt 7 could not be given effect)106BPower to seize non-conforming building products(1)An investigator who has entered a place under this part may seize a building product at the place if the investigator reasonably believes—
(a)the product is, or is proposed to be, associated with a building for an intended use and the product is a non-conforming building product for the use; or
(b)the product is the subject of a recall order under part 6AA, division 4, or a corresponding recall order.
(2)In this section—corresponding recall order means an order, however called, under a law of another State providing for the recall of a building product from use.s 106B ins 2003 No. 1s 38sub 2017 No. 29s 22amd 2017 No. 43s 294(1)106CPower to seize dangerous places, structures and things(1)This section applies if—
(a)an investigator enters a place under this part; and
(b)the place is a building site or has a non-conforming structure on it; and
(c)the investigator reasonably believes that the place, a part of the place, or a building or other structure or other thing on the place, is hazardous to a degree likely to cause death or a serious injury or illness to a person.
(2)The investigator may seize the place, part of the place, or the building, structure or thing.(3)In this section—non-conforming structure means a building or other structure with which a building product that is, or is suspected to be, a non-conforming building product is or has been associated.s 106C ins 2003 No. 1s 38sub 2017 No. 29s 22amd 2017 No. 43s 294(1)106DSeizure of property subject to security(1)An investigator may seize a place, part of a place, building, structure or other thing, and exercise powers relating to the place, part of the place, building, structure or thing, despite a lien or other security over it claimed by another person.(2)However, the seizure does not affect the other person’s claim to the lien or other security against a person other than the investigator or a person acting under the direction or authority of the investigator.s 106D ins 2017 No. 29s 22amd 2017 No. 43s 294(1)Subdivision 2Powers to support seizurept 9 div 6 sdiv 2 hdg ins 2017 No. 29s 22106EPower to secure seized thing(1)Having seized a place, part of a place, building, structure or other thing under this division, an investigator may—
(a)for a place, part of a place or building—take reasonable action to restrict access to it; or
(b)for another seized thing—
(i)leave it at the place where it was seized (the place of seizure) and take reasonable action to restrict access to it; or
(ii)move it from the place of seizure.
(2)For subsection (1)(a) and (b)(i), the investigator may, for example—
(a)for a place, part of a place or building—
(i)seal the entrance to the place, part of the place or building, and mark the place, part of the place or building to show access to it is restricted; or
(ii)make any equipment on the place or part of the place, or in the building, inoperable; or
(b)for another seized thing—
(i)seal the thing, or the entrance to the place of seizure, and mark the thing or place to show access to it is restricted; or
(ii)for equipment—make it inoperable; or
(c)require a person the investigator reasonably believes is in control of the seized thing to do an act mentioned in paragraph (a) or (b) or anything else an investigator could do under subsection (1)(a) or (b)(i).
Example for making equipment inoperable—make the equipment inoperable by dismantling it or removing a component without which it can not be useds 106E ins 2017 No. 29s 22amd 2017 No. 43s 294(1)106FOffence to contravene seizure requirementA person must comply with a requirement made of the person under section 106E(2)(c) unless the person has a reasonable excuse.Maximum penalty—50 penalty units.s 106F ins 2017 No. 29s 22106GOffence to interfere(1)If access to a seized thing is restricted under section 106E, a person must not tamper with the thing or with anything used to restrict access to the thing without—
(a)an investigator’s approval; or
(b)a reasonable excuse.
Maximum penalty—100 penalty units.(2)If access to a place, part of a place or building is restricted under section 106E, a person must not enter the place, part of the place or building in contravention of the restriction or tamper with anything used to restrict access to the place, part of the place or building without—
(a)an investigator’s approval; or
(b)a reasonable excuse.
Maximum penalty—100 penalty units.s 106G ins 2017 No. 29s 22amd 2017 No. 43s 294(3)Subdivision 4Forfeiturept 9 div 6 sdiv 4 hdg ins 2017 No. 29s 22106KForfeiture by commissioner decision(1)The commissioner may decide a seized thing is forfeited to the State if an investigator—
(a)after making reasonable inquiries, can not find an owner; or
(b)after making reasonable efforts, can not return it to an owner; or
(c)reasonably believes it is necessary to keep the thing to prevent it being used to commit the offence for which it was seized.
(2)However, the investigator is not required to—
(a)make inquiries if it would be unreasonable to make inquiries to find an owner; or
(b)make efforts if it would be unreasonable to make efforts to return the thing to an owner.Example for paragraph (b)—the owner of the thing has migrated to another country
(3)Regard must be had to the seized thing’s condition, nature and value in deciding—
(a)whether it is reasonable to make inquiries or efforts; and
(b)if inquiries or efforts are made—what inquiries or efforts, including the period over which they are made, are reasonable.
s 106K ins 2017 No. 29s 22amd 2017 No. 43s 294(1)106LInformation notice about forfeiture decision(1)If the commissioner decides under section 106K(1) to forfeit a seized thing, the commissioner must as soon as practicable give a person who owned the thing immediately before the forfeiture (the former owner) an information notice about the decision.(2)If the decision was made under section 106K(1)(a) or (b), the information notice may be given by leaving it at the place where the seized thing was seized, in a conspicuous position and in a reasonably secure way.(3)The information notice must state that the former owner may apply for a stay of the decision if he or she applies to the tribunal for a review of the decision.(4)However, subsections (1) to (3) do not apply if—
(a)the decision was made under section 106K(1)(a) or (b); and
(b)the place where the seized thing was seized is—
(i)a public place; or
(ii)a place where the notice is unlikely to be read by the former owner.
s 106L ins 2017 No. 29s 22Subdivision 5Dealing with property forfeited or transferred to Statept 9 div 6 sdiv 5 hdg ins 2017 No. 29s 22106MWhen place, structure or thing becomes property of the StateA place, part of a place, building or other structure or other thing becomes the property of the State if—
(a)it is forfeited to the State under section 106K(1); or
(b)its owner and the State agree, in writing, to the transfer of the ownership of it to the State.
s 106M ins 2017 No. 29s 22106NHow property may be dealt with(1)This section applies if, under section 106M, a place, part of a place, building or other structure or other thing becomes the property of the State.(2)The commissioner may deal with the place, part of the place, building, structure or thing as the commissioner considers appropriate, including, for example, by destroying it or giving it away.(3)The commissioner must not deal with the place, part of the place, building, structure or thing in a way that could prejudice the outcome of an appeal against the forfeiture under this part.(4)If the commissioner sells the place, part of the place, building, structure or thing, the commissioner may, after deducting the costs of the sale, return the proceeds of the sale to the former owner of the place, part of the place, building, structure or thing.s 106N ins 2017 No. 29s 22Division 7Additional powers for building productspt 9 div 7 hdg ins 2017 No. 29s 22106OPower to have building products or samples examined(1)This section applies if an investigator takes for examination a building product, or a sample of or from a building product, under section 105L(1)(b).(2)The commission may have the building product or sample examined.(3)A person must not, with intent to adversely affect the examination of a building product or a sample of or from a building product—
(a)tamper with a building product before an investigator takes it, or a sample of or from it, for examination; or
(b)tamper with a building product or a sample of or from a building product after it is taken by an investigator for examination.
Maximum penalty—100 penalty units.(4)An examination under this section must be conducted by a person of a class, and in the way, prescribed by regulation.(5)The commission must obtain a certificate or report stating the outcome of an examination under this section from the person conducting the examination.(6)The commission may recover, as a debt, the reasonable costs of conducting an examination of a building product, or a sample of or from a building product, under this section from a person in the chain of responsibility for the product who has failed to comply with a duty under part 6AA, division 2 in relation to the product.s 106O ins 2017 No. 29s 22amd 2017 No. 43s 294(1)106PDirection about use of non-conforming building product associated with a building or other structure(1)This section applies if an investigator reasonably believes—
(a)a building product associated with a building or other structure is, or may be, a non-conforming building product; and
(b)the building product, or using the building product in a particular way or for a particular use, is hazardous to a degree likely to cause death or a serious injury or illness to a person.
(2)The investigator may, by written notice given to the person in control of the building or structure, direct the person—
(a)to not use the building product or to not use the building product in a stated way or for a stated use; or
(b)to make the building product incapable of operation.
(3)A person to whom a notice is given under subsection (2) must comply with the notice, unless the person has a reasonable excuse.Maximum penalty—100 penalty units.s 106P ins 2017 No. 29s 22amd 2017 No. 43s 294(1)106QDirection about action at place where non-conforming building product is present(1)This section applies if an investigator reasonably believes—
(a)circumstances causing, or likely to cause, an immediate risk of serious injury or illness have arisen at a place; and
(b)the circumstances are, or involve, the presence of a building product at the place, whether or not the building product has been associated with a building or other structure.
(2)The investigator may direct the person in control of the place, or another person at the place, to take action the investigator considers necessary to remove or minimise the risk.Example of direction—An investigator reasonably believes the association of a particular building product with a medium-rise building at a place may cause pieces of glass to fragment and fall, creating a risk of injury to persons walking near the building. The investigator may direct the person in control of the place to install temporary overhead protection for persons walking near the building.(3)The direction under subsection (2) may be given orally, but must be confirmed by written notice given to the person as soon as practicable.(4)The person must comply with—
(a)the direction under subsection (2); and
(b)the notice under subsection (3).
Maximum penalty—100 penalty units.(5)The notice must state—
(a)the investigator believes that—
(i)circumstances causing, or likely to cause, an immediate risk of serious injury or illness have arisen at the place; and
(ii)the circumstances are, or involve, the presence of a building product at the place; and
(b)briefly, the circumstances that have caused or are likely to cause the risk; and
(c)if the investigator believes the circumstances involve a contravention, or likely contravention, of a provision of an Act—the provision contravened or likely to be contravened; and
(d)the action the person must take to remove or minimise the risk.
s 106Q ins 2017 No. 29s 22amd 2017 No. 43s 294(1)106RPower to take remedial action(1)This section applies in relation to a risk of death or a serious injury or illness if—
(a)a person to whom a direction is given under section 106P or 106Q in relation to the risk fails to comply with the direction; or
(b)an investigator can not give a direction under section 106P or 106Q in relation to the risk because, after taking reasonable steps, a person to whom the direction can be given can not be found.
(2)An investigator may take any remedial action the investigator believes reasonable to remove or minimise the risk.(3)The commission may recover, as a debt, the reasonable costs of any remedial action taken under this section from—
(a)if subsection (1)(a) applies—the person to whom the direction was given; or
(b)if subsection (1)(b) applies—any person to whom the direction could have been given.
s 106R ins 2017 No. 29s 22amd 2017 No. 43s 294(1)Division 7ADamage and compensationpt 9 div 7A hdg ins 2017 No. 43s 295Subdivision 1Damagept 9 div 7A sdiv 1 hdg ins 2017 No. 43s 295106SDuty to avoid inconvenience and minimise damageIn exercising a power, an investigator must take all reasonable steps to cause as little inconvenience, and do as little damage, as possible.Note—See also section 106U.s 106S ins 2017 No. 43s 295106TNotice of damage(1)This section applies if—
(a)an investigator damages something when exercising, or purporting to exercise, a power; or
(b)a person (the assistant) acting under the direction or authority of an investigator damages something.
(2)However, this section does not apply to damage the investigator reasonably considers is trivial or if the investigator reasonably believes—
(a)there is no-one apparently in possession of the thing; or
(b)the thing has been abandoned.
(3)The investigator must give notice of the damage to a person who appears to the investigator to be an owner, or person in control, of the thing.(4)However, if for any reason it is not practicable to comply with subsection (3), the investigator must—
(a)leave the notice at the place where the damage happened; and
(b)ensure it is left in a conspicuous position and in a reasonably secure way.
(5)The investigator may delay complying with subsection (3) or (4) if the investigator reasonably suspects complying with the subsection may frustrate or otherwise hinder an investigation by the investigator.(6)The delay may be only for so long as the investigator continues to have the reasonable suspicion and remains in the vicinity of the place.(7)If the investigator believes the damage was caused by a latent defect in the thing or other circumstances beyond the control of the investigator or the assistant, the investigator may state the belief in the notice.(8)The notice must state—
(a)particulars of the damage; and
(b)that the person who suffered the damage may claim compensation under section 106U.
s 106T ins 2017 No. 43s 295Subdivision 2Compensationpt 9 div 7A sdiv 2 hdg ins 2017 No. 43s 295106UCompensation(1)A person may claim compensation from the commission if the person incurs loss because of the exercise, or purported exercise, of a power by or for an investigator including a loss arising from compliance with a requirement made of the person under this part.(2)The compensation may be claimed and ordered in a proceeding—
(a)brought in a court with jurisdiction for the recovery of the amount of compensation claimed; or
(b)for an alleged offence against this Act or a relevant Act the investigation of which gave rise to the claim for compensation.
(3)A court may order the payment of compensation only if it is satisfied it is just to make the order in the circumstances of the particular case.(4)In considering whether it is just to order compensation, the court must have regard to—
(a)any relevant offence committed by the claimant; and
(b)whether the loss arose from a lawful seizure or lawful forfeiture; and
(c)whether the loss arose from performing a function or exercising a power of an investigator in good faith and without negligence.
(5)A regulation may prescribe other matters that may, or must, be taken into account by the court when considering whether it is just to order compensation.(6)Section 106S does not provide for a statutory right of compensation other than as provided by this section.(7)In this section—loss includes costs and damage.relevant Act means—
(a)this Act; or
(b)the Building Act 1975; or
(c)the Building Industry Fairness (Security of Payment) Act 2017; or
(d)the Plumbing and Drainage Act 2018.
s 106U ins 2017 No. 43s 295amd 2018 No. 17s 197sch 2Part 9ATransfer of particular assets, liabilities and employeespt 9A hdg ins 2014 No. 56s 66108AA Relevant entity(1)Each of the following entities is a relevant entity—
(a)the commission;
(b)the department administering this Act;
(c)an entity prescribed by regulation for this section.
(2)However, the regulation may only prescribe—
(a)a department; or
(b)an entity established under an Act; or
(c)an entity ultimately owned by a relevant entity or the State.
s 108AA ins 2014 No. 56s 66108AB Transfer of assets, liabilities etc. to relevant entity(1)A regulation (a transfer regulation) may make provision about all or any of the following for a relevant entity—
(a)the transfer of an asset or liability of the relevant entity to another relevant entity;
(b)the consideration for an asset or liability transferred under paragraph (a);
(c)whether and, if so, the extent to which the relevant entity is the successor in law of another relevant entity;
(d)a legal proceeding that is being, or may be, taken by or against the relevant entity to be continued or taken by or against another relevant entity;
(e)the transfer of an employee of the relevant entity to another relevant entity;
(f)the employees of the relevant entity transferred under paragraph (e), and their terms and conditions of employment, rights and entitlements;
(g)the application of a particular industrial instrument to—
(i)the employees mentioned in paragraph (f); or
(ii)the relevant entity to which the employees mentioned in paragraph (f) are transferred; or
(iii)other employees of the relevant entity mentioned in subparagraph (ii).
(2)A transfer regulation—
(a)may transfer an asset attached to land without transferring the land, even though the asset would otherwise be a part of the land; and
(b)has effect despite any other law or instrument; and
(c)may provide for a matter by reference to a document held by an entity.
(3)To remove any doubt it is declared that a transfer regulation applies despite—
(a)the Industrial Relations Act 2016; and
(b)any industrial instrument.
(4)A transfer regulation may make provision about an accounting treatment in relation to a matter mentioned in subsection (1).s 108AB ins 2014 No. 56s 66amd 2016 No. 63s 1157sch 6108AC Rights of transferred employees etc.(1)This section applies if there is a transfer of an employee (a transferred employee) from a relevant entity (the transferor) to another relevant entity (the transferee) under a transfer regulation made under section 108AB.(2)The transfer does not—
(a)reduce the transferred employee’s total remuneration; or
(b)prejudice the transferred employee’s existing or accruing rights to superannuation or recreation, sick, long service or other leave; or
(c)affect a right or entitlement of the transferred employee to be employed as a public service employee accrued—
(i)immediately before the commencement of this section; or
(ii)before, on or after the commencement of this section; or
(iii)before, on or after the commencement of this section under the Public Service Act 2008, section 123; or
(d)interrupt continuity of service, except that the transferred employee is not entitled to claim the benefit of a right or entitlement more than once for the same period of service; or
(e)constitute a termination, retrenchment or redundancy of the transferred employee’s employment by the transferor; or
(f)entitle the transferred employee to a payment or other benefit merely because he or she is no longer employed by the transferor; or
(g)require the transferor to make any payment to the transferred employee for the transferred employee’s accrued rights to recreation, sick, long service or other leave irrespective of any arrangement between the transferor and the transferred employee.
(3)The transfer has effect despite any other contract, law or instrument.(4)If the transfer regulation provides for the application of a particular industrial instrument to an employee of the transferee (other than a transferred employee), the provision does not reduce the employee’s total remuneration.s108AC ins 2014 No. 56s 66Part 9BInjunctions and stop work noticespt 9B hdg ins 2014 No. 57s 53sub 2017 No. 29s 24Division 1Injunctionspt 9B div 1 hdg ins 2017 No. 29s 24108AD Grounds for injunctionThe Supreme Court may grant an injunction against a person if the court is satisfied that the person (a respondent) has engaged, or is proposing to engage, in conduct that constitutes or would constitute—
(a)a contravention of this Act or the Building Act 1975; or
(b)an attempt to contravene this Act or the Building Act 1975; or
(c)the aiding, abetting, counselling or procuring of another person to contravene this Act or the Building Act 1975; or
(d)the inducement of, or attempt to induce, whether by threats, promises or otherwise, another person to contravene this Act or the Building Act 1975; or
(e)being in any way, directly or indirectly, knowingly concerned in, or party to, the contravention by another person of this Act or the Building Act 1975; or
(f)conspiring with other persons to contravene this Act or the Building Act 1975.
s 108AD ins 2014 No. 57s 53108AE Commissioner may apply for injunctionThe commissioner may apply to the Supreme Court for an injunction granted under this division.s 108AE ins 2014 No. 57s 53108AG Court’s powers for injunctions(1)The power of the Supreme Court to grant an injunction restraining a respondent from engaging in conduct may be exercised—
(a)whether or not it appears to the court that the respondent intends to engage again, or to continue to engage, in conduct of that kind; and
(b)whether or not the respondent has previously engaged in conduct of that kind.
(2)The power of the court to grant an injunction requiring a respondent to do an act or thing may be exercised—
(a)whether or not it appears to the court that the respondent intends to fail again, or to continue to fail, to do the act or thing; and
(b)whether or not the respondent has previously failed to do the act or thing.
(3)An interim injunction may be granted under this division until the application of the commissioner is finally decided.(4)The Supreme Court may rescind or vary an injunction granted under this division at any time.s 108AG ins 2014 No. 57s 53108AH Terms of injunction(1)The Supreme Court may grant an injunction on the terms the court considers appropriate.(2)Without limiting the court’s power under subsection (1), an injunction may be granted restraining a respondent from carrying on a business (whether or not the respondent is a building contractor or the business is carried on as part of, or incidental to, the carrying on of another business)—
(a)for a stated period; or
(b)except on stated terms and conditions.
(3)Also, the court may grant an injunction requiring a respondent to take stated action, including action to disclose information or publish advertisements, to remedy any adverse consequences of the respondent’s contravention of this Act or the Building Act 1975.s 108AH ins 2014 No. 57s 53Division 2Stop work noticespt 9B div 2 hdg ins 2017 No. 29s 25108AICommissioner may issue stop work notice(1)This section applies if the commissioner is satisfied that something is being done, or is about to be done, in contravention of a prescribed provision.(2)The commissioner may issue a notice (a stop work notice)—
(a)prohibiting the person who is doing, or about to do, the thing from starting or continuing the thing; and
(b)directing the person to take any other action the commissioner considers necessary—
(i)to give effect to the prohibition under paragraph (a); or
(ii)to ensure the contravention of the prescribed provision is not repeated or does not happen in the future.
(3)Before issuing a stop work notice to a person, the commissioner must—
(a)give the person written notice of the commissioner’s intention to issue the notice and the reasons for issuing the notice; and
(b)ask the person to show cause why the commissioner should not issue the notice.
(4)If a person wishes to show cause why the stop work notice should not be issued, the person may make written submissions to the commissioner within 5 days after receiving the notice under subsection (3) from the commissioner.(5)The commissioner must consider any written submissions made by a person within the period mentioned in subsection (4) before issuing a stop work notice.(6)A person must not contravene a stop work notice.Maximum penalty—500 penalty units.(7)In this section—prescribed provision means a provision of—
(a)this Act; or
(b)the Building Act 1975; or
(c)the Building Code of Australia.
s 108AI ins 2017 No. 29s 25Schedule 1Transitional and validating provisionssch 1 hdg amd 10 January 1994 RA s 39; 1994 No. 20s 3sch; 1997 No. 70s 3(1); 1999 No. 43s 38(4)Part 1Transitional provisions for Act No. 98 of 1991 and amending Acts up to and including Act No. 70 of 1997sch 1 pt 1 hdg ins 1997 No. 70s 3(1)amd 1999 No. 43s 38(1)1ADefinitionsIn section 2—authority means the former Queensland Building Services Authority established under the Queensland Building Services Authority Act 1991, section 5.sch 1 s 1A def authority ins 2013 No. 38s 14sch 1former board means the Builders’ Registration Board of Queensland established under the repealed Act.sch 1 s 1A def former board ins 1993 No. 76s 3sch 1repealed Act means the Builders’ Registration and Home-Owners’ Protection Act 1979.sch 1 s 1A def repealed Act ins 1993 No. 76s 3sch 1sch 1 s 1A ins 1993 No. 76s 3sch 1amd 1997 No. 70s 3(2)3sch 1 s 3 ins 1994 No. 20s 3schexp 20 November 1994 (see s 3(4))4References to repealed ActsA reference in an Act or document to either of the following Acts is taken to be a reference to this Act—
•Builders’ Registration Act 1971
•Builders’ Registration and Home-owners’ Protection Act 1979.
sch 1 s 4 prev s 4 ins 1994 No. 20s 3schexp 5 August 1994 (see s 4(4))pres s 4 ins 1994 No. 87s 3sch 15References to registrar/general manager and Home Building Advisory ServiceIn an Act or document—
(a)a reference to the registrar/general manager of the authority is taken to be a reference to the general manager of the authority; and
(b)a reference to Home Building Advisory Service is taken to be a reference to the authority.
sch 1 s 5 ins 1994 No. 20s 3sch6sch 1 s 6 ins 1994 No. 20s 3schexp 20 May 1994 (see s 6(3))7sch 1 s 7 ins 1994 No. 20s 3schamd 1997 No. 70s 3(2), (4)exp 1 October 1998 (see s 7(2))Part 2Validating provisions for Act No. 70 of 1997sch 1 pt 2 hdg ins 1997 No. 70s 3(5)amd 1999 No. 43s 38(2)9Validation of affected licences(1)An affected licence is taken to be, and at all times to have been, a validly issued licence.(2)Subsection (3) applies if—
(a)before the commencement day, an affected licence was suspended, cancelled or surrendered; and
(b)for a suspension or cancellation—the decision to suspend or cancel the licence was or is not subsequently annulled or terminated under this Act.
(3)Despite subsection (1), the licence is taken to have been a validly issued licence only until it was suspended, cancelled or surrendered.sch 1 s 9 ins 1997 No. 70s 3(5)10Period of effect of transitional licences—compliance period ended(1)This section applies to a transitional licence if—
(a)the licence is not an expired licence; and
(b)the compliance period for the licence ended before the commencement day.
(2)The licence is taken to have remained in force for the period starting when the compliance period ended and ending on the day before the commencement day.(3)Also, the licence remains in force, subject to this Act, until the end of the period of 3 months starting on the commencement day.(4)Subsection (6) applies if—
(a)before the commencement day, the relevant licensee entered into a building contract; and
(b)neither of the following things happens before the end of the period of 3 months mentioned in subsection (3)—
(i)practical completion under the contract;
(ii)termination of the contract.
(5)However, subsection (6) applies only for the contract or contracts to which it relates.(6)Despite subsection (3), the licence remains in force, subject to this Act—
(a)if, by the application of subsection (4), there is only 1 contract involved—until one of the following things happens—
(i)the stage of practical completion is reached under the contract;
(ii)the contract is terminated; or
(b)if, by the application of subsection (4), there is more than 1 contract involved—until there is no contract either under which the stage of practical completion has not been reached or that has not been terminated.
sch 1 s 10 ins 1997 No. 70s 3(5)11Period of effect of transitional licences—compliance period current(1)This section applies to a transitional licence if—
(a)the licence is not an expired licence; and
(b)the compliance period for the licence has not ended before the commencement day.
(2)The licence remains in force, subject to this Act, until the later of the following—
(a)the end of the compliance period;
(b)the end of the period of 3 months starting on the commencement day.
(3)Subsection (5) applies if—
(a)before the commencement day, the relevant licensee entered into a building contract; and
(b)neither of the following things happens before the end of the period for which the licence remains in force under subsection (2)—
(i)practical completion under the contract;
(ii)termination of the contract.
(4)However, subsection (5) applies only for the contract or contracts to which it relates.(5)Despite subsection (2), the licence remains in force, subject to this Act—
(a)if, by the application of subsection (3), there is only 1 contract involved—until one of the following things happens—
(i)the stage of practical completion is reached under the contract;
(ii)the contract is terminated; or
(b)if, by the application of subsection (3), there is more than 1 contract involved—until there is no contract either under which the stage of practical completion has not been reached or that has not been terminated.
sch 1 s 11 ins 1997 No. 70s 3(5)12Condition of transitional licences(1)This section applies to a transitional licence that is not an expired licence.(2)The licence is subject to a condition that the relevant licensee must not, while the licence remains in force under section 10 or 11, enter into a building contract on the basis of being a licensee under the licence.(3)The authority must promptly give written notice of the condition to the relevant licensee.(4)A failure by the authority to comply with subsection (3) does not affect the effectiveness of the condition.sch 1 s 12 ins 1997 No. 70s 3(5)Part 3Transitional provisions for Queensland Building Services Authority Amendment Act 1999sch 1 pt 3 hdg ins 1999 No. 43s 38(3)13Existing board goes out of officeOn the commencement of this section, the members of the board in office immediately before the commencement go out of office.sch 1 s 13 ins 1999 No. 43s 38(3)Part 4Transitional provisions for GST and Related Matters Act 2000sch 1 pt 4 hdg ins 2000 No. 20s 29sch 314Residential construction work for s 71For applying section 71(2)(a)(iii) to (vi), the relevant residential construction work mentioned in section 71(2)(a) does not include relevant residential construction work that was the subject of a contract entered into before 1 July 2000.sch 1 s 14 ins 2000 No. 20s 29sch 315Building work for s 72For applying section 72(5)(ba) to (bd), the building work mentioned in section 72(5) does not include building work that was the subject of a contract entered into before 1 July 2000.sch 1 s 15 ins 2000 No. 20s 29sch 316Delayed operation of definition building work, para (g)Despite schedule 2, definition building work, paragraph (g), until the end of 31 December 2000, building work under this Act is taken not to include the installation, maintenance, or certification of the installation or maintenance, of a fire protection system for a commercial or residential building.sch 1 s 16 ins 2000 No. 20s 29sch 3Part 5Validating and transitional provisions for Queensland Building Services Authority and Other Legislation Amendment Act 2003sch 1 pt 5 hdg ins 2003 No. 1s 43Division 1Interpretationsch 1 pt 5 div 1 hdg ins 2003 No. 1s 4317Definitions for pt 5In this part—authority means the former Queensland Building Services Authority established under the Queensland Building Services Authority Act 1991, section 5.sch 1 s 17 def authority ins 2013 No. 38s 14sch 1board means the former Queensland Building Services Board established under the Queensland Building Services Authority Act 1991, section 8.sch 1 s 17 def board ins 2013 No. 38s 14sch 1the regulation means the Queensland Building Services Authority Regulation 1992.sch 1 s 17 ins 2003 No. 1s 43Division 3Terms of insurance policiessch 1 pt 5 div 3 hdg ins 2003 No. 1s 4319Validation of provision about terms of insurance policy(1)This section applies to section 24 of the regulation as in force, or purporting to be in force, before the commencement of this section.(2)The section is taken to have been valid at all times including for the purpose of prescribing the terms of a policy of insurance under section 69(2) of the Act as in force at a time mentioned in subsection (1).(3)Without limiting subsection (2), the board is taken to have had the power to make the policies mentioned in the section of the regulation.sch 1 s 19 ins 2003 No. 1s 4320Existing policies apply for amended s 69(2)(1)Board policies in force, or purporting to be in force, immediately before the commencement of this section for the purpose of section 24 of the regulation continue in force for the purpose of section 69(2) of the Act as amended by the Queensland Building Services Authority and Other Legislation Amendment Act 2003.(2)Subsection (1) does not prevent the board amending or repealing the policies.sch 1 s 20 ins 2003 No. 1s 43Division 5Non-trading licencessch 1 pt 5 div 5 hdg ins 2003 No. 1s 4323Definition for div 5In this division—non-trading licence means an instrument purporting to be a contractor’s licence issued or renewed by the authority, in the period starting on 19 November 1999 and ending immediately before 27 August 2001, stating that it was a non-trading licence or containing an expression indicating that it was a non-trading licence.Example of contractor’s licence containing an expression indicating the licence was a non-trading licence—a contractor’s licence containing the expression ‘NTL’sch 1 s 23 ins 2003 No. 1s 4324Non-trading licence taken to be valid(1)A non-trading licence is taken to have been and to be a valid contractors licence subject to a valid condition under section 35 or 36 of the Act that the licensee must not carry out, undertake to carry out or supervise the carrying out of building work.(2)If the authority removed or removes the statement or expression on the licence stating or indicating that it was a non-trading licence, the authority is taken to have validly revoked the condition.sch 1 s 24 ins 2003 No. 1s 43Division 6Courses of instruction for owner-builderssch 1 pt 5 div 6 hdg ins 2003 No. 1s 4325Validation of provision about courses of instruction for owner-builders(1)This section applies to section 13(4) and (5) of the regulation as in force, or purporting to be in force, before the commencement of this section.(2)Section 13(4) and (5) are taken to have been, and to be, valid at all times including for the purpose of specifying a course of instruction under section 44(3) of the Act.(3)Without limiting subsection (2), the board is taken to have had the power to make the policies mentioned in section 13(4) and (5) of the regulation.sch 1 s 25 ins 2003 No. 1s 43Division 7Board’s policiessch 1 pt 5 div 7 hdg ins 2003 No. 1s 4326Certain board’s policies continue in force(1)The board’s policies that are general policies in force under the Act before amendment—
(a)continue in force as board’s policies under the Act after amendment; and
(b)may be reviewed by the board and amended or repealed as if they were made under section 9A of the Act after amendment.
(2)The board’s policies that are supervision policies continue in force only until the commencement of section 17 of the amendment Act.(3)In this section—Act after amendment means the Queensland Building Services Authority Act 1991 as in force immediately after the commencement of section 6 of the amendment Act.Act before amendment means the Queensland Building Services Authority Act 1991 as in force immediately before the commencement of section 6 of the amendment Act.amendment Act means the Queensland Building Services Authority and Other Legislation Amendment Act 2003.sch 1 s 26 ins 2003 No. 1s 43Part 6Transitional provisions for the Building and Construction Industry Payments Act 2004sch 1 pt 6 hdg ins 2004 No. 6s 113sch 127Definitions for pt 6In this part—commencement means the commencement of this part.former provisions means sections 67H, 67I, 67J, 67Q, 67U and 67W, as in force before the commencement.sch 1 s 27 ins 2004 No. 6s 113sch 128Application of former provisions to existing building contractsThe former provisions continue to apply to building contracts entered into before the commencement as if the Building and Construction Industry Payments Act 2004, schedule 1 had not commenced.sch 1 s 28 ins 2004 No. 6s 113sch 1Part 7Transitional provisions for Statutory Bodies Legislation Amendment Act 2007sch 1 pt 7 hdg ins 2007 No. 20s 5829Rights and entitlements of particular employees(1)This section applies to a person who—
(a)becomes an employee of the employing office; and
(b)was an employee of the authority—
(i)immediately before the commencement of this section; and
(ii)immediately before becoming an employee of the employing office.
(2)On becoming an employee of the employing office, the person is taken to be employed under section 29F of the Act on the conditions on which the person would have been employed by the authority, immediately before the person became an employee of the employing office, if the authority had never become an employer under the Workplace Relations Act 1996 (Cwlth).(3)Also—
(a)the person keeps all rights and entitlements, including entitlements to receive long service, recreation and sick leave and any similar entitlements, that—
(i)have accrued or were accruing to the person as an employee of the authority; and
(ii)would have accrued to the person if the authority had never become an employer under the Workplace Relations Act 1996 (Cwlth); and
(b)if the person is a member of a superannuation scheme—
(i)the person keeps all entitlements accrued or accruing to the person as a member of the scheme; and
(ii)the person’s membership of the scheme is not affected.
(4)Without limiting subsection (3), for working out the person’s rights and entitlements, including entitlements to receive long service, recreation and sick leave and any similar entitlements, employment of the person by the employing office is a continuation of employment of the person by the authority.(5)If the person was a seconded employee immediately before becoming an employee of the employing office, the arrangement under which the person was performing work for a government entity other than the authority may continue until the arrangement ends, and, if the arrangement does continue—
(a)subsection (2) does not apply to the person; and
(b)on the ending of the arrangement, the person is taken to be employed under section 29F of the Act on the conditions on which the person would have been employed by the authority, on the ending of the arrangement, if—
(i)the person had continued to be an employee of the authority; and
(ii)the authority had never become an employer under the Workplace Relations Act 1996 (Cwlth).
(6)Subsections (2) and (5)(b) do not limit section 29F(3) and (4) of the Act.(7)In this section—authority means the former Queensland Building Services Authority established under the Queensland Building Services Authority Act 1991, section 5.employee of the authority includes a seconded employee.seconded employee means an employee of the authority performing work for another government entity under an arrangement entered into, before the commencement of this section, by the authority with the appropriate authority of the other government entity.sch 1 s 29 ins 2007 No. 20s 58amd 2013 No. 38s 14sch 130Application of industrial instrumentsThe employing office is taken to be bound by the industrial instruments that bound the authority immediately before it became an employer under the Workplace Relations Act 1996 (Cwlth).sch 1 s 30 ins 2007 No. 20s 58Part 8Transitional provisions for Queensland Building Services Authority and Other Legislation Amendment Act 2007sch 1 pt 8 hdg ins 2007 No. 47s 8131Transitional provisions for existing supervisors’ licences(1)This section applies to a licensee who at the commencement of this section holds a supervisor’s licence.(2)The licensee is taken to hold a nominee supervisor’s licence for the classes of building work to which the supervisor’s licence applies.(3)In this section—supervisor’s licence means a licence authorising the licensee to supervise (but not to carry out) building work.sch 1 s 31 ins 2007 No. 47s 8132Transitional qualifications for site supervisors’ licences(1)This section applies if a person who does not have the required qualifications applies for a site supervisor’s licence during the transitional period.(2)The authority may grant the application even though the applicant does not have the required qualifications for the licence if —
(a)the authority has sighted a declaration by a licensed contractor stating that—
(i)the applicant has carried out building work as an officer or employee of the contractor for a period of not less than 12 months; and
(ii)the contractor has had an opportunity to assess the skills of the applicant during the period; and
(iii)the contractor is satisfied that the applicant has the skills to carry out the duties of a site supervisor for a licence of the class applied for; and
(b)the authority is satisfied that the applicant has the skills to be a site supervisor for that class.
(3)If the licensed contractor is a company, the declaration must be by the company’s nominee.(4)Nothing in this section limits the powers the authority may exercise under section 33(2) or (3).(5)In this section—required qualifications means the qualifications required for a site supervisor’s licence under section 32AA.transitional period means the period of 1 year from the commencement of section 30B.sch 1 s 32 ins 2007 No. 47s 8133Transitional provision for fire protection occupational licencesSections 42C and 42D do not apply to anything happening before 2 years from the commencement of section 30C.sch 1 s 33 ins 2007 No. 47s 8134Transitional provision for certain fire protection workSection 42 does not apply to the following building work until 2 years after the commencement of this section—
(a)the design of a fire protection system;
(b)the development, approval or certification of emergency evacuation procedures for a controlled evacuation during a fire emergency;
(c)the formulation or provision of alternative solutions relating to fire safety;
(d)the inspection or investigation of, and the provision of advice or a report about compliance with the Building Act 1975 or the Building Code of Australia relating to fire safety.
sch 1 s 34 ins 2007 No. 47s 8136Transitional provision for continuation of register of licensees(1)The register of licensees under section 39, as in force immediately before the commencement of section 99, continues as the licensee register under section 99.(2)The authority may continue to exercise its powers under part 8 in relation to the licensee register.sch 1 s 36 ins 2007 No. 47s 81Part 9Transitional provisions for Queensland Building Services Authority Amendment Act 2013sch 1 pt 9 hdg ins 2013 No. 38s 10Division 1Preliminarysch 1 pt 9 div 1 hdg ins 2013 No. 38s 1037DefinitionsIn this part—amending Act means the Queensland Building Services Authority Amendment Act 2013.transfer day means the day the amending Act, section 5 commences.document includes a policy of the former board.former authority means the former Queensland Building Services Authority established under the QBSA Act.former board means the Queensland Building Services Board established under the QBSA Act.general manager means the person holding the office under the QBSA Act immediately before the transfer day.QBSA Act means this Act as in force immediately before its amendment under the amending Act, section 5.sch 1 s 37 ins 2013 No. 38s 10Division 2Dissolutionssch 1 pt 9 div 2 hdg ins 2013 No. 38s 1038DissolutionsOn the transfer day the following end or cease to exist—
(a)the former authority;
(b)the former board;
(c)the appointment of the members of the former board;
(d)office of the general manager;
(e)the general manager’s employment.
sch 1 s 38 ins 2013 No. 38s 1039No compensation because of dissolutions(1)No amount, whether by way of compensation, reimbursement or otherwise, is payable by the State or the commission to any person for or in connection with the enactment of section 38.(2)However, to avoid any doubt, subsection (1) does not limit or otherwise affect the general manager’s right to a benefit or entitlement that, under the existing conditions of appointment, had accrued or was accruing immediately before the transfer day.(3)On the transfer day, a benefit or entitlement mentioned in subsection (2) ceases to accrue and becomes payable as if—
(a)the general manager’s appointment had, according to its conditions, been terminated on the transfer day; and
(b)the termination is other than by the general manager.
(4)In this section—existing conditions of appointment, for the general manager, means the general manager’s conditions of appointment as determined by the Minister under the QBSA Act, section 17.sch 1 s 39 ins 2013 No. 38s 10Division 3Migration of matters to the commissionsch 1 pt 9 div 3 hdg ins 2013 No. 38s 1040Agreements, assets, liabilities and rights(1)On the transfer day—
(a)the former authority’s assets, liabilities and rights vest in the commission; and
(b)the commission is substituted for the former authority in all agreements to which the former authority is a party.
(2)In this section—agreement includes leases, undertakings and contractual arrangements.sch 1 s 40 ins 2013 No. 38s 1041Unresolved applications(1)On the transfer day, the commission stands in place of the former authority for any unresolved application made—
(a)under the QBSA Act to the former authority; or
(b)by the former authority to the tribunal.
(2)For subsection (1)(a), the commission may be satisfied about a matter merely because the former authority was satisfied about the matter under the relevant provision of the QBSA Act.(3)In this section—unresolved application means an application made, but not finally decided or withdrawn, before the transfer day.sch 1 s 41 ins 2013 No. 38s 1042Pending legal proceedings(1)If, immediately before the transfer day, the former authority was a party to a legal proceeding, the commission is substituted for the former authority as the party.(2)For section 111(1), the commission is taken to have knowledge of the commission of a past offence—
(a)if the offence came to the former authority’s knowledge; and
(b)when the offence came to the former authority’s knowledge.
Note—See section 45(6) for the continued authorisation of particular persons to bring prosecutions for offences against this Act.(3)In this section—legal proceeding means a proceeding before a court or tribunal.past offence means an offence against this Act for which—
(a)the alleged date of commission of the offence was before the transfer day; and
(b)the prosecution for the offence had not yet started on the transfer day.
sch 1 s 42 ins 2013 No. 38s 1043Ministerial directions to former authority(1)A pending Ministerial direction to the former authority applies, if the context permits, to the commission as it would have applied to the former authority.(2)In this section—pending Ministerial direction means a direction by the Minister under section 7 of the QBSA Act and in effect immediately before the transfer day.sch 1 s 43 ins 2013 No. 38s 1044Records of the former authority(1)On the transfer day, a record of the former board becomes a record of the commission.(2)In this section—record includes a register kept by the former authority under the QBSA Act.sch 1 s 44 ins 2013 No. 38s 1046Annual report of former board(1)This section applies unless the transfer day is 1 July in a year.(2)The commission’s annual report for the financial year in which the commission is established must include information about the former authority’s operations that would have been required to be included in the commission’s annual report if the QBSA Act had not been amended by the amending Act.(3)In this section—annual report means annual report under the Financial Accountability Act 2009.sch 1 s 46 ins 2013 No. 38s 1047Other administrative matters(1)From the transfer day, each of the following things in effect immediately before the transfer day continue in effect as if the thing was approved, given or made by the commission when the thing first took effect—
(a)a direction or notice given by the former authority under the QBSA Act;Example—a direction to a licensee to rectify or complete tribunal work
(b)a demand, request or requirement made by the former authority under the QBSA Act that has not been fully complied with on the transfer day;Examples—
1a demand of a licensee to pay an amount owed to the former authority
2a request of an applicant to provide the former authority with further information or evidence to decide an application
(c)a certificate, licence or permit issued by the former authority under the QBSA Act;
(d)a decision of the former authority made under the QBSA Act.
(2)A policy of the former board, approved under section 9A of the QBSA Act and still in effect immediately before the transfer day, continues in effect as if the policy was made by the board.(3)For a provision of this Act enabling the taking of action by an entity if the commission had previously taken a particular action, a reference to the commission having previously taken the action is taken to include a reference to the former authority having previously taken it.sch 1 s 47 ins 2013 No. 38s 10Division 4Other matterssch 1 pt 9 div 4 hdg ins 2013 No. 38s 1048References to former entitiesIn an Act or document—
(a)a reference to the former authority may, if the context permits, be taken to be a reference to the commission; and
(b)a reference to the former board may, if the context permits, be taken to be a reference to the board; and
(c)a reference to the general manager under the QBSA Act may, if the context permits, be taken to be a reference to the commissioner.
sch 1 s 48 ins 2013 No. 38s 1049References to QBSA ActIn an Act or document, a reference to the QBSA Act may, if the context permits, be taken as a reference to this Act as in force after the transfer day.sch 1 s 49 ins 2013 No. 38s 1050Change to name of employing officeA change in the name of the employing office under the amending Act does not affect the status of that office.sch 1 s 50 ins 2013 No. 38s 1051Effect on legal relationships(1)Nothing done under the amendments to the QBSA Act under the amending Act (the Act amendments)—
(a)makes a relevant entity in breach of any instrument, including an instrument prohibiting, restricting or regulating the assignment, novation or transfer of a right or liability or the disclosure of information; or
(b)except as provided for under the Act amendments, is taken to fulfil a condition that—
(i)terminates, or allows a person to terminate, an instrument or obligation; or
(ii)modifies, or allows a person to modify, the operation or effect of an instrument or obligation; or
(iii)allows a person to avoid or enforce an obligation or liability contained in an instrument or requires a person to perform an obligation contained in an instrument; or
(iv)requires any money to be paid before its stated maturity; or
(c)releases a surety or other obligee, wholly or partly, from an obligation.
(2)If, apart from this subsection, the advice, consent or approval of a person would be necessary to do something under the Act amendments, the advice is taken to have been obtained or the consent or approval is taken to have been given unconditionally.(3)If, apart from this Act, giving notice to a person would be necessary to do something under the Act amendments, the notice is taken to have been given.(4)In this section—relevant entity means—
(a)the State or an employee or agent of the State; or
(b)the commission, a member or a relevant officer of the commission.
sch 1 s 51 ins 2013 No. 38s 10Part 10Transitional provision for Residential Tenancies and Rooming Accommodation and Other Legislation Amendment Act 2013sch 1 pt 10 hdg ins 2013 No. 58s 3052Application of s 42 (Unlawful carrying out of building work)(1)Section 42(4) applies to building work carried out on or after 1 July 1992, unless the entitlement to payment for the carrying out of the building work was—
(a)before the commencement of this section, decided by—
(i)a court; or
(ii)the tribunal; or
(iii)an arbitrator or another entity authorised to make a binding decision about the entitlement; or
(b)before 2 March 1999, the subject of—
(i)a claim or counterclaim filed in a court; or
(ii)an application made to the tribunal; or
(iii)a reference to an arbitrator or another entity authorised to make a binding decision about the entitlement; or
(c)provided for as a term of a binding agreement entered into before the commencement of this subsection, but only if the binding agreement—
(i)is between—
(A)1 or more consumers and 1 or more building contractors; or
(B)1 or more building contractors and 1 or more other building contractors; and
(ii)was entered into to resolve a dispute between some or all of the parties to the binding agreement; and
(iii)is not the contract for the carrying out of the building work as originally entered into, or as originally entered into and as subsequently varied.
(2)In this section—tribunal means the former Queensland Building Tribunal previously established under this Act, part 7, before amendment of this Act under the repealed Queensland Building Tribunal Act 2000.sch 1 s 52 ins 2013 No. 58s 30Part 11Transitional provisions for the Queensland Building and Construction Commission and Other Legislation Amendment Act 2014sch 1 pt 11 hdg ins 2014 No. 57s 59Division 1Preliminarysch 1 pt 11 div 1 hdg ins 2014 No. 57s 5953Definitions for pt 11In this part—Amendment Act means the Queensland Building and Construction Commission and Other Legislation Amendment Act 2014.commencement means the commencement of the provision in which the term is used.former, in relation to a provision, means the provision as in force immediately before the amendment of the provision under the Amendment Act.sch 1 s 53 ins 2014 No. 57s 59Division 2Generalsch 1 pt 11 div 2 hdg ins 2014 No. 57s 5954Continuation of particular reviews(1)This section applies if, before the commencement, a person could have applied to the commission or tribunal for a review of any of the following decisions under former part 7, division 3—
(a)a decision to direct or not to direct rectification or completion of tribunal work;
(b)a decision that tribunal work undertaken at the direction of the commission is or is not of a satisfactory standard;
(c)a decision not to categorise an individual as a permitted individual for a relevant event.
(2)If the person had not applied before the commencement, the person may make the application in compliance with the requirements of former part 7, division 3 and the commission or tribunal may review the decision.(3)If the person had applied before the commencement, the commission or tribunal may start, continue and decide the review of the decision.(4)For the purpose of starting, continuing or deciding a review to which this section applies, this Act, as in force immediately before the commencement, has effect as if this Act had not been amended by the Amendment Act.(5)A decision of the commission or tribunal made after reviewing a decision under subsection (2) or (3) has effect despite the amendment of this Act by the Amendment Act.(6)A decision of the commission made after reviewing a decision under subsection (2) or (3) is taken to be a reviewable decision for part 7, division 3, subdivision 2 and a person affected by the decision may apply to the tribunal under section 87 for a review of the decision.sch 1 s 54 ins 2014 No. 57s 5955Existing disciplinary proceedings(1)This section applies if—
(a)the commission had applied to the tribunal under former section 88 to conduct a proceeding to decide whether proper grounds exist for taking disciplinary action against a person before the commencement; and
(b)the tribunal had not started or completed the disciplinary proceeding before the commencement.
(2)The tribunal may start, continue and complete the disciplinary proceeding as if former part 7, division 4 had not been repealed by the Amendment Act.sch 1 s 55 ins 2014 No. 57s 5956Allocation of demerit points(1)This section applies if, before the commencement of this section, the commission—
(a)had an obligation to allocate demerit points to a person under former part 3E; but
(b)had not allocated the demerit points.
(2)The commission must allocate the demerit points to the person, as required under former part 3E, despite—
(a)any amendment of this Act under the Amendment Act; or
(b)the repeal of the Domestic Building Contracts Act 2000.
sch 1 s 56 ins 2014 No. 57s 5957Categorisation as excluded individual or permanently excluded individual continues(1)An individual who, immediately before the commencement, was an excluded individual for a relevant bankruptcy or company event under former section 56AC continues to be an excluded individual for the relevant bankruptcy or company event under former section 56AC as if that section had not been amended by the Amendment Act.Note—The individual would continue under former section 56AC to be an excluded individual until 5 years had elapsed from the day the relevant bankruptcy or company event happened.(2)An individual who, immediately before the commencement, was a permanently excluded individual under former section 58 continues to be a permanently excluded individual despite any amendment of parts 3A or 3B under the Amendment Act.(3)However, section 61 continues to apply to the person.sch 1 s 57 ins 2014 No. 57s 5958Becoming a permitted individual after the commencement(1)Subsection (2) applies if—
(a)the commission gave an individual a written notice under former section 56AF(2) before the commencement; and
(b)at the commencement, 28 days have not elapsed from the day the commission gave the person the notice mentioned in paragraph (a).
(2)The person may apply to the commission, and the commission may consider and decide the application, under former section 56AD, as if that section had not been repealed under the Amendment Act.(3)Subsection (4) applies if, before the commencement, an individual applied to the commission under former section 56AD and the commission had not finally dealt with the application.(4)The commission may continue to consider and decide the application, under former section 56AD, as if that section had not been repealed under the Amendment Act.(5)To remove any doubt it is declared that the commission may categorise the person as a permitted individual despite the repeal of former section 56AD by the Amendment Act.sch 1 s 58 ins 2014 No. 57s 5959Categorisation as permitted individual continues(1)A permitted individual for a relevant event continues to be taken not to be an excluded individual for the relevant event.(2)The relevant event must not be counted in deciding, under section 61, whether the individual is or continues to be a permanently excluded individual.(3)In this section—permitted individual means—
(a)an individual categorised as a permitted individual for a relevant event under former section 56AD if—
(i)the person continued to be categorised as a permitted individual immediately before the commencement; or
(ii)the person is categorised as a permitted individual after the commencement because of schedule 1, section 58; or
(b)an individual categorised as a permitted individual for a relevant event as result of the tribunal reversing the commission’s decision not to categorise the individual as a permitted individual for the relevant event after a review of the decision by the tribunal.
sch 1 s 59 ins 2014 No. 57s 59Division 3Rectification of building worksch 1 pt 11 div 3 hdg ins 2014 No. 57s 5960Outstanding applications for rectification of building work that is defective or incomplete(1)This section applies if, before the commencement—
(a)a consumer applied to the commission under former section 71A for a direction to rectify building work that was defective or incomplete; and
(b)the commission had not finally dealt with the application.
(2)The commission may deal with the application under former section 71A despite the repeal of that section by the Amendment Act.(3)Former section 72 continues to apply for the purpose of subsection (2) as if that section had not been repealed by the Amendment Act.sch 1 s 60 ins 2014 No. 57s 59Division 4Repeal of the Domestic Building Contracts Act 2000sch 1 pt 11 div 4 hdg ins 2014 No. 57s 5963Continued reference to conduct under the repealed Domestic Building Contracts Act 2000(1)The repeal of the Domestic Building Contracts Act 2000 (the repealed Act) does not—
(a)cause or require—
(i)the licensee register kept under section 99 to be amended to remove notes relating to the repealed Act; or
(ii)the cancellation of any demerit points relating to the repealed Act; and
(b)prevent the consideration of—
(i)any past contravention of a requirement imposed under the repealed Act; or
(ii)any conviction of an offence against the repealed Act; or
(iii)a person having been served with an infringement notice relating to the repealed Act.
(2)For the purpose of subsection (1)(b), a provision of this Act that includes a reference to a provision of schedule 1B is taken to include a reference to the equivalent provision of the repealed Act.sch 1 s 63 ins 2014 No. 57s 5964Past contraventions of repealed Act(1)This section applies if a person is alleged to have committed an offence against the repealed Domestic Building Contracts Act 2000 (the repealed Act) before its repeal.(2)Proceedings for the offence may be started, continued or completed, and the Court may hear and decide the proceedings, as if the repealed Act had not been repealed.(3)This section applies despite the Criminal Code, section 11.sch 1 s 64 ins 2014 No. 57s 59Division 5Statutory insurance schemesch 1 pt 11 div 5 hdg ins 2014 No. 57s 5965Continuation and finalisation of matters under former part 5(1)This section applies if, before the commencement, a right, privilege or liability was acquired, accrued or incurred by the commission or a person under former part 5 and—
(a)the right or privilege had not been exhausted; or
(b)the liability had not been released.
(2)The right, privilege or liability may be exercised or enforced under former part 5 despite the replacement of that part by the Amendment Act.(3)To remove any doubt, it is declared that—
(a)a person continues to be liable for any contravention of a provision of former part 5 that happened before the commencement; or
(b)a person who, before the commencement, was liable to pay an insurance premium under former part 5 continues to be liable to pay the premium; or
(c)a liability of the commission to issue a certificate of insurance under former part 5 that had not been issued before the commencement must be issued in compliance with former section 69(1); or
(e)a proceeding to recover an amount under former section 71 may be started, continued or completed and any defence available to a person under that section may be relied upon.
(4)In this section—liability includes an obligation of the commission or a person to take particular action under former part 5.sch 1 s 65 ins 2014 No. 57s 5966Existing policies of insurance(1)A policy of insurance that came into force under former part 5 continues in force on the terms stated in the board’s policies for that purpose.(2)Despite the replacement of part 5 by the Amendment Act, former part 5 continues to apply to a contract for residential construction work if the contract was entered into before the replacement day.(3)To remove any doubt, it is declared that subsection (2)—
(a)applies to a contract even if an insurance premium is paid in relation to the contract on or after the replacement day; and
(b)does not prevent the consumer for the contract from obtaining optional additional cover under section 67Z.
(4)The board’s policies that are relevant for this section continue for that purpose despite the replacement of part 5 by the Amendment Act or the repeal of the policies under schedule 1, section 67.(5)In this section—board’s policies means the policies of the board made for the purposes of section 19 and relating to the statutory insurance scheme.replacement day means the day former part 5 was replaced under the Amendment Act.sch 1 s 66 ins 2014 No. 57s 5967Repeal of board’s policies about statutory insurance schemeOn the commencement all policies of the board made, for the purposes of section 19, about the terms of cover under the statutory insurance scheme are repealed.sch 1 s 67 ins 2014 No. 57s 59Division 6sch 1 pt 11 div 6 hdg ins 2014 No. 57s 59exp 15 December 2015 (see s 68(4))68sch 1 s 68 ins 2014 No. 57s 59exp 15 December 2015 (see s 68(4))Part 12Transitional provision for the Plumbing and Drainage and Other Legislation Amendment Act 2016sch 1 pt 12 hdg ins 2016 No. 11s 2269Internal review applications of relevant decisions(1)This section applies if, before the commencement—
(a)an internal review application for a relevant decision under the unamended Act had been made but not decided or otherwise finally dealt with; or
(b)the period under the unamended Act in which a person was entitled to apply to have a relevant decision reviewed had started but not ended.
(2)An internal review may be completed, or started and completed, as if the unamended Act continued to apply.(3)Part 7, division 3, subdivision 2 applies to a person affected by a decision made under subsection (2) as if the decision under subsection (2) were a reviewable decision under section 87.(4)In this section—internal review means a proceeding for review under part 7, division 3, subdivision 1.relevant decision means a decision under the Plumbing and Drainage Act 2002, section 68.unamended Act means this Act as in force immediately before the commencement.sch 1 s 69 ins 2016 No. 11s 22Part 14Transitional provisions for Building and Construction Legislation (Non-conforming Building Products—Chain of Responsibility and Other Matters) Amendment Act 2017sch 1 pt 14 hdg ins 2017 No. 29s 3071Information-sharingSections 28A and 28B apply in relation to information obtained by the commission before or after the commencement.sch 1 s 71 ins 2017 No. 29s 3072Grounds for suspending or cancelling licence or disciplinary action(1)A new ground under section 48 or 74B applies only in relation to an act or omission that happens after the commencement.(2)In this section—new ground means—
(a)for section 48—a ground for suspending or cancelling a licence under the section that was not a ground for cancelling or suspending a licence under the section immediately before the commencement; or
(b)for section 74B—a ground for taking disciplinary action under the section that was not a ground for taking disciplinary action under the section immediately before the commencement.
sch 1 s 72 ins 2017 No. 29s 3073Recall orders and warning statements(1)The Minister may make a recall order under part 6AA, division 4, or publish a warning statement under part 6AA, division 5, for a building product in existence on the commencement.(2)Subsection (1) applies even if the building product was associated with a building or other structure before the commencement.sch 1 s 73 ins 2017 No. 29s 3074Current investigations(1)This Act as in force after the commencement applies to an investigation under this Act started but not finished before the commencement.(2)Without limiting subsection (1)—
(a)the commission may—
(i)give a direction under section 74AN during or after conducting an investigation under part 6A; and
(ii)use information mentioned in section 74A(3) for the investigation, including information obtained before the commencement; and
(b)an inspector may exercise powers under part 9 for the investigation.
sch 1 s 74 ins 2017 No. 29s 3075Stop orders(1)This Act as in force before the commencement continues to apply to the following as if the amendment Act had not been enacted—
(a)a stop order in force immediately before the commencement;
(b)a proceeding before the tribunal to allow a person to show cause why a stop order should not be confirmed that was started, but not finished, before the commencement;
(c)the outcome of a proceeding mentioned in paragraph (b).
(2)In this section—amendment Act means the Building and Construction Legislation (Non-conforming Building Products—Chain of Responsibility and Other Matters) Amendment Act 2017.stop order means an order of the tribunal under section 97B as in force before the commencement.sch 1 s 75 ins 2017 No. 29s 30Part 15Transitional provisions for Building Industry Fairness (Security of Payment) Act 2017sch 1 pt 15 hdg ins 2017 No. 43s 30576Board’s policy(1)A policy, made by the board under repealed section 19 and approved by regulation, in force immediately before the commencement continues in force—
(a)despite the repeal of section 19; and
(b)until the matters provided for under the policy are prescribed by regulation.
Note—The policies in force were the Rectification of Building Work made by the board on 16 May 2014 and the Minimum Financial Requirements made by the board on 28 August 2015.(2)A regulation may declare the day a policy mentioned in subsection (1) expires under that subsection.sch 1 s 76 ins 2017 No. 43s 30577AValidation of particular continued appointments(1)An existing appointment of a person continued as mentioned in section 77 is taken to have been continued as mentioned in that section from the commencement of the section as originally enacted.Note—Section 77 as originally enacted commenced on 10 November 2017.(2)Anything done between 10 November 2017 and the commencement of this section by a person as the holder of the appointment is taken to have been validly done by the person as if the appointment had been continued as mentioned in section 77 as in force after the commencement.(3)Nothing in this section continues the appointment of a person beyond the end of that appointment under section 104D.sch 1 s 77A ins 2018 No. 17s 193GPart 16Transitional provision for Plumbing and Drainage Act 2018sch 1 pt 16 hdg ins 2018 No. 17s 19478Continuing classes of licences that automatically transition to new licence class(1)Subsection (2) applies to a licensee who immediately before the commencement held a contractor’s licence for refrigeration, airconditioning and mechanical services including unlimited design licence.(2)The licensee is taken to be a licensee for a mechanical services—air-conditioning and refrigeration (unlimited design), subject to any conditions applying to the licence.(3)Subsection (4) applies to a licensee who immediately before the commencement held a contractor’s licence for refrigeration, airconditioning and mechanical services including limited design licence.(4)The licensee is taken to be a licensee for a mechanical services—air-conditioning and refrigeration (limited design), subject to any conditions applying to the licence.sch 1 s 78 ins 2018 No. 17s 194Part 17Transitional and validation provisions for Building Industry Fairness (Security of Payment) and Other Legislation Amendment Act 2020sch 1 pt 17 hdg ins 2020 No. 24s 12579Validation of relevant landscaping work(1)This section applies in relation to relevant landscaping work carried out before the commencement of the Queensland Building and Construction Commission (Structural Landscaping Licences) Amendment Regulation 2019 by the holder of a licence of either of the following classes—
(a)a builder restricted to structural landscaping licence;
(b)a structural landscaping (trade) licence.
(2)The holder is taken to have held a licence of the appropriate class for carrying out the relevant landscaping work.(3)In this section—relevant landscaping work means work mentioned in the following provisions of the Queensland Building and Construction Commission Regulation 2018—
(a)schedule 2, part 10, section 2(7);
(b)schedule 2, part 54, section 2(5).
sch 1 s 79 ins 2020 No. 24s 12579AValidation of work—installation of fire collars(1)This section applies in relation to work that is the installation of a fire collar—
(a)that was carried out by the holder of a relevant licence before the relevant commencement; and
(b)to the extent the work would, if it were carried out by the holder on the relevant commencement, have been authorised for the holder’s licence under an amended provision.
(2)The holder is taken to have held a licence of the appropriate class for carrying out the work.(3)In this section—amended provisions means the following provisions of the Queensland Building and Construction Commission Regulation 2018, schedule 2, as in force on the relevant commencement—
(a)part 18, section 2(2);
(b)part 25, section 2(3)(b);
(c)part 26, section 2(7);
(d)part 30, section 2(2)(b);
(e)part 36, section 2(2);
(f)part 47, section 2(2);
(g)part 48, section 2(2).
relevant commencement means the commencement of the Queensland Building and Construction Commission and Other Legislation Amendment Regulation 2019, section 12.Note—The date of the relevant commencement is 13 December 2019.relevant licence means a licence of any of the following classes—
(a)plumbing and drainage;
(b)the licence class of install and maintain for a special hazard suppression systems licence;
(c)the following licence classes for a sprinkler and suppression systems (reticulated water-based) licence—
(i)install and maintain;
(ii)install and maintain—restricted to commercial or industrial type;
(iii)install and maintain—restricted to domestic or residential type;
(d)the licence class of install and maintain—extra low voltage for a fire detection, alarm and warning systems licence;
(e)gasfitting;
(f)refrigeration, air conditioning and mechanical services including unlimited design;
(g)refrigeration, air conditioning and mechanical services including limited design.
sch 1 s 79A ins 2020 No. 24s 12580Matters relating to interstate or New Zealand licences(1)For deciding whether a person is a fit and proper person or whether to suspend or cancel a licence, sections 31, 32, 32AA(2) and 48(2) apply in relation to the suspension or cancellation of an interstate or New Zealand licence only if the suspension or cancellation happens after the commencement.(2)The commission may give a notice under section 28C for an event mentioned in section 28C(1) only if the event happens after the commencement.sch 1 s 80 ins 2020 No. 24s 12581Accountants excluded under minimum financial requirements before commencement(1)This section applies if, before the commencement, the commission decided not to approve a person as a qualified accountant for the Queensland Building and Construction Commission (Minimum Financial Requirements) Regulation 2018, section 11D.(2)As soon as practicable after the commencement, the commission must give the person an exclusion notice for the decision.(3)The exclusion notice is taken to have been given to the person on the day the person was given notice of the decision mentioned in subsection (1) that the person was not approved as a qualified accountant.sch 1 s 81 ins 2020 No. 24s 12582Transitional regulation-making power(1)A regulation (a transitional regulation) may make provision about a matter for which—
(a)it is necessary to make provision to allow or facilitate the doing of anything to achieve the transition from the operation of this Act as in force immediately before the commencement to the operation of the amended Act; and
(b)this Act does not make provision or sufficient provision.
(2)A transitional regulation may have retrospective operation to a day not earlier than the day of commencement.(3)A transitional regulation must declare it is a transitional regulation.(4)This section and any transitional regulation expire 2 years after the day of commencement.(5)In this section—amended Act means this Act as amended by the Building Industry Fairness (Security of Payment) and Other Legislation Amendment Act 2020.sch 1 s 82 ins 2020 No. 24s 125exp 1 October 2022 (see s 82(4))83Application of pts 3A, 3B, 3C and 3E(1)Parts 3A, 3B, 3C and 3E apply to a site supervisor only in relation to a relevant event that happens after the commencement.(2)Part 3A, division 4 applies in relation to an individual, other than a site supervisor, who is an excluded individual for a relevant event, whether the event happened before or after the commencement.(3)Part 3B, division 3 applies in relation to an individual, other than a site supervisor, who is a permanently excluded individual, even if the individual became a permanently excluded individual before the commencement.sch 1 s 83 ins 2020 No. 24s 14884Continued application of pre-amended limitation periodSection 111, as in force from time to time before the commencement, continues to apply in relation to an offence committed before the commencement.sch 1 s 84 ins 2020 No. 24s 148Part 18Transitional and validation provisions for Justice and Other Legislation Amendment Act 2021sch 1 pt 18 hdg ins 2021 No. 23s 56C85Definition for partIn this part—validation period means the period—
(a)starting at the beginning of the day on 11 November 2019; and
(b)ending at the end of the day on 9 November 2021.Notes—
1The Building Industry Fairness (Security of Payment) Act 2017, section 281 commenced on 11 November 2019.
2The Queensland Building and Construction Commission (Rectification of Building Work) Amendment Regulation 2021 commenced on 10 November 2021.
sch1 s 85 ins 2021 No. 23s 56C86Application of amended section 72Section 72, as amended by the Justice and Other Legislation Amendment Act 2021, is taken to have applied from the start of the validation period.sch 1 s 86 ins 2021 No. 23s 56C87Validation of particular directions to rectify or remedy(1)This section applies in relation to a direction made, or purportedly made, under section 72(2) during the validation period.(2)It is declared that the direction is, and always has been, as valid as it would have been if the 35-day period had been prescribed by regulation under section 72(4) throughout the validation period.(3)Also, subsection (4) applies if the period stated in the direction for rectifying building work or remedying consequential damage ended on a day that was—
(a)between 28 and 34 days after the day the direction was made, as stated in the direction; or
(b)later than 35 days after the day the direction was made, as stated in the direction.
(4)It is declared that the direction is, and always has been, as valid as it would have been if the period stated in the direction had complied with the 35-day period.(5)Without limiting subsection (2) or (4), any action, or purported action, taken in reliance on the direction is taken to be as lawful and valid as it would have been if the matters mentioned in the subsection had effect.Example of action, or purported action, taken in reliance on the direction—the grant, under section 72B, of an extension of the period for compliance with the direction(6)This section does not limit the operation of section 76 of this schedule in relation to matters provided for under a policy mentioned in that section.(7)In this section—35-day period means the period prescribed under section 72(4) by the Queensland Building and Construction Commission Regulation 2018, section 53A.Note—Section 53A was inserted by the Queensland Building and Construction Commission (Rectification of Building Work) Amendment Regulation 2021.sch 1 s 87 ins 2021 No. 23s 56C88Extension of time for giving directions(1)This section applies if, during the suspension period—
(a)the limitation period for giving a direction to rectify or remedy building work ended; and
(b)the commission did not give the direction.
(2)Despite section 72A(4), the limitation period for giving the direction is taken to end on the day that is 7 days after the commencement.(3)In this section—limitation period, for giving a direction to rectify or remedy building work, means the period, mentioned in section 72A(4), of 6 years and 6 months after the building work to which the direction relates.suspension period means the period—
(a)starting at the beginning of the day on 3 November 2021; and
(b)ending at the end of the day on 9 November 2021.
sch 1 s 88 ins 2021 No. 23s 56CSchedule 1AExemptions from requirement to hold contractor’s licencesection 42~~(2)~~(1)1EmployeesAn unlicensed person who carries out, in the course of employment, building work (other than fire protection work or mechanical services work) for which the person’s employer holds a licence of the appropriate class under this Act does not contravene section 42(1).sch 1A s 1 ins 2013 No. 58s 31amd 2018 No. 17s 195(1)2Subcontractors(1)An unlicensed person who, as a subcontractor, carries out, or undertakes to carry out, building work (other than fire protection work or mechanical services work) for a licensed trade contractor, does not contravene section 42(1) if the work is within the scope of the building work allowed by the class of licence held by the contractor.(2)In this section—licensed trade contractor means a licensed contractor other than the following—
(a)a licensed builder;
(b)a licensed contractor who holds a contractor’s licence authorising the licensee to carry out completed building inspections.
sch 1A s 2 ins 2013 No. 58s 31amd 2018 No. 17s 195(2)3PartnershipsAn unlicensed person who carries out, or undertakes to carry out, building work (other than fire protection work or mechanical services work) in partnership with another person who is licensed to carry out building work of the relevant class does not contravene section 42(1).Note—Section 56 states that a licensed contractor may carry on business under the contractor’s licence in partnership with an unlicensed person subject to the conditions stated in the section.sch 1A s 3 ins 2013 No. 58s 31amd 2018 No. 17s 195(3)4Owner-buildersAn unlicensed person who holds an owner-builder permit does not contravene section 42(1) by carrying out building work permitted under the permit.sch 1A s 4 ins 2013 No. 58s 315Design work by landscape architectsAn unlicensed person who carries out, or undertakes to carry out, design work does not contravene section 42(1) if—
(a)the person carries on business as a landscape architect; and
(b)the person carries out the design work, or undertakes to carry it out, as part of the person’s work as a landscape architect; and
(c)the design work is of a type ordinarily carried out as an appropriate or necessary component of a landscape architect’s work.
sch 1A s 5 ins 2013 No. 58s 316ConsumersA consumer who engages 1 or more licensed contractors to carry out building work for the consumer does not contravene section 42(1) if the consumer does not provide building work services for the work.Examples of a consumer who does not provide building work services—
•a consumer who engages a licensed builder to build, and carry out all building work services for, a new residence
•a consumer who, as a principal, enters into construction management trade contracts for building work and engages a construction manager for building work services for the work
sch 1A s 6 ins 2013 No. 58s 317Other licencesA person who holds any of the following licences does not contravene section 42(1) only by doing something permitted under the licence—
(a)a nominee supervisor’s licence;
(b)a site supervisor’s licence;
(c)a fire protection occupational licence;
(d)a mechanical services occupational licence.
sch 1A s 7 ins 2013 No. 58s 31amd 2018 No. 17s 195(4)8Head contracts to carry out building work(1)An unlicensed person who enters into a contract to carry out building work does not contravene section 42(1) merely because the person entered into the contract if the building work—
(a)is not residential construction work or domestic building work; and
(b)is to be carried out by a person (an appropriately licensed contractor) who is licensed to carry out building work of the relevant class.
(2)Also, the unlicensed person does not contravene section 42(1) merely because the person—
(a)directly or indirectly causes the building work to be carried out by an appropriately licensed contractor; or
(b)enters into another contract, with an appropriately licensed contractor, to carry out the work.
(3)However, subsection (1) ceases to apply to the unlicensed person if the person causes or allows any of the building work to be carried out by a person who is not licensed to carry out building work of the relevant class.(4)Also, subsections (1) and (2) do not apply in circumstances prescribed by regulation.Editor’s note—Schedule 1A, s 8 has an uncommenced amendment—see 2020 Act No. 24s 125A. This amendment is omitted by the Building and Other Legislation Amendment Bill 2022, s 36 and has not been included in this indicative reprint.sch 1A s 8 ins 2013 No. 58s 319Tenders and offersAn unlicensed person who submits a tender to carry out building work or makes an offer to carry out building work does not contravene section 42(1) merely because the person submits the tender or makes the offer if the building work—
(a)is not residential construction work or domestic building work; and
(b)is to be carried out by a person who is licensed to carry out building work of the relevant class.
sch 1A s 9 ins 2013 No. 58s 3110Public-private partnerships(1)This section applies to a special purpose vehicle that undertakes to carry out building work under a public-private partnership.(2)The special purpose vehicle does not contravene section 42(1) merely because the vehicle undertakes to carry out the building work if the work is to be carried out by a person (an appropriately licensed contractor) who is licensed to carry out building work of the relevant class.(3)Also, the special purpose vehicle does not contravene section 42(1) merely because the special purpose vehicle—
(a)directly or indirectly causes the building work to be carried out by an appropriately licensed contractor; or
(b)enters into a contract, with an appropriately licensed contractor, to carry out the work.
(4)However, this section ceases to apply to the special purpose vehicle if the special purpose vehicle causes or allows any of the building work to be carried out by a person who is not licensed to carry out building work of the relevant class.sch 1A s 10 ins 2013 No. 58s 3111Prescribed government projects(1)This section applies to an unlicensed person who, by doing any of the following, undertakes to carry out building work for a prescribed government project—
(a)enters into a contract with a government entity to carry out building work for the project;
(b)submits a tender to a government entity to carry out building work for the project;
(c)makes an offer to a government entity to carry out building work for the project.
(2)The unlicensed person does not contravene section 42(1) merely because the person undertakes to carry out the building work if the work—
(a)is of a class prescribed, under a regulation, for the prescribed government project; and
(b)is to be carried out by a person (an appropriately licensed contractor) who is licensed to carry out building work of the relevant class.
(3)Also, the unlicensed person does not contravene section 42(1) merely because the person—
(a)directly or indirectly causes the building work to be carried out by an appropriately licensed contractor; or
(b)enters into a contract, with an appropriately licensed contractor, to carry out the work.
(4)However, this section ceases to apply to the unlicensed person if the person causes or allows any of the building work to be carried out by a person who is not licensed to carry out building work of the relevant class.(5)In this section—government entity means the State, the Commonwealth or a local government, or any of their authorities or agencies.prescribed government project means a project, prescribed under a regulation, involving building work to be carried out—
(a)for, or on behalf of, a government entity; and
(b)by 1 or more private sector entities.
sch 1A s 11 ins 2013 No. 58s 31sch 1A hdg ins 2013 No. 58s 31Schedule 1BDomestic building contractssection 67AZNPart 1Interpretationsch 1B pt 1 hdg ins 2014 No. 57s 601Definitions for sch 1BIn this schedule—building includes—
(a)a structure, including a temporary building and other temporary structure; and
(b)a part of a structure.
building contractor means a person who—
(a)carries out domestic building work; or
(b)manages the carrying out of domestic building work; or
(c)has carried out, or managed the carrying out of, domestic building work; or
(d)intends to carry out, or to manage the carrying out of, domestic building work.
building owner means the person for whom domestic building work has been, is being, or is to be, carried out.building site means a place where domestic building work has been, is being, or is to be, carried out.certificate of inspection, for a regulated contract, means a certificate that—
(a)is issued under an Act following an inspection of the subject work or a part of the subject work; and
(b)contains a certification to the effect that the subject work, or a stated stage of the subject work, has been satisfactorily completed.
consumer building guide means a statement prepared and published by the commission under schedule section 46(1).contracted services, for a domestic building contract, means the thing done, being done or to be done by the building contractor under the contract in relation to domestic building work, being either—
(a)the carrying out of the work; or
(b)the managing of the carrying out of the work.
contract price, for a domestic building contract, see schedule section 2.cost plus contract means a domestic building contract under which the amount the building contractor is to receive under the contract can not be accurately calculated when the contract is entered into, even if prime cost items and provisional sums are ignored.defects document, for a domestic building contract, means a document that—
(a)lists the minor defects and minor omissions in the subject work that the building contractor and building owner agree exist; and
(b)states when the building contractor is to remedy the minor defects and minor omissions mentioned in paragraph (a); and
(c)lists the minor defects and minor omissions that the building owner claims exist and the building contractor does not agree exist; and
(d)is signed by the building contractor.
detached dwelling means—
(a)a single detached dwelling; or
(b)a duplex.
development approval ...sch 1B def development approval om 2016 No. 27s 375domestic building contract see schedule section 3.domestic building work see schedule section 4.draftsperson means a person who holds a contractor’s licence authorising the person to prepare plans and specifications for domestic building work.excluded building work means any of the following work—
(a)work relating to any of the following buildings—
(i)a farm building, or proposed farm building, that is not a home;
(ii)a building intended to be used only for business purposes;
(iii)a building intended to be used only to accommodate animals;
(b)design work carried out by an architect, engineer or draftsperson;
(c)the preparation of plans, specifications or bills of quantity for the carrying out of domestic building work;
(d)work involved in obtaining foundations data about a building site;
(e)transporting a building or kit home;
(f)work declared under a regulation to be excluded building work if there are reasonable grounds for considering the work to be excluded building work.
farm building means a building that—
(a)is constructed on land used entirely or mainly for agricultural or pastoral purposes; and
(b)is used, or intended to be used, for agricultural or pastoral purposes.
foundations data see schedule section 8.home see schedule section 9.level 1 regulated contract see schedule section 6.level 2 regulated contract see schedule section 7.manage, the carrying out of domestic building work, includes the provision of supervisory, advisory or administrative services for carrying out the work.mixed-purpose contract means a contract entered into between a building contractor and building owner that entitles the building contractor to be paid for both of the following—
(a)carrying out, or managing the carrying out of, domestic building work;
(b)additional services.
practical completion, for a domestic building contract, means the day when the subject work is completed—
(a)in compliance with the contract, including all plans and specifications for the work and all statutory requirements applying to the work; and
(b)without any defects or omissions, other than minor defects or minor omissions that will not unreasonably affect occupation; and
(c)if the building owner claims there are minor defects or minor omissions—the building contractor gives the building owner a defects document for the minor defects or minor omissions.
prime cost item, for a domestic building contract, means an item, including, for example, a fixture or fitting—
(a)that has not been selected, or the price of which is not known, when the contract is entered into; and
(b)for the cost of supply and delivery of which a reasonable allowance is, or is to be, made in the contract by the building contractor.
progress payment, for a regulated contract, means a payment of an amount that is a part of the contract price for the contract, but does not include a payment of an amount that is, or is in the nature of, a deposit under the contract.provisional sum, for a domestic building contract, see schedule section 10.reasonably believes ...sch 1B def reasonably believes om 2017 No. 29s 34sch 1regulated amount means $3,300 or the higher amount, if any, prescribed by a regulation.regulated contract see schedule section 5.resident owner, under a domestic building contract, means a building owner who—
(a)is an individual; and
(b)intends to reside in the building—
(i)on completion of the domestic building work; or
(ii)within 6 months after the completion of the work.
schedule section, in relation to a reference, means the section of this schedule corresponding to the reference.Example—Schedule section 14 means section 14 of this schedule.statutory warranties means the warranties that are part of a regulated contract because of schedule section 19.subcontractor means a person who enters into a contract with a building contractor to carry out domestic building work to be carried out under a domestic building contract.subject work, for a domestic building contract, means—
(a)the domestic building work carried out, being carried out or to be carried out under the contract; or
(b)the domestic building work the carrying out of which has been, is being or is to be managed under the contract.
written form, for a regulated contract, means—
(a)in handwritten or typewritten form; or
(b)in a combination of handwritten and typewritten forms.
sch 1B s 1 ins 2014 No. 57s 602Meaning of contract price(1)Contract price, for a domestic building contract, means the total amount payable under the contract to carry out domestic building work and includes—
(a)an amount the building contractor is entitled to receive and keep under the contract; and
(b)an amount the building contractor is entitled to receive under the contract for payment to another person.
(2)However, the contract price does not include an amount a person, other than the building contractor, is entitled to receive directly from the building owner for any of the following matters if the matter for which it is payable relates to the carrying out of the subject work—
(a)conveying services to the building site;
(b)connecting or installing services for use at the building site;Examples of services—gas, electricity, telephone, water and sewerage
(c)issuing a development approval or similar authorisation.
sch 1B s 2 ins 2014 No. 57s 603Meaning of domestic building contract(1)A domestic building contract is—
(a)a contract to carry out domestic building work; or
(b)a construction management contract for the provision of building work services for domestic building work; or
(c)another contract to manage the carrying out of domestic building work.
(2)However, a domestic building contract does not include—
(a)a contract between a building contractor and subcontractor; or
(b)a contract between a building contractor and a building owner for the construction of 2 or more detached dwellings; or
(c)a contract between the holder of an owner-builder permit and a building contractor; or
(d)a contract under which the building owner is the State, an entity representing the State or a local government.
(3)Subsection (4) applies if—
(a)a building contractor and building owner enter into 2 or more separate contracts, each for the construction of 1 detached dwelling; and
(b)the separate contracts could be the subject of a single contract for the construction of 2 or more detached dwellings.
(4)The separate contracts are taken to be a contract between a building contractor and a building owner for the construction of 2 or more detached dwellings.sch 1B s 3 ins 2014 No. 57s 604Meaning of domestic building work(1)Each of the following is domestic building work—
(a)the erection or construction of a detached dwelling;
(b)the renovation, alteration, extension, improvement or repair of a home;
(c)removal or resiting work for a detached dwelling;
(d)the installation of a kit home at a building site.
(2)However—
(a)removal work for a detached dwelling is domestic building work only if the dwelling is intended to be resited at another place and used, at the place, as a residence; and
(b)resiting work for a detached dwelling is domestic building work only if the dwelling is intended to be used at the place at which it is being resited as a residence.
(3)Domestic building work includes—
(a)work (associated work) associated with the erection, construction, removal or resiting of a detached dwelling; and
(b)work (associated work) associated with the renovation, alteration, extension, improvement or repair of a home.
(4)Without limiting subsection (3), associated work includes—
(a)landscaping; and
(b)paving; and
(c)the erection or construction of a building or fixture associated with the detached dwelling or home.Examples of buildings and fixtures—retaining structures, driveways, fencing, garages, carports, workshops, swimming pools and spas
(5)For the erection or construction of a detached dwelling, domestic building work includes the provision of services or facilities to the dwelling or the property on which the dwelling is, or is to be, situated.(6)For the renovation, alteration, extension, improvement or repair of a home, domestic building work includes the provision of services or facilities to the home or the property on which the home is situated.Examples of services and facilities for subsections (5) and (6)—lighting, heating, ventilation, air conditioning, water supply, sewerage and drainage(7)Also, domestic building work includes—
(a)site work relating to work mentioned in subsection (1), (3), (5) or (6); and
(b)work declared under a regulation to be domestic building work if there are reasonable grounds for considering the work to be domestic building work.
(8)However, domestic building work does not include excluded building work.(9)In this section—
(a)a reference to a detached dwelling includes a reference to any part of a detached dwelling; and
(b)a reference to a home includes a reference to any part of a home; and
(c)a reference to site work includes a reference to work required to be carried out to gain access, or to remove impediments to access, to a site.
(10)In this section—kit home means a set of building components offered for sale on the basis that the components are sufficient for the construction of 1 of the following if constructed in compliance with a plan or instruction provided by the seller—
(a)a detached dwelling;
(b)a garage;
(c)a carport;
(d)another structure prescribed by regulation.
removal work, for a detached dwelling, means work relating to the dwelling carried out at the place at which the dwelling is located for relocating the dwelling to another place.resiting work, for a detached dwelling, means work relating to the dwelling carried out at a place for resiting the dwelling at the place following its removal from another place.sch 1B s 4 ins 2014 No. 57s 606Meaning of level 1 regulated contract(1)A level 1 regulated contract is—
(a)a domestic building contract for which the contract price is more than the regulated amount but less than the level 2 amount; or
(b)a cost plus contract for which the total amount payable for the contracted services is reasonably estimated to be more than the regulated amount but less than the level 2 amount; or
(c)a mixed-purpose contract for which the amount referable to the contracted services is more than the regulated amount but less than the level 2 amount.
(2)In this section—level 2 amount means the amount prescribed under schedule section 7(2).sch 1B s 6 ins 2014 No. 57s 607Meaning of level 2 regulated contract(1)A level 2 regulated contract is—
(a)a domestic building contract for which the contract price is equal to or more than the level 2 amount; or
(b)a cost plus contract for which the total amount payable for the contracted services is reasonably estimated to be equal to or more than the level 2 amount; or
(c)a mixed-purpose contract for which the amount referable to the contracted services is equal to or more than the level 2 amount.
(2)In this section—level 2 amount means the amount prescribed by regulation.sch 1B s 7 ins 2014 No. 57s 608Meaning of foundations data(1)Foundations data is the information about a building site a building contractor exercising reasonable care and skill would need to have to prepare—
(a)an appropriate footings design for the site and, if appropriate, an appropriate concrete slab design for the site; and
(b)an adequate estimate of the cost of constructing the footings and, if appropriate, concrete slab.
(2)The information mentioned in subsection (1) includes—
(a)relevant information contained in, or obtainable from, reports, surveys, test results, plans, specifications or calculations prescribed under a regulation; and
(b)other information prescribed under a regulation.
sch 1B s 8 ins 2014 No. 57s 609Meaning of home(1)A home is a building or portion of a building that is designed, constructed or adapted for use as a residence.Examples—a detached or semi-detached dwelling, transportable house, terrace or townhouse, duplex, villa home, strata or community title home unit or residential unit(2)However, a home does not include a building or a part of a building declared under a regulation not to be a home.sch 1B s 9 ins 2014 No. 57s 6010Meaning of provisional sum(1)A provisional sum, for a domestic building contract, is an amount that is an estimate of the cost of providing particular contracted services.(2)However, subsection (1) applies only to contracted services for which the building contractor, after making all reasonable enquiries, can not state a definite amount when the contract is entered into.(3)The reference in subsection (1) to the cost of providing the contracted services includes a reference to the cost of supplying materials needed for the subject work.sch 1B s 10 ins 2014 No. 57s 6011Multiple contracts for the same domestic building work(1)This section applies if a building contractor and building owner enter into 2 or more separate contracts that—
(a)could be the subject of a single contract for carrying out domestic building work; and
(b)if they were the subject of a single contract, would be a contract for carrying out domestic building work.
(2)The separate contracts are taken to be a single contract for which the contract price is the sum of the contract prices for the separate contracts.Example for this section—A building contractor that manufactures and installs kitchens enters into one contract with a building owner for the manufacture of a kitchen and a second contract for its installation.sch 1B s 11 ins 2014 No. 57s 6012References to particular termsIn this schedule—
(a)a reference to a building contractor in association with a reference to a domestic building contract is a reference to the building contractor under the contract; and
(b)a reference to a building owner in association with a reference to a domestic building contract is a reference to the building owner under the contract; and
(c)a reference to contracted services in association with a reference to a domestic building contract is a reference to the contracted services for the contract; and
(d)a reference to subject work in association with a reference to a domestic building contract is a reference to the subject work for the contract; and
(e)a reference to a building site in association with a reference to a domestic building contract is a reference to the building site for the contract.
sch 1B s 12 ins 2014 No. 57s 60Part 2Contracts and related documentssch 1B pt 2 hdg ins 2014 No. 57s 60Division 1The contractsch 1B pt 2 div 1 hdg ins 2014 No. 57s 6014Requirements for contract—level 2 regulated contract(1)This section applies to a level 2 regulated contract.(2)The contract must be in a written form, dated and signed by or on behalf of each of the parties to it.(3)The contract must contain all of the following—
(a)the names of the parties to it, including the name of the building contractor as it appears on the contractor’s licence;
(b)the building contractor’s licence number as it appears on the building contractor’s licence;
(c)a description of the subject work;
(d)any plans and specifications for the subject work, including all plans and specifications required for carrying out the work in compliance with any development approvals or similar authorisations that are required by law for carrying out the work;
(e)the contract price or the method for calculating it, including the building contractor’s reasonable estimate;
(f)a provision that states the date for the start of the subject work at the building site, or how the date is to be determined;
(g)a provision that states the date for practical completion or how the date is to be determined;
(h)a statement of each of the statutory warranties that apply to the subject work;
(i)a conspicuous notice advising the building owner of the right the owner may have to withdraw from the contract under schedule section 35.
(4)If the contract price is fixed, it must be stated in a prominent position on the first page of the contract schedule.(5)If the contract price is not fixed, the method for calculating it, including any allowances, must be stated in the contract schedule.(6)If the contract price may be changed under a provision of the contract, the contract must also contain—
(a)a warning to that effect; and
(b)a brief explanation of the effect of the provision allowing change to the contract price.
(7)The warning and explanation mentioned in subsection (6) must be in a prominent position on the first page of the contract schedule.(8)The contract must not state the name of any person—
(a)as the building contractor; or
(b)so it may reasonably be mistaken to be the building contractor;
unless the person is the building contractor under the contract.Example—a domestic building contract stating a company name as the building contractor if an individual is actually the building contractor under the contract(9)The contract must also comply with all other requirements prescribed by regulation.(10)The contract has effect only if it complies with subsection (2).sch 1B s 14 ins 2014 No. 57s 60Division 2Copies of documentssch 1B pt 2 div 2 hdg ins 2014 No. 57s 6015Copy of contract for building ownerWithin 5 business days after entering into a regulated contract, the building contractor must give the building owner a readily legible signed copy of the contract, including any plans and specifications for the subject work.Maximum penalty—60 penalty units.sch 1B s 15 ins 2014 No. 57s 6016Copy of commencement notice(1)This section applies to a level 2 regulated contract.(2)Within 10 business days of starting the subject work at the building site, the building contractor must give the building owner a commencement notice signed by the contractor and stating—
(a)the date the subject work started at the building site; and
(b)the date for practical completion.
Maximum penalty—40 penalty units.sch 1B s 16 ins 2014 No. 57s 6017Copies of certificate of inspection(1)This section applies if the building contractor under a regulated contract is responsible for engaging a building certifier for the subject work under regulated contract (whether personally or as agent for the building owner).(2)The building contractor must give the building owner a copy of each certificate of inspection issued by the building certifier for the subject work as soon as practicable after receiving the certificate.Maximum penalty—20 penalty units.(3)In a proceeding for a contravention of subsection (2) in relation to a certificate of inspection, it is a defence for the building contractor to prove that the contractor did not comply with the subsection because the contractor reasonably believed the building owner already had a copy of the certificate of inspection.sch 1B s 17 ins 2014 No. 57s 6018Copy of consumer building guide(1)This section applies to a level 2 regulated contract.(2)The building contractor must give the building owner a copy of the consumer building guide before the owner signs the contract.Maximum penalty—20 penalty units.(3)The consumer building guide may be given to the building owner separate from, or attached to, the contract.sch 1B s 18 ins 2014 No. 57s 60Part 3Warrantiessch 1B pt 3 hdg ins 2014 No. 57s 60Division 1Incorporation of warrantiessch 1B pt 3 div 1 hdg ins 2014 No. 57s 6019Implied warranties(1)The warranties mentioned in division 2 are part of every regulated contract.(2)A warranty mentioned in a section of division 3 is part of each regulated contract that is a contract of the type to which the section applies.Note—The Australian Consumer Law (Queensland) also provides particular statutory consumer guarantees if a person supplies, in trade or commerce, goods or services to a consumer as defined under that law.sch 1B s 19 ins 2014 No. 57s 60Division 2Implied warranties for all contractssch 1B pt 3 div 2 hdg ins 2014 No. 57s 6020Suitability of materials(1)The building contractor warrants that all materials to be supplied for use in the subject work—
(a)will be good and, having regard to the relevant criteria, suitable for the purpose for which they are used; and
(b)unless otherwise stated in the contract, will be new.
(2)Subsection (1) applies to the building contractor for materials only if the materials are supplied by the responsible person for the contract.(3)Despite subsection (2), if the contract is being administered by an architect engaged by the building owner, subsection (1) does not apply to the building owner for materials if the responsible person is subject to the direction of the architect for supplying the materials.(4)Also, despite subsection (2), subsection (1) does not apply to the building contractor for materials if—
(a)the building owner is responsible for nominating the materials for use in the subject work; and
(b)either—
(i)there are no reasonable grounds for not using the materials; or
(ii)if there are reasonable grounds for not using the materials—the building owner insists on the materials being used despite written advice to the contrary given to the building owner by the building contractor.
(5)A building owner is responsible for nominating materials for use in the subject work only if—
(a)the building owner nominates the materials specifically; and
(b)the nomination is made without any recommendation, representation, suggestion or other approach being made to the building owner by the building contractor—
(i)supporting, or approving, the use of the materials; or
(ii)criticising, or disapproving the use of, other materials that could be considered to be appropriate for use for the purpose for which the materials nominated by the building owner are to be used.
(6)In this section—relevant criteria, for materials, means—
(a)generally accepted practices or standards applied in the building industry for the materials; or
(b)specifications, instructions or recommendations of manufacturers or suppliers of the materials.
responsible person, for a regulated contract, means—
(a)if the contract is a contract for carrying out the subject work—the building contractor; or
(b)if the contract is a contract for managing the carrying out of the subject work—the person responsible for carrying out the work.
sch 1B s 20 ins 2014 No. 57s 6021Compliance with legal requirementsThe building contractor warrants the subject work will be carried out in accordance with all relevant laws and legal requirements, including, for example, the Building Act 1975.sch 1B s 21 ins 2014 No. 57s 6022Standard of work and exercise of care and skillThe building contractor warrants the subject work will be carried out—
(a)in an appropriate and skilful way; and
(b)with reasonable care and skill.
sch 1B s 22 ins 2014 No. 57s 60Division 3Implied warranties for particular contractssch 1B pt 3 div 3 hdg ins 2014 No. 57s 6023Adherence to plans and specifications(1)This section applies to a regulated contract if plans and specifications form part of the contract.(2)The building contractor warrants the subject work will be carried out in accordance with the plans and specifications.sch 1B s 23 ins 2014 No. 57s 6024Suitability of premises for occupation(1)This section applies to a regulated contract if the subject work—
(a)consists of the erection or construction of a detached dwelling to a stage suitable for occupation; or
(b)is work intended to renovate, alter, extend, improve or repair a home to a stage suitable for occupation.
(2)The building contractor warrants the detached dwelling or home will be suitable for occupation when the work is finished.sch 1B s 24 ins 2014 No. 57s 6025Carrying out work with reasonable diligenceThe building contractor warrants the subject work will be carried out with reasonable diligence.sch 1B s 25 ins 2014 No. 57s 6026Calculation of provisional sums and prime cost items(1)This section applies to a regulated contract providing for a provisional sum or prime cost item.(2)The building contractor warrants the provisional sum or prime cost item has been calculated with reasonable care and skill, having regard to all the information reasonably available when the contract is entered into (including information about the nature and location of the building site).sch 1B s 26 ins 2014 No. 57s 60Division 4Generalsch 1B pt 3 div 4 hdg ins 2014 No. 57s 6027Warranties run with building(1)An associated person for a regulated contract has the same rights for a breach of a warranty mentioned in division 2 or schedule section 23 or 24 as if the person were the building owner.(2)However, subsection (1) applies to the associated person—
(a)only if, at the relevant time, the person did not know, and could not reasonably have known, of the existence of the breach; and
(b)only to the extent the rights are rights that, immediately before the person became an associated person for the contract, were held by—
(i)the building owner; or
(ii)another associated person for the contract.
(3)In this section—associated person, for a regulated contract, means a person, other than the building owner, who is the owner for the time being of the building in relation to which, or land on which, the subject work was carried out.relevant time, for an associated person, for a regulated contract, means the time the person entered into the agreement under which the person became an associated person for the contract.sch 1B s 27 ins 2014 No. 57s 6028Protection of rights given by warrantiesA provision of an agreement or other document that purports to restrict or take away the rights of a person for a breach of a warranty mentioned in this part is void.sch 1B s 28 ins 2014 No. 57s 6029Proceedings for breach of warranties(1)Proceedings for a breach of a statutory warranty must be started before the end of the warranty period for the breach.(2)However, if the breach of statutory warranty becomes apparent within the last 6 months of the warranty period, proceedings may be started within a further 6 months after the end of the warranty period.(3)The warranty period for a regulated contract—
(a)is 6 years for a breach that results in a structural defect, as prescribed by regulation, or 1 year in any other case; and
(b)starts—
(i)if the subject work is completed—on completion of the work; or
(ii)if the subject work is not completed—
(A)if the contract is terminated—the date the contract is terminated; or
(B)if the contract is not terminated—the date on which work under the contract ceased; or
(C)if the contract is not terminated and work under the contract was not started—the date the contract was entered into.
(4)A breach of a statutory warranty becomes apparent when any person entitled to the benefit of the warranty first becomes aware, or ought reasonably to have become aware, of the breach.(5)The fact that a person entitled to the benefit of a statutory warranty has enforced the warranty in relation to a particular deficiency in domestic building work does not prevent the person from enforcing the same warranty for a deficiency of a different kind in the work (the other deficiency) if—
(a)the other deficiency was in existence when the work to which the warranty relates was completed; and
(b)the person did not know, and could not reasonably have been expected to know, of the existence of the other deficiency when the warranty was previously enforced; and
(c)the proceedings to enforce the warranty in relation to the other deficiency are brought within the period mentioned in subsection (1).
(6)In proceedings for a breach of a statutory warranty, it is a defence for the defendant to prove that—
(a)the deficiencies of which the plaintiff complains arise from instructions given by the person for whom the work was done contrary to the written advice of the defendant or the person who did the work; or
(b)the defendant was not reasonably given access to rectify the deficiencies of which the plaintiff complains.
sch 1B s 29 ins 2014 No. 57s 60Part 4Restrictions relating to contractssch 1B pt 4 hdg ins 2014 No. 57s 60Division 1Entering into contractssch 1B pt 4 div 1 hdg ins 2014 No. 57s 6030Contracted services must not start before regulated contract complies with requirementsThe building contractor for a regulated contract must not start to provide the contracted services before the contract complies with the requirements of—
(a)for a level 1 regulated contract—schedule section 13; or
(b)for a level 2 regulated contract—schedule section 14.
Maximum penalty—100 penalty units.sch 1B s 30 ins 2014 No. 57s 6031Foundations data(1)This section applies if the subject work proposed for a regulated contract—
(a)requires the construction or alteration of footings, or a concrete slab, for a building; or
(b)may adversely affect the footings of a building or a concrete slab forming part of a building.
(2)Before entering into the contract, the building contractor must obtain the foundations data that is appropriate for the building site, having regard to the following—
(a)the Building Code of Australia;
(b)the need for a drainage plan;
(c)the need for engineer’s drawings and computations;
(d)the need for information on the fall of the land at the building site.
Maximum penalty—100 penalty units.(3)However, subsection (2) does not apply if—
(a)the building contractor is not lawfully entitled to enter the land at the building site to obtain the foundations data before entering into the contract; and
(b)the contract guarantees that there will be no increase in the contract price because of the foundations data.
(4)Nothing in subsection (2) requires a building contractor to commission the preparation of foundations data to the extent the data already exists and it is reasonable for the building contractor to rely on the data.(5)The building contractor must give a copy of any foundations data obtained by the building contractor for this section to the building owner on payment by the building owner of the costs incurred by the building contractor in obtaining the data.Maximum penalty—10 penalty units.(6)Subsection (5) does not apply to a building contractor for foundations data if the data is given to the building contractor by the building owner.(7)In a proceeding for a contravention of subsection (5) in relation to a copy of any foundations data, it is a defence for the building contractor to prove that the building contractor reasonably believes the building owner already has a copy of the data.(8)The building contractor under a regulated contract can not seek from the building owner an amount not already provided for in the contract if—
(a)the building contractor entered into the contract before obtaining the foundations data under subsection (2); and
(b)the need for the additional amount could reasonably have been established, and the amount calculated, had the building contractor complied with the subsection.
(9)For subsection (8), an amount is not taken to be provided for in a regulated contract only because the contract contains a provision allowing for an increase to be made of the contract price.(10)Nothing in this section prevents the building contractor from claiming an amount not provided for in the contract if—
(a)the building contractor has complied with subsection (2); and
(b)the need for the additional amount can not be established from the foundations data obtained by the building contractor.
sch 1B s 31 ins 2014 No. 57s 6032Arbitration clauses(1)A provision of a regulated contract, or other agreement, requiring that a dispute under the contract be referred to arbitration is void.(2)Subsection (1) does not apply to a provision of an agreement, other than a regulated contract, if the agreement is entered into after a dispute under the contract arises.sch 1B s 32 ins 2014 No. 57s 60Division 2Payments relating to contractssch 1B pt 4 div 2 hdg ins 2014 No. 57s 6033Deposits(1)The building contractor under a regulated contract must not, before starting to provide the contracted services at the building site, demand or receive a deposit under the contract of more than—
(a)for a level 1 regulated contract (other than a contract mentioned in paragraph (c))—10% of the contract price; or
(b)for a level 2 regulated contract (other than a contract mentioned in paragraph (c))—5% of the contract price; or
(c)for a level 1 or 2 regulated contract under which the value of the off-site work is more than 50% of the contract price—20% of the contract price.
Maximum penalty—100 penalty units.(2)In this section, a reference to the contract price for a contract includes, for a cost plus contract, a reference to the estimated amount for the contract.(3)In this section—deposit, for a regulated contract, includes any payment for domestic building work demanded or received by the building contractor prior to the contracted services commencing at the building site, including, for example, any insurance premium paid under part 5.off-site work, for a regulated contract, means contracted services performed at a place that is not the place at which the domestic building work is to be finally installed or constructed under the contract.sch 1B s 33 ins 2014 No. 57s 6034Progress payments for regulated contracts(1)The building contractor under a regulated contract must not claim an amount under the contract, other than a deposit, unless the amount—
(a)is directly related to the progress of carrying out the subject work at the building site; and
(b)is proportionate to the value of the subject work that relates to the claim, or less than that value.Example for paragraph (b)—The claimed amount is for half of the contract price for a regulated contract, less a 5% deposit, and is demanded after the completion of half of the subject work.
Maximum penalty—50 penalty units.(2)A regulation may prescribe when an amount is proportionate to the value of subject work under a regulated contract.(3)For subsection (1), a building contractor is taken to claim an amount if the contractor demands or receives the amount.(4)In this section—building site, for a regulated contract, does not include a place where the subject work has been, is being, or is to be, carried out if the work is required to later be installed or constructed at another place under the contract.deposit, for a regulated contract, means the deposit permitted for the contract under schedule section 33(1).sch 1B s 34 ins 2014 No. 57s 60Part 5Cooling-off period and withdrawing from regulated contractssch 1B pt 5 hdg ins 2014 No. 57s 6035Right of building owner to withdraw from contract in cooling-off period(1)The building owner under a regulated contract may withdraw from the contract within 5 business days after the day on which the owner receives a copy of the signed contract from the building contractor.(2)Also, if the building owner under a level 2 regulated contract does not receive the consumer building guide before receiving a copy of the signed contract, the owner may withdraw from the contract within 5 business days after the day on which the owner receives the consumer building guide.(3)If 5 business days have elapsed from the day the contract was entered into and the owner has not received from the building contractor a copy of the signed contract and, for a level 2 regulated contract, the consumer building guide, the owner may withdraw from the contract.(4)Nothing in subsection (3) affects the right of the building owner to withdraw from the contract under subsection (1) or (2) if the owner subsequently receives from the building contractor a copy of the signed contract and, for a level 2 regulated contract, the consumer building guide.sch 1B s 35 ins 2014 No. 57s 6036Restrictions affecting right of withdrawal in cooling-off period(1)This section applies despite schedule section 35.(2)A building owner may not withdraw from a regulated contract (the current contract) under schedule section 35 if—
(a)the building owner and building contractor previously entered into a regulated contract (the previous contract); and
(b)the terms of the previous contract and current contract are substantially the same; and
(c)the contracted services for the previous contract and current contract—
(i)are substantially the same; and
(ii)relate to the same detached dwelling, home or land.
(3)Also, a building owner may not withdraw from a regulated contract under schedule section 35 if—
(a)before entering into the contract, the building owner received formal legal advice about the contract; or
(b)when, or after, the contract is entered into, the building owner tells the building contractor that the building owner received formal legal advice about the contract before entering into the contract.
(4)In this section—formal legal advice means independent advice—
(a)given by a practising legal practitioner; and
(b)for the giving of which an amount is paid, or is payable, to the legal practitioner by the person to whom the advice is given.
practising legal practitioner means a lawyer authorised under a law of the State to practise as a lawyer for purposes including the giving, for reward, of advice, including, for example, advice about domestic building contracts.sch 1B s 36 ins 2014 No. 57s 6037Withdrawal procedure(1)To withdraw from a regulated contract under schedule section 35, the building owner must, within the time allowed under the section for the withdrawal—
(a)give a withdrawal notice to the building contractor; or
(b)leave a withdrawal notice at the address shown as the building contractor’s address in the contract; or
(c)serve a withdrawal notice on the building contractor in accordance with any provision in the contract providing for service of notices on the building contractor by the building owner.
(2)In this section—withdrawal notice means a written notice signed by the building owner under a regulated contract stating—
(a)that the building owner withdraws from the contract; and
(b)the section of this schedule under which the withdrawal is made.
sch 1B s 37 ins 2014 No. 57s 6038Rights and obligations of parties following withdrawal in cooling-off period(1)This section applies if a building owner withdraws from a regulated contract under schedule section 35.(2)If there is a prepaid amount for the contract that is not less than the retainable amount, the building contractor—
(a)may keep an amount equal to the retainable amount out of the prepaid amount; and
(b)must refund any balance of the prepaid amount to the building owner.
(3)If there is a prepaid amount for the contract that is less than the retainable amount, the building owner must pay the building contractor an amount equal to the difference between the retainable amount and the prepaid amount.(4)If there is no prepaid amount for the contract, the building owner must pay the building contractor an amount equal to the retainable amount.(5)If an amount is not paid by a person as required under this section, the person to whom it is payable may recover the amount from the other person as a debt.(6)Except as provided under subsection (3) or (4), the building owner is not liable to the building contractor in any way for withdrawing from the contract.(7)In this section, a reference to the prepaid amount for the contract is a reference to the amount paid to the building contractor under the contract by the building owner before the building owner withdrew from the contract.(8)Also, in this section, a reference to the retainable amount for the contract is a reference to the sum of—
(a)an amount equal to any out-of-pocket expenses reasonably incurred by the building contractor before the building owner withdrew from the contract; and
(b)if the building owner withdraws from the contract under schedule section 35(1)—$100.
sch 1B s 38 ins 2014 No. 57s 6039Waiving right of withdrawal(1)The building owner under a repair contract may waive the building owner’s right to withdraw from the contract.(2)To waive the right, the building owner must—
(a)give a waiver notice to the building contractor; or
(b)leave a waiver notice at the address shown as the building contractor’s address in the contract; or
(c)serve a waiver notice on the building contractor in accordance with any provision in the contract providing for service of notices on the building contractor by the building owner.
(3)This section has effect despite section 108D.(4)In this section—repair includes an alteration, improvement or replacement that it is necessary or reasonable to carry out instead of effecting a repair.repair contract means a regulated contract under which the subject work is composed of any 1 or more of the following—
(a)the repair of a home;
(b)work associated with the repair of a home;
(c)the provision, for the repair of a home, of services or facilities to the home or the property on which the home is situated;
(d)site work relating to work mentioned in paragraph (a), (b) or (c).
waiver notice means a written notice signed by the building owner under a repair contract stating that the building owner waives the building owner’s right to withdraw from the contract.sch 1B s 39 ins 2014 No. 57s 60Part 6Variations of contractssch 1B pt 6 hdg ins 2014 No. 57s 6040Variations must be in writing(1)This section applies if there is to be a variation of a regulated contract.(2)The building contractor must give the building owner a copy of the variation in writing before the first of the following happens—
(a)5 business days elapse from the day the building contractor and the building owner agree to the variation;
(b)any domestic building work the subject of the variation starts.
Maximum penalty—20 penalty units.(3)The building contractor may give the building owner the variation under subsection (2)—
(a)personally; or
(b)by sending it by post, facsimile or email; or
(c)in accordance with any provision in the contract providing for service of notices on the building owner by the building contractor.
(4)In a proceeding for a contravention of subsection (2), it is a defence for the building contractor to prove that—
(a)the variation is for domestic building work that is required to be carried out urgently; and
(b)it is not reasonably practicable, in the particular circumstances, to produce a copy of the variation in writing before carrying out the work.
(5)The building contractor must not start to carry out any domestic building work the subject of the variation before the building owner agrees to the variation in writing.Maximum penalty—20 penalty units.sch 1B s 40 ins 2014 No. 57s 6041General contents of document evidencing a variation(1)The building contractor under a regulated contract must ensure a document evidencing a variation of the contract complies with the formal requirements for a variation.Maximum penalty—20 penalty units.(2)The document evidencing the variation complies with the formal requirements if it—
(a)is readily legible; and
(b)describes the variation; and
(c)states the date of the request for the variation; and
(d)if the variation will result in a delay affecting the subject work—states the building contractor’s reasonable estimate for the period of delay; and
(e)states the change to the contract price because of the variation, or the method for calculating the change to the contract price because of the variation; and
(f)if the variation results in an increase in the contract price—states when the increase is to be paid; and
(g)if the variation results in a decrease in the contract price—states when the decrease is to be accounted for.
(3)Any increase in the contract price as a result of the variation can not be required to be paid before work the subject of the variation is started.sch 1B s 41 ins 2014 No. 57s 6042Extension of time(1)The building contractor under a regulated contract may only claim for an extension of time under the contract if—
(a)the delay causing the need for the extension of time was—
(i)not reasonably foreseeable and beyond the reasonable control of the contractor; or
(ii)caused by the building owner; or
(iii)caused by a variation of the contract complying with schedule section 40; and
(b)the claim is made to the building owner in writing; and
(c)the claim is given to the building owner within 10 business days of the building contractor becoming aware of the cause and extent of the delay or when the building contractor reasonably ought to have become aware of the cause and extent of the delay; and
(d)the owner approves the claim in writing.
(2)A building contractor under a regulated contract must not seek to rely on an extension of time under the contract unless the contractor claimed for the extension of time in compliance with subsection (1).Maximum penalty—20 penalty units.(3)A building contractor under a regulated contract must give the building owner a signed copy of a claim for an extension of time within 5 business days of the owner approving the claim.Maximum penalty—20 penalty units.(4)A regulation may prescribe when a series of similar delays may be taken to be a single delay for the purpose of subsection (1)(c).sch 1B s 42 ins 2014 No. 57s 60Part 7Building sitessch 1B pt 7 hdg ins 2014 No. 57s 6043Building contractor does not acquire interest in land of resident owner(1)A domestic building contract does not give the building contractor an interest in land of a resident owner for the Land Title Act 1994, section 122.(2)A building contractor who lodges a caveat claiming an interest in land of a building owner under a domestic building contract knowing the owner to be a resident owner commits an offence.Maximum penalty for subsection (2)—100 penalty units.sch 1B s 43 ins 2014 No. 57s 60Part 8Other matters relating to contractssch 1B pt 8 hdg ins 2014 No. 57s 6044Effect of failure by building contractor to comply with requirementUnless the contrary intention appears in this Act, a failure by a building contractor to comply with a requirement under this Act in relation to a domestic building contract does not make the contract illegal, void or unenforceable.sch 1 s 44 ins 2014 No. 57s 60Part 9Miscellaneoussch 1B pt 9 hdg ins 2014 No. 57s 6045Relationship with other ActsThe Commercial Arbitration Act 2013 does not apply to domestic building work unless the relevant arbitration agreement under that Act—
(a)is an agreement other than a domestic building contract; and
(b)is entered into after the dispute to which it relates arises.
sch 1B s 45 ins 2014 No. 57s 60amd 2017 No. 43s 30646Consumer building guide(1)The commission must prepare and publish a consumer building guide in a form prescribed by regulation.(2)The consumer building guide may, for informational purposes, contain information about the following—
(a)warnings about cost plus contracts;
(b)information about the cooling-off period;
(c)commencement notice requirements;
(d)deposit and progress payment requirements;
(e)variation procedures;
(f)statutory warranties;
(g)dispute resolution procedures.
(3)Subsection (2) does not limit the type of information the commission may include in the consumer building guide.sch 1B s 46 ins 2014 No. 57s 60sch 1B hdg ins 2014 No. 57s 60Schedule 2Dictionarysection 4accumulate, for part 3E, see section 67AQ.sch 2 def accumulate ins 2003 No. 1s 44(2)administering authority, for part 3E, see section 67AQ.sch 2 def administering authority ins 2003 No. 1s 44(2)administration services, for building work or tribunal work, includes the following—
(a)preparing tender documentation and calling and selecting tenders;
(b)arranging and conducting on-site meetings and inspections;
(c)arranging payment of subcontractors;
(d)arranging for certificates, including certificates from a local government, to be issued;
(e)administration for the work usually carried out by—
(i)a construction manager; or
(ii)a project manager under a project management agreement;
(f)other administration for the work usually carried out by a licensed contractor in the course of the contractor’s business.
sch 2 def administration services ins 2007 No. 47s 82(2)Advisory Service ...sch 2 def Advisory Service om from prev s 4 1994 No. 20s 4(1)advisory services, for building work or tribunal work, includes the provision of advice or a report about building work other than—
(a)the carrying out of a completed building inspection; or
(b)the inspection or investigation of a building, and the provision of advice or a report, for the following—
(i)termite management systems for the building;
(ii)termite infestation in the building.
sch 2 def advisory services ins 2007 No. 47s 82(2)alternative solution ...sch 2 def alternative solution ins 2007 No. 47s 82(2)om 2020 No. 24s 153 sch 1pt 2apprentice see the Further Education and Training Act 2014, schedule 1.sch 2 def apprentice ins 2007 No. 47s 82(2)sub 2014 No. 25s 223 sch 1pt 2appropriate insurance premium, for part 5, see section 67WA.sch 2 def appropriate insurance premium ins 2014 No. 57s 61(2)approved form means a form approved by the chief executive or the commissioner under section 115C.sch 2 def approved form ins 2017 No. 43s 307(2)approved security provider, for part 4A, see section 67A.sch 2 def approved security provider ins 1999 No. 43s 4(2)reloc 1999 No. 43s 4(4)architect means a person registered as an architect under the Architects Act 2002.sch 2 def architect reloc 1999 No. 43s 4(4)amd 2002 No. 53s 166sch 1assessment manager means an assessment manager under the Planning Act.sch 2 def assessment manager ins 1998 No. 13s 187reloc 1999 No. 43s 4(4)sub 2009 No. 36s 872sch 2amd 2016 No. 27s 376(3); 2019 No. 11s 231 sch 1pt 1assistance, for part 5, see section 67WA.sch 2 def assistance ins 2014 No. 57s 61(2)associated insurable work, for part 5, see section 67WD.sch 2 def associated insurable work ins 2014 No. 57s 61(2)associated with, in relation to a building or other structure, see section 74AA.sch 2 def associated with ins 2017 No. 29s 31(2)authority ...sch 2 def authority reloc 1999 No. 43s 4(4)om 2013 No. 38s 11(1)automated bleeding device means an automatic device used for the purposes of draining or bleeding or removing fluid or gas.sch 2 def automated bleeding device ins 2018 No. 17s 196(1)banned individual see section 67AC.sch 2 def banned individual ins 2003 No. 1s 44(2)board means the Queensland Building and Construction Board established under section 10.sch 2 def board reloc 1999 No. 43s 4(4)sub 2013 No. 38s 11(1)–(2)board’s policies ...sch 2 def board’s policies ins 1994 No. 20s 4(2)reloc 1999 No. 43s 4(4)amd 2013 No. 38s 11(3)om 2017 No. 43s 307(1)building—
(a)generally, includes any fixed structure; orExamples of a fixed structure—
•a fence other than a temporary fence
•a water tank connected to the stormwater system for a building
•an in-ground swimming pool or an above-ground pool fixed to the ground
(b)for part 6AA, see section 74AA; or
(c)for schedule 1B, see schedule 1B, section 1.
sch 2 def building reloc 1999 No. 43s 4(4)amd 2007 No. 47s 82(3)sub 2014 No. 57s 61(1)–(2)amd 2017 No. 29s 31(3)–(4)Building Code of Australia see the Building Act 1975, section 12.sch 2 def Building Code of Australia ins 2003 No. 1s 44(2); 2006 No. 36s 101sch; 1975 No. 11s 283(3)(e) (amd 2006 No. 36s 69)building contract—
(a)for part 3E—see section 67AAA; and
(b)for part 4A—see section 67AAA; and
(c)for schedule 1, part 2—see schedule 1, section 8; and
(d)otherwise—means a contract or other arrangement for carrying out building work in Queensland.
sch 2 def building contract ins 2007 No. 47s 82(2)sub 2013 No. 58s 32sch 2 def building contract, for part 4A, ins 1999 No. 43s 4(2)reloc 1999 No. 43s 4(4)om 2013 No. 58s 32(1)building contractor—
(a)generally, means a person who carries on a business that consists of or includes carrying out building work, and includes a subcontractor who carries out building work for a building contractor; but
(b)for schedule 1B, see schedule 1B, section 1.
sch 2 def building contractor reloc 1999 No. 43s 4(4)amd 2007 No. 47s 82(4)sub 2014 No. 57s 61(1)–(2)building dispute means—
(a)a domestic building dispute; or
(b)a minor commercial building dispute; or
(c)a major commercial building dispute if the parties to the dispute consent to the dispute being heard by the tribunal under section 79.
sch 2 def building dispute ins 2003 No. 30s 169sch 1building owner—
(a)generally, means a person for whom tribunal work is to be, is being or has been carried out, but does not include a building contractor for whom tribunal work is carried out by a subcontractor; but
(b)for schedule 1B, see schedule 1B, section 1.
sch 2 def building owner ins 2003 No. 30s 169sch 1sub 2014 No. 57s 61(1)–(2)building product see section 74AB(1).sch 2 def building product ins 2017 No. 29s 31(2)building product undertaking, for part 6AA, see section 74AO(1).sch 2 def building product undertaking ins 2017 No. 29s 31(2)building site—
(a)generally, means a place where building work has been, is being, or is to be, carried out; but
(b)for schedule 1B, see schedule 1B, section 1.
sch 2 def building site reloc 1999 No. 43s 4(4)sub 2014 No. 57s 61(1)–(2)amd 2017 No. 29s 31(5)building work means—
(a)the erection or construction of a building; or
(b)the renovation, alteration, extension, improvement or repair of a building; or
(c)the provision of lighting, heating, ventilation, air conditioning, water supply, sewerage or drainage in connection with a building; or
(e)any site work (including the construction of retaining structures) related to work of a kind referred to above; or
(f)the preparation of plans or specifications for the performance of building work; or
(fa)contract administration carried out by a person in relation to the construction of a building designed by the person; or
(g)fire protection work; or
(ga)mechanical services work; or
(h)carrying out site testing and classification in preparation for the erection or construction of a building on the site; or
(i)carrying out a completed building inspection; or
(j)the inspection or investigation of a building, and the provision of advice or a report, for the following—
(i)termite management systems for the building;
(ii)termite infestation in the building;
but does not include work of a kind excluded by regulation from the ambit of this definition.sch 2 def building work amd 1999 No. 43s 4(3)reloc 1999 No. 43s 4(4)amd 2000 No. 9s 104sch 1; 2003 No. 1s 44(3); 2007 No. 47s 82(5); 2018 No. 17s 196(2)building work services means 1 or more of the following for building work—
(a)administration services;
(b)advisory services;
(c)management services;
(d)supervisory services.
sch 2 def building work services ins 2007 No. 47s 82(2)calling includes a craft, manufacture, occupation, trade, undertaking or vocation.sch 2 def calling ins 2007 No. 47s 82(2)carry out, for building work (other than for part 4A) means any of the following—
(a)carry out the work personally;
(b)directly or indirectly cause the work to be carried out;
(c)provide building work services for the work.
sch 2 def carry out ins 2007 No. 47s 82(2)carry out building work, for part 4A, see section 67A.sch 2 def carry out building work ins 1999 No. 43s 4(2)reloc 1999 No. 43s 4(4)carry out tier 1 defective work see section 67AB(2).sch 2 def carry out tier 1 defective work ins 2003 No. 1s 44(2)certificate of inspection, for schedule 1B, see schedule 1B, section 1.sch 2 def certificate of inspection ins 2014 No. 57s 61(2)code of practice, for part 6AA, see section 74AA.sch 2 def code of practice ins 2017 No. 29s 31(2)commercial building contract, for part 4A, see section 67A.sch 2 def commercial building contract ins 1999 No. 43s 4(2)reloc 1999 No. 43s 4(4)commercial building dispute means—
(a)a claim or dispute arising between a building owner and a building contractor relating to the performance of reviewable commercial work or a contract for the performance of reviewable commercial work; or
(b)a claim or dispute arising between 2 or more building contractors relating to the performance of reviewable commercial work or a contract for the performance of reviewable commercial work; or
(c)a claim or dispute in negligence, nuisance or trespass related to the performance of reviewable commercial work other than a claim for personal injuries; or
(d)a claim or dispute arising between a building owner or a building contractor and any 1 or more of the following relating to the performance of reviewable commercial work or a contract for the performance of reviewable commercial work—
(i)an architect;
(ii)an engineer;
(iii)a surveyor;
(iv)a quantity surveyor;
(v)an electrician or an electrical contractor;
(vi)a supplier or manufacturer of materials used in the tribunal work.
sch 2 def commercial building dispute ins 2003 No. 30s 169sch 1commission means the Queensland Building and Construction Commission established under section 5.sch 2 def commission ins 2013 No. 38s 11(2)commissioner means the commissioner of the commission.sch 2 def commissioner ins 2013 No. 38s 11(2)company means any body corporate.sch 2 def company reloc 1999 No. 43s 4(4)completed building inspection means the inspection or investigation of, and the provision of advice or a report about, the following class 1a or 10 buildings under the Building Code of Australia—
(a)a building for which there is no current contract between a building contractor and a consumer because the contract has been completed;Example—an existing detached house that has previously been occupied or that has recently been built
(b)a building on which work is not being carried out because the contract under which it was being carried out has been terminated;Example—a detached house on which a building contractor has stopped building work in breach of the terms of a contract with a consumer and the consumer has terminated the contract
(c)a building on which work is being, or was, carried out but not under a contract between a building contractor and a consumer.Example—a detached house being built by, or that was built by, a building contractor but not under a contract with a particular consumer This is known in the building industry as “a speccy”.
sch 2 def completed building inspection ins 1999 No. 43s 4(2)reloc 1999 No. 43s 4(4)sub 2003 No. 1s 44(1)–(2)compliance purpose, for part 9, see section 103G.sch 2 def compliance purpose ins 2017 No. 29s 31(2)condition includes a limitation or restriction.sch 2 def condition reloc 1999 No. 43s 4(4)consequential damage see section 71H.sch 2 def consequential damage ins 2014 No. 57s 61(2)construction management contract means a contract under which a principal engages a construction manager to provide building work services for building work carried out for the principal under construction management trade contracts.sch 2 def construction management contract ins 2007 No. 47s 82(2)construction management trade contract see section 67A.sch 2 def construction management trade contract ins 1999 No. 43s 4(2)reloc 1999 No. 43s 4(4)amd 2007 No. 47s 82(6)construction manager means a person who provides building work services for the carrying out of building work for a principal under a construction management contract.sch 2 def construction manager ins 2007 No. 47s 82(2)consumer—
(a)generally, means a person for whom building work is carried out, but does not include a building contractor for whom building work is carried out by a subcontractor; but
(b)for part 5, see section 67WA.
sch 2 def consumer reloc 1999 No. 43s 4(4)sub 2014 No. 57s 61(1)–(2)consumer building guide, for schedule 1B, see schedule 1B, section 1.sch 2 def consumer building guide ins 2014 No. 57s 61(2)contract, for part 7, means a contract for carrying out tribunal work.sch 2 def contract ins 2003 No. 30s 169sch 1amd 2004 No. 53s 2schcontract administration, in relation to building work designed by a person, includes the following—
(a)preparing tender documentation and calling and selecting tenders;
(b)preparing, or helping the person’s clients with the preparation of, contracts;
(c)preparing additional documentation for the person’s clients or building contractors;
(d)arranging and conducting on-site meetings and inspections;
(e)arranging progress payments;
(f)arranging for certificates, including certificates from a local government, to be issued;
(g)providing advice and help to the person’s clients including during the maintenance period allowed under a contract.
sch 2 def contract administration ins 2003 No. 1s 44(2)contracted party, for part 4A, see section 67A.sch 2 def contracted party ins 1999 No. 43s 4(2)reloc 1999 No. 43s 4(4)contracted services, for schedule 1B, see schedule 1B, section 1.sch 2 def contracted services ins 2014 No. 57s 61(2)contracting party see section 67A.sch 2 def contracting party ins 1999 No. 43s 4(2)reloc 1999 No. 43s 4(4)amd 2007 No. 47s 82(7)contractor’s licence see section 30(1).sch 2 def contractor’s licence reloc 1999 No. 43s 4(4)sub 2007 No. 47s 82(1)–(2)contract price, for a building contract, means the amount payable under the contract for carrying out the building work the subject of the contract, including, if the contract has been the subject of a variation, the contract as varied.sch 2 def contract price ins 1999 No. 43s 4(2)reloc 1999 No. 43s 4(4)sub 2014 No. 57s 61(1)–(2); 2017 No. 43s 307convicted company officer means a person who has been convicted of an offence under the Corporations Act 2001 (Cwlth), section 596(1)(b) or (c).sch 2 def convicted company officer ins 2003 No. 1s 44(2)amd 2004 No. 53s 2schconviction, for part 3E, see section 67AQ.sch 2 def conviction ins 2003 No. 1s 44(2)cooling tower means a device for lowering—
(a)the temperature of recirculated water by bringing the water into contact with fan-forced, or fan-induced, atmospheric air; or
(b)the temperature of water, a refrigerant or other fluid in a pipe or other container by bringing recirculated water and fan-forced, or fan-induced, atmospheric air into contact with the pipe or container.
sch 2 def cooling tower ins 2018 No. 17s 196(1)cost escalation clause ...sch 2 def cost escalation clause reloc 1999 No. 43s 4(4)om 2000 No. 9s 104sch 1cost plus contract, for schedule 1B, see schedule 1B, section 1.sch 2 def cost plus contract ins 2014 No. 57s 61(2)decision includes an order or direction.sch 2 def decision ins 2003 No. 30s 169sch 1~~default certificate see section 67AQ.~~Editor’s note—Schedule 2 definition default certificate incorporates an uncommenced amendment—see 2017 Act No. 13s 90sch 1.sch 2 def default certificate ins 2003 No. 1s 44(2)amd 2007 No. 47s 82(8)defective, in relation to building work, includes faulty or unsatisfactory.sch 2 def defective reloc 1999 No. 43s 4(4)defects document, for schedule 1B, see schedule 1B, section 1.sch 2 def defects document ins 2014 No. 57s 61(2)defects liability period, for part 4A, see section 67A.sch 2 def defects liability period ins 2017 No. 43s 307(2)demerit matter see section 67AQ.sch 2 def demerit matter ins 2003 No. 1s 44(2)demerit offence, for part 3E, see section 67AR.sch 2 def demerit offence ins 2003 No. 1s 44(2)demerit points see section 67AQ.sch 2 def demerit points ins 2003 No. 1s 44(2)sub 2017 No. 43s 307(1)–(2); 2018 No. 17s 196(3)design work means—
(a)the preparation of plans or specifications for building work; or
(b)professional advice in relation to building work.
sch 2 def design work reloc 1999 No. 43s 4(4)detached dwelling, for schedule 1B, see schedule 1B, section 1.sch 2 def detached dwelling ins 2014 No. 57s 61(2)determination ...sch 2 def determination reloc 1999 No. 43s 4(4)om 2000 No. 10s 183sch 1developer register, for part 8, see section 98.sch 2 def developer register ins 2007 No. 47s 82(2)development approval means a development approval under the Planning Act.sch 2 def development approval ins 2014 No. 57s 61(2)sub 2016 No. 27s 376(1)–(2)direction to rectify or remedy means a direction given under section 72(2).sch 2 def direction to rectify or remedy ins 2014 No. 57s 61(2)sub 2017 No. 43s 307disciplinary proceeding ...sch 2 def disciplinary proceeding ins 2003 No. 30s 169sch 1om 2014 No. 57s 61(1)display home ...sch 2 def display home reloc 1999 No. 43s 4(4)om 2000 No. 9s 104sch 1disqualified individual see section 67AU.sch 2 def disqualified individual ins 2003 No. 1s 44(2)document certification requirement, for part 9, see section 105Q(6).sch 2 def document certification requirement ins 2003 No. 1s 44(2)sub 2017 No. 29s 31(1)–(2)document production requirement, for part 9, see section 105Q(2).sch 2 def document production requirement ins 2003 No. 1s 44(2)sub 2017 No. 29s 31(1)–(2)domestic building contract, for schedule 1B, see schedule 1B, section 3.sch 2 def domestic building contract reloc 1999 No. 43s 4(4)sub 2000 No. 9s 104sch 1; 2014 No. 57s 60(1)–(2)domestic building dispute means—
(a)a claim or dispute arising between a building owner and a building contractor relating to the performance of reviewable domestic work or a contract for the performance of reviewable domestic work; or
(b)a claim or dispute arising between 2 or more building contractors relating to the performance of reviewable domestic work or a contract for the performance of reviewable domestic work; or
(c)a claim or dispute in negligence, nuisance or trespass related to the performance of reviewable domestic work other than a claim for personal injuries; or
(d)a claim or dispute arising between a building owner or a building contractor and any 1 or more of the following relating to the performance of reviewable domestic work or a contract for the performance of reviewable domestic work—
(i)an architect;
(ii)an engineer;
(iii)a surveyor;
(iv)a quantity surveyor;
(v)an electrician or an electrical contractor;
(vi)a supplier or manufacturer of materials used in the tribunal work.
sch 2 def domestic building dispute reloc 1999 No. 43s 4(4)om 2000 No. 10s 183sch 1ins 2003 No. 30s 169sch 1domestic building work see schedule 1B, section 4.sch 2 def domestic building work reloc 1999 No. 43s 4(4)om 2000 No. 9s 104sch 1ins 2003 No. 1s 44(2)sub 2014 No. 57s 61(1)–(2)amd 2018 No. 17s 196(4)draftsperson, for schedule 1B, see schedule 1B, section 1.sch 2 def draftsperson ins 2014 No. 57s 61(2)drainage see the Plumbing and Drainage Act 2018, schedule 1.sch 2 def drainage ins 2018 No. 17s 197sch 2electronic document, for part 9, see section 103G.sch 2 def electronic document ins 2017 No. 29s 31(2)employee of the employing office see section 29F(2).sch 2 def employee of the employing office ins 2007 No. 20s 59employing office means the Queensland Building and Construction Employing Office established under section 29A.sch 2 def employing office ins 2007 No. 20s 59amd 2013 No. 38s 11(4)enforcement debtor see the State Penalties Enforcement Act 1999, schedule 2.sch 2 def enforcement debtor ins 2007 No. 47s 82(2)enforcement order see the State Penalties Enforcement Act 1999, schedule 2.sch 2 def enforcement order ins 2007 No. 47s 82(2)engineer means a person who is a registered professional engineer under the Professional Engineers Act 2002.sch 2 def engineer sub 1992 No. 68s 3sch 1reloc 1999 No. 43s 4(4)amd 2002 No. 54s 166sch 1examine, for part 9, see section 103G.sch 2 def examine ins 2017 No. 29s 31(2)excluded building work, for schedule 1B, see schedule 1B, section 1.sch 2 def excluded building work ins 2014 No. 57s 61(2)excluded company see section 56AC(6).sch 2 def excluded company ins 1999 No. 43s 4(2)reloc 1999 No. 43s 4(4)sub 2003 No. 1s 44(1)–(2)amd 2014 No. 56s 67(2)excluded individual, for a relevant event, see section 56AC(3) and (4).sch 2 def excluded individual ins 1999 No. 43s 4(2)reloc 1999 No. 43s 4(4)sub 2003 No. 1s 44(1)–(2)exclusion notice see section 50CB(1).sch 2 def exclusion notice ins 2020 No. 24s 126(2)executive officer, for part 2A, means the executive officer of the employing office appointed under section 29D.sch 2 def executive officer, for part 2A, ins 2007 No. 20s 59executive officer, of a company, means a person who is—
(a)a director or secretary of the company; or
(b)a person who is concerned with, or takes part in, the company’s management, whether or not the person is a director or secretary of the company or the person’s position is given the name of executive officer.
sch 2 def executive officer, of a company, ins 1999 No. 43s 4(2)reloc 1999 No. 43s 4(4)exempt building work ...sch 2 def exempt building work om from prev s 4 1994 No. 20s 4(1)farm building, for schedule 1B, see schedule 1B, section 1.sch 2 def farm building prev def reloc 1999 No. 43s 4(4)om 2007 No. 47s 82(1)pres def ins 2014 No. 57s 61(2)field work means—
(a)a site investigation; or
(b)a site assessment; or
(c)soil sampling; or
(d)soil collection.
sch 2 def field work ins 1999 No. 43s 4(2)reloc 1999 No. 43s 4(4)fire protection equipment, for a building, means equipment for protecting all or part of the building from fire that consists of, or is a system comprised of, 1 or more of the following—
(a)a portable firefighting appliance, including, for example, a wheeled fire-extinguisher, fire hose or portable fire-extinguisher;
(b)a fire hydrant system, with or without a pump;
(c)a fire hose reel system, with or without a pump;
(d)a fire or smoke detection system, heat or smoke alarm or another alarm system or emergency warning and communication system;
(e)a fire suppression system or fire sprinkler system, whether solid-based, liquid-based or gas-based;
(f)a fire door, fire shutter or fire damper assembly;
(g)a fire or smoke wall;
(h)a fire collar;
(i)a fire penetration joint or seal;
(j)emergency lighting.
sch 2 def fire protection equipment ins 2020 No. 24s 126(2)fire protection occupational licence see section 30C(1) and (2).sch 2 def fire protection occupational licence ins 2007 No. 47s 82(2)fire protection system ...sch 2 def fire protection system ins 1999 No. 43s 4(2)reloc 1999 No. 43s 4(4)amd 2007 No. 47s 82(9)–(10)om 2020 No. 24s 126(1)fire protection work see section 30CA.sch 2 def fire protection work ins 2007 No. 47s 82(2)sub 2020 No. 24s 126foundations data, for schedule 1B, see schedule 1B, section 8.sch 2 def foundations data ins 2014 No. 57s 61(2)general power, for part 9, see section 105L(1).sch 2 def general power ins 2017 No. 29s 31(2)government entity see the Public Service Act 2008, section 24.sch 2 def government entity ins 2007 No. 20s 59amd 2009 No. 25s 83schhelp requirement, for part 9, see section 105M(1).sch 2 def help requirement ins 2017 No. 29s 31(2)home, for schedule 1B, see schedule 1B, section 9.sch 2 def home prev def reloc 1999 No. 43s 4(4)om 2000 No. 9s 104sch 1pres def ins 2014 No. 57s 61(2)home-building contract ...sch 2 def home-building contract reloc 1999 No. 43s 4(4)om 2000 No. 9s 104schidentity card, for part 9, see section 103G.sch 2 def identity card ins 2017 No. 29s 31(2)incomplete, for part 5, see section 67WA.sch 2 def incomplete ins 2014 No. 57s 61(2)industrial instrument see the Industrial Relations Act 2016, schedule 5.sch 2 def industrial instrument ins 2007 No. 20s 59amd 2016 No. 63s 1157sch 6influential person see section 4AA.sch 2 def influential person ins 1999 No. 43s 4(2)reloc 1999 No. 43s 4(4)sub 2003 No. 1s 44(1)–(2); 2017 No. 43s 307information notice, for part 9, see section 103G.sch 2 def information notice ins 2017 No. 29s 31(2)infringement notice see section 67AQ.sch 2 def infringement notice ins 2003 No. 1s 44(2)amd 2007 No. 47s 82(11)infringement notice offence see the State Penalties Enforcement Act 1999, schedule 2.sch 2 def infringement notice offence ins 2007 No. 47s 82(2)insolvent under administration has the meaning given by the Corporations Act, section 9.sch 2 def insolvent under administration ins 2013 No. 38s 11(2)install and installer, for part 6AA, see section 74AA.sch 2 def install and installer ins 2018 No. 17s 196(6)insurable value, for part 5, see section 67WA.sch 2 def insurable value ins 2014 No. 57s 61(2)insurance notification form means a form approved by the commission on which information about building work is submitted to the commission for covering the work under the statutory insurance scheme.sch 2 def insurance notification form ins 2000 No. 20s 29sch 3amd 2013 No. 38s 11(5); 2014 No. 57s 61(3)intended use, for a building product, see section 74AA.sch 2 def intended use ins 2017 No. 29s 31(2)internal review application, for part 7, division 3, subdivision 1, see section 85A.sch 2 def internal review application ins 2014 No. 56s 67(1)internal review decision, for part 7, division 3, subdivision 1, see section 86C(1).sch 2 def internal review decision ins 2014 No. 56s 67(1)internal reviewer, for part 7, division 3, subdivision 1, see section 85A.sch 2 def internal reviewer ins 2016 No. 11s 23interstate or New Zealand licence means a licence granted by an interstate or New Zealand licensing authority that authorises the carrying out of building work that is equivalent, or substantially equivalent, to building work authorised under a licence under this Act.sch 2 def interstate or New Zealand licence ins 2020 No. 24s 126(2)interstate or New Zealand licensing authority means an entity established under a law of another State or New Zealand having functions similar to the commission’s functions for granting licences under this Act.sch 2 def interstate or New Zealand licensing authority ins 2020 No. 24s 126(2)judgment debt see section 67AS.sch 2 def judgment debt ins 2003 No. 1s 44(2)level 1 regulated contract, for schedule 1B, see schedule 1B, section 6.sch 2 def level 1 regulated contract ins 2014 No. 57s 61(2)level 2 regulated contract, for schedule 1B, see schedule 1B, section 7.sch 2 def level 2 regulated contract ins 2014 No. 57s 61(2)licence means a licence under this Act.sch 2 def licence reloc 1999 No. 43s 4(4)licence card means a licence card issued under section 34.sch 2 def licence card ins 2007 No. 47s 82(2)licence certificate means a licence certificate issued under section 34.sch 2 def licence certificate ins 2007 No. 47s 82(2)licensed builder means a person who is a licensed builder under the regulations.sch 2 def licensed builder ins 1994 No. 20s 4(2)reloc 1999 No. 43s 4(4)licensed contractor means a person who holds a contractor’s licence.sch 2 def licensed contractor reloc 1999 No. 43s 4(4)licensed supervisor, for building work, means a person who holds a licence under this Act authorising supervision of building work of the relevant class.sch 2 def licensed supervisor reloc 1999 No. 43s 4(4)sub 2007 No. 47s 82(1)–(2)licensee means a person who holds a licence.sch 2 def licensee reloc 1999 No. 43s 4(4)licensee register, for part 8, see section 98.sch 2 def licensee register ins 2007 No. 47s 82(2)major commercial building dispute means a commercial building dispute where either the claim or the counterclaim exceeds $50,000.sch 2 def major commercial building dispute ins 2003 No. 30s 169sch 1major domestic building work ...sch 2 def major domestic building work reloc 1999 No. 43s 4(4)om 2000 No. 9s 104sch 1manage, for schedule 1B, see schedule 1B, section 1.sch 2 def manage ins 2014 No. 57s 61(2)management services, for building work or tribunal work, includes—
(a)coordinating the scheduling of the work by building contractors including as agent for another person; and
(b)management for the work usually carried out by—
(i)a construction manager; or
(ii)a project manager under a project management agreement; and
(c)other management for the work usually carried out by a licensed contractor in the course of the contractor’s business.
sch 2 def management services ins 2007 No. 47s 82(2)mechanical services occupational licence see section 30D(1) and (2).sch 2 def mechanical services occupational licence ins 2018 No. 17s 196(1)mechanical services work means—
(a)the construction, installation, replacement, repair, alteration, maintenance, testing or commissioning of a mechanical heating or cooling system in a building, that is associated with the heating or cooling of that building and includes the construction, installation, replacement, repair, alteration, maintenance, testing or commissioning of—
(i)a valve, regulator, register, pipe, tank, heating or cooling pipe or surface, solid fuel heater, coil or other item that is used in the system; and
(ii)in relation to a cooling tower—a water pipe, valve, pump, automated dosing device or automated bleeding device or any other mechanical component that affects the cooling tower's cooling water flow rate or wastewater disposal; and
(b)the construction, installation, replacement, repair, alteration, maintenance, testing and commissioning of a medical gas system; and
(c)any design work that is—
(i)incidental to, or associated with work mentioned in paragraph (a); and
(ii)prescribed by regulation;
but does not include—
(d)gas work regulated under the Petroleum and Gas (Production and Safety) Act 2004; or
(e)any treatment of cooling water; or
(f)the connection or disconnection of a system mentioned in paragraph (a) or (b) from a water supply other than disconnection of the system from a water supply at an isolating valve adjacent to a mechanical component of that system; or
(g)design work that is a professional engineering service under the Professional Engineers Act 2002; or
(h)manufacturing of pipe or ducting or components manufactured off-site; or
(i)installation of a single head split system; or
(j)installing ductwork and enclosures for air-conditioning, air handling and mechanical ventilation systems; or
(k)any other work prescribed by regulation.
sch 2 def mechanical services work ins 2018 No. 17s 196(1)medical gas means any gas or mixture of gases or other substance or process used for hospital or medical use that is supplied to, removed from or conducted at, a hospital or other place where medical procedures are carried out, by way of a pipeline reticulation system and includes oxygen, helium, nitrous oxide, nitrogen, medical air, surgical tool gas, carbon dioxide and common mixtures of those gases as well as anaesthesia waste.sch 2 def medical gas ins 2018 No. 17s 196(1)medical gas system means any fixed component used—
(a)in a reticulation system for the supply or removal of medical gas from the gas source to a wall outlet; and
(b)for patient care, therapeutic, diagnostic purposes or surgical tools.
sch 2 def medical gas system ins 2018 No. 17s 196(1)member means member of the board.sch 2 def member ins 2013 No. 38s 11(2)minimum financial requirements means the financial requirements prescribed by regulation.sch 2 def minimum financial requirements ins 2017 No. 43s 307(2)minor commercial building dispute means a commercial building dispute where neither the claim nor the counterclaim exceeds $50,000.sch 2 def minor commercial building dispute ins 2003 No. 30s 169sch 1minor domestic building dispute means a domestic building dispute where neither the claim nor the counterclaim exceeds $10,000.sch 2 def minor domestic building dispute ins 2003 No. 30s 169sch 1mixed-purpose contract, for schedule 1B, see schedule 1B, section 1.sch 2 def mixed-purpose contract ins 2014 No. 57s 61(2)nominated supervisor ...sch 2 def nominated supervisor reloc 1999 No. 43s 4(4)om 2003 No. 1s 44(1)nominee, in relation to a company, means an officer or employee of the company nominated by the company to have the general supervision of building work to be carried out under a licence.sch 2 def nominee ins 2003 No. 1s 44(2)nominee supervisor means a person who holds a nominee supervisor’s licence.sch 2 def nominee supervisor ins 2007 No. 47s 82(2)nominee supervisor’s licence see section 30A(1).sch 2 def nominee supervisor’s licence ins 2007 No. 47s 82(2)non-compliance risk, for part 6AA, see section 74AA.sch 2 def non-compliance risk ins 2017 No. 29s 31(2)non-conforming building product see section 74AB(2).sch 2 def non-conforming building product ins 2017 No. 29s 31(2)notifiable incident means—
(a)the death or serious injury or illness of a person; or
(b)an incident that exposes a person to a risk of serious injury or illness.Example for paragraph (b)—the collapse or partial collapse of a building
sch 2 def notifiable incident ins 2017 No. 29s 31(2)occupational licence means a licence or registration for an occupation relating to building work that is—
(a)given to a person under an Act prescribed by regulation; and
(b)required by the person to carry out the occupation.
sch 2 def occupational licence ins 2003 No. 1s 44(2)amd 2013 No. 38s 11(5)sub 2020 No. 24s 126occupier, for part 9, see section 103G.sch 2 def occupier ins 2017 No. 29s 31(2)offence warning, for part 9, see section 103G.sch 2 def offence warning ins 2017 No. 29s 31(2)optional additional cover, for part 5, see section 67Z(4).sch 2 def optional additional cover ins 2014 No. 57s 61(2)owner—
(a)of land generally, means—
(i)for freehold land—the registered owner of the land under the Land Title Act 1994; or
(ii)for land held under a statutory lease or licence giving a right to possession of the land—the lessee or licensee; and
(b)of land, for part 3, division 8—see also section 43D; and
(c)of a seized thing under part 9—see section 103G.
sch 2 def owner sub 1994 No. 11s 194sch 2reloc 1999 No. 43s 4(4)amd 2007 No. 47s 82(12)sub 2017 No. 29s 31(1)–(2)owner-builder course, for part 3, division 8, see section 43D.sch 2 def owner-builder course ins 2007 No. 47s 82(2)owner-builder permit see section 43E.sch 2 def owner-builder permit reloc 1999 No. 43s 4(4)sub 2007 No. 47s 82(1)–(2)owner-builder register, for part 8, see section 98.sch 2 def owner-builder register ins 2007 No. 47s 82(2)owner-builder work see section 43D.sch 2 def owner-builder work ins 2007 No. 47s 82(2)payment claim, for part 4A, see section 67A.sch 2 def payment claim ins 2004 No. 6s 113sch 1performance solution see the Building Act 1975, schedule 2.sch 2 def performance solution ins 2020 No. 24s 153 sch 1pt 2period of 3 years, for part 3E, see section 67AQ.sch 2 def period of 3 years ins 2003 No. 1s 44(2)permanently excluded individual see section 58.sch 2 def permanently excluded individual ins 2003 No. 1s 44(2)permitted individual ...sch 2 def permitted individual ins 1999 No. 43s 4(2)reloc 1999 No. 43s 4(4)sub 2003 No. 1s 44(1)–(2)om 2014 No. 57s 61(1)permittee means the holder of an owner-builder permit under this Act.sch 2 def permittee ins 2007 No. 47s 82(2)personal details requirement, for part 9, see section 105O(5).sch 2 def personal details requirement ins 2017 No. 29s 31(2)personally supervise, in relation to building work, means personally exercise control over the work by overseeing and directing the work to ensure it is—
(a)in accordance with the plans and specifications set out in the contract for the work; and
(b)of a standard expected of a competent holder of a contractor’s licence of the relevant class.
sch 2 def personally supervise ins 2007 No. 47s 82(2)person in control, for part 9, see section 103G.sch 2 def person in control ins 2017 No. 29s 31(2)person in the chain of responsibility, for a building product, see section 74AE.sch 2 def person in the chain of responsibility ins 2017 No. 29s 31(2)PIN see section 34A.sch 2 def PIN ins 2000 No. 20s 29sch 3place, for part 9, see section 103G.sch 2 def place ins 2017 No. 29s 31(2)Planning Act means the Planning Act 2016.sch 2 def Planning Act ins 2016 No. 27s 376(2)plumbing see the Plumbing and Drainage Act 2018, schedule 1.sch 2 def plumbing ins 2018 No. 17s 197sch 2practical completion, for schedule 1B, see schedule 1B, section 1.sch 2 def practical completion ins 2014 No. 57s 61(2)practical completion, for part 4A, see section 67A.sch 2 def practical completion ins 2017 No. 43s 307(2)premises, for part 9, see section 103G.sch 2 def premises ins 2017 No. 29s 31(2)primary insurable work, for part 5, see section 67WC.sch 2 def primary insurable work ins 2014 No. 57s 61(2)prime cost item, for schedule 1B, see schedule 1B, section 1.sch 2 def prime cost item ins 2014 No. 57s 61(2)principal see section 67A.sch 2 def principal ins 1999 No. 43s 4(2)reloc 1999 No. 43s 4(4)amd 2007 No. 47s 82(13)private sector entity means an entity that is not owned, either wholly or partly, by the State, the Commonwealth or a local government, or any of their authorities or agencies.sch 2 def private sector entity ins 2013 No. 58s 32(2)progress payment—
(a)for part 4A, see section 67A; and
(b)for schedule 1B, see schedule 1B, section 1.
sch 2 def progress payment ins 1999 No. 43s 4(2)reloc 1999 No. 43s 4(4)sub 2014 No. 57s 61(1)–(2)project management agreement means a contract under which a principal engages a project manager to provide building work services for building work carried out for the principal other than under construction management trade contracts.sch 2 def project management agreement ins 2007 No. 47s 82(2)project manager means a person who provides building work services for the carrying out of building work for a principal under a project management agreement.sch 2 def project manager ins 2007 No. 47s 82(2)provisional sum, for schedule 1B, see schedule 1B, section 10.sch 2 def provisional sum ins 2014 No. 57s 61(2)public place, for part 9, see section 103G.sch 2 def public place ins 2017 No. 29s 31(2)public-private partnership means an arrangement between the following entities with the purpose of financing, designing, constructing, maintaining or operating public infrastructure—
(a)the State, the Commonwealth or a local government, or any of their authorities or agencies;
(b)1 or more private sector entities.
sch 2 def public-private partnership ins 2013 No. 58s 32(2)qualified accountant see section 50CA(1).sch 2 def qualified accountant ins 2020 No. 24s 126(2)Real Property Acts ...sch 2 def Real Property Acts om from prev s 4 1994 No. 11s 194sch 2reasonably believes means believes on grounds that are reasonable in the circumstances.sch 2 def reasonably believes ins 2014 No. 57s 61(2)sub 2017 No. 29s 31(1)–(2)reasonably practicable, for part 6AA, see section 74AA.sch 2 def reasonably practicable ins 2017 No. 29s 31(2)reasonably suspects, for part 9, see section 103G.sch 2 def reasonably suspects ins 2017 No. 29s 31(2)recall order, for part 6AA, see section 74AW(1).sch 2 def recall order ins 2017 No. 29s 31(2)recorded conviction, for an indictable offence, does not include a finding of guilt, or the acceptance of a plea of guilty, by a court, in relation to the offence, without recording a conviction for the offence.sch 2 def recorded conviction ins 2013 No. 38s 11(2)rectify building work means to remedy defective building work or to complete incomplete building work.sch 2 def rectify reloc 1999 No. 43s 4(4)registrar means the principal registrar under the Tribunal Act.Editor’s note—Schedule 2 definition registrar incorporates an uncommenced amendment—see 2017 Act No. 13s 90sch 1.registrar—
(a)for part 3E—see section 67AQ; or
(b)otherwise—means the principal registrar under the Tribunal Act.
sch 2 def registrar ins 2003 No. 1s 44(2)sub 2009 No. 24s 1697(2)registrar of titles, for land that is not under the Land Title Act 1994, means the officer responsible for keeping a register for the land.sch 2 def registrar of titles sub 1994 No. 11s 194sch 2reloc 1999 No. 43s 4(4)regulated amount, for schedule 1B, see schedule 1B, section 1.sch 2 def regulated amount ins 2014 No. 57s 61(2)regulated contract, for schedule 1B, see schedule 1B, section 5.sch 2 def regulated contract ins 2014 No. 57s 61(2)related roofed building, for part 5, see section 67WF.sch 2 def related roofed building ins 2014 No. 57s 61(2)relevant Act, for part 9, see section 103G.sch 2 def relevant Act ins 2017 No. 29s 31(2)relevant bankruptcy event see section 56AC(1)(a).sch 2 def relevant bankruptcy event ins 1999 No. 43s 4(2)reloc 1999 No. 43s 4(4)sub 2003 No. 1s 44(1)–(2)relevant company event see section 56AC(2)(b).sch 2 def relevant company event ins 1999 No. 43s 4(2)reloc 1999 No. 43s 4(4)sub 2003 No. 1s 44(1)–(2)relevant details, for part 3A, division 4, see section 56AI(2).sch 2 def relevant details ins 2020 No. 24s 149relevant entity, for part 9A, see section 108AA(1).sch 2 def relevant entity ins 2014 No. 56s 67(1)relevant event means a relevant bankruptcy event or a relevant company event.sch 2 def relevant event ins 1999 No. 43s 4(2)reloc 1999 No. 43s 4(4)sub 2003 No. 1s 44(1)–(2)relevant officer, of the commission, means—
(a)an employee of the employing office or of another government entity performing work for the commission under a work performance arrangement; or
(b)an officer or employee of the commission.
sch 2 def relevant officer ins 2007 No. 20s 59amd 2013 No. 38s 11(5)relevant regulatory provisions, for part 6AA, see section 74AA.sch 2 def relevant regulatory provisions ins 2017 No. 29s 31(2)relevant work, for part 6AA, see section 74AA.sch 2 def relevant work ins 2017 No. 29s 31(2)renewal day, for a licence, means the day the licence is due to be renewed.sch 2 def renewal day ins 2007 No. 47s 82(2)representation, for part 6AA, see section 74AA.sch 2 def representation ins 2017 No. 29s 31(2)residence, for part 5, see section 67WE.sch 2 def residence ins 2014 No. 57s 61(2)residential construction work see section 67WA.sch 2 def residential construction work reloc 1999 No. 43s 4(4)sub 2014 No. 57s 61(1)–(2)amd 2018 No. 17s 196(5)residential unit means a part of a building designed for separate occupation as a residence.sch 2 def residential unit ins 2007 No. 47s 82(2)resident owner, for schedule 1B, see schedule 1B, section 1.sch 2 def resident owner ins 2014 No. 57s 61(2)responsible person, for part 6AA, see section 74AA.sch 2 def responsible person ins 2018 No. 17s 196(6)retention amount, for part 4A, see section 67A.sch 2 def retention amount ins 1999 No. 43s 4(2)reloc 1999 No. 43s 4(4)review means review by the tribunal.sch 2 def review ins 2000 No. 10s 183sch 1reviewable commercial work means tribunal work other than reviewable domestic work.sch 2 def reviewable commercial work ins 2003 No. 30s 169sch 1reviewable decision—
(a)for part 7, division 3, subdivision 1, see section 86; or
(b)for part 7, division 3, subdivision 2, see section 86E.
sch 2 def reviewable decision ins 2014 No. 56s 67(1)reviewable domestic work means domestic building work under schedule 1B, section 4, except that for applying schedule 1B, section 4(8), the definition excluded building work under the schedule is taken not to mean anything mentioned in paragraph (b), (c) or (d) of that definition.sch 2 def reviewable domestic work ins 2003 No. 30s 169sch 1sub 2014 No. 57s 61(1)–(2)safe, for part 6AA, see section 74AA.sch 2 def safe ins 2017 No. 29s 31(2)safety risk, for part 6AA, see section 74AA.sch 2 def safety risk ins 2017 No. 29s 31(2)schedule section, for schedule 1B, see schedule 1B, section 1.sch 2 def schedule section ins 2014 No. 57s 61(2)security, for part 4A, see section 67A.sch 2 def security ins 1999 No. 43s 4(2)reloc 1999 No. 43s 4(4)seized thing, for part 9, see section 103G.sch 2 def seized thing ins 2017 No. 29s 31(2)serious injury or illness, of a person, means an injury or illness requiring the person to have—
(a)immediate treatment as an inpatient in a hospital; or
(b)immediate treatment for—
(i)the amputation of any part of his or her body; or
(ii)a serious head injury; or
(iii)a serious eye injury; or
(iv)a serious burn; or
(v)the separation of his or her skin from an underlying tissue (for example, degloving or scalping); or
(vi)a spinal injury; or
(vii)the loss of a bodily function; or
(viii)serious lacerations; or
(c)medical treatment within 48 hours of exposure to a substance.
sch 2 def serious injury or illness ins 2017 No. 29s 31(2)Service Trades Council means the Service Trades Council continued in existence under the Plumbing and Drainage Act 2018, section 105.sch 2 def Service Trades Council ins 2016 No. 11s 23amd 2018 No. 17s 197sch 2site classification means the classification of a site, or the reclassification of a site, under a standard directed to ensuring the appropriate selection or design of footings.sch 2 def site classification ins 1999 No. 43s 4(2)reloc 1999 No. 43s 4(4)site supervisor means a person who holds a site supervisor’s licence.sch 2 def site supervisor ins 2007 No. 47s 82(2)site supervisor’s licence see section 30B(1) and (2).sch 2 def site supervisor’s licence ins 2007 No. 47s 82(2)site testing means—
(a)field work for soil testing or site classification; or
(b)laboratory testing of soil.
sch 2 def site testing ins 1999 No. 43s 4(2)reloc 1999 No. 43s 4(4)special purpose vehicle means an entity—
(a)established for the purpose of carrying out a public-private partnership; and
(b)declared by the Treasurer by gazette notice to be a special purpose vehicle for this Act.
sch 2 def special purpose vehicle ins 2013 No. 58s 32(2)speculative residential construction work, for part 5, see section 67WA.sch 2 def speculative residential construction work ins 2007 No. 47s 82(2)sub 2014 No. 57s 61(1)–(2)spent conviction means a conviction—
(a)for which the rehabilitation period under the Criminal Law (Rehabilitation of Offenders) Act 1986 has expired under that Act; and
(b)that is not revived as prescribed by section 11 of that Act.
sch 2 def spent conviction ins 2013 No. 38s 11(2)SPER, for part 3E, see section 67AQ.sch 2 def SPER ins 2003 No. 1s 44(2)statutory insurance scheme means the insurance scheme established under part 5.sch 2 def statutory insurance scheme reloc 1999 No. 43s 4(4)statutory warranties, for schedule 1B, see schedule 1B, section 1.sch 2 def statutory warranties ins 2014 No. 57s 61(2)subcontract, for part 4A, see section 67A.sch 2 def subcontract ins 1999 No. 43s 4(2)reloc 1999 No. 43s 4(4)subcontractor—
(a)for part 7—means—
(i)a building contractor who carries out tribunal work for another building contractor; or
(ii)a building contractor who carries out tribunal work for another person under a construction management trade contract under section 67B; and
(b)for schedule 1B, see schedule 1B, section 1.
sch 2 def subcontractor ins 2003 No. 30s 169sch 1amd 2004 No. 53s 2schsub 2014 No. 57s 61(1)–(2)subject work, for schedule 1B, see schedule 1B, section 1.sch 2 def subject work ins 2014 No. 57s 61(2)supervisor’s licence ...sch 2 def supervisor’s licence reloc 1999 No. 43s 4(4)om 2007 No. 47s 82(1)supervisory services, for building work or tribunal work, includes—
(a)the development, implementation and management of a system for the supervision of the work; and
(b)the coordination or management of persons undertaking the supervision of the work; and
(c)the personal supervision of the work; and
(d)any other supervision of building work under this Act.
sch 2 def supervisory services ins 2007 No. 47s 82(2)term of ban see section 67AO.sch 2 def term of ban ins 2003 No. 1s 44(2)term of disqualification, for part 3E, see section 67AZM.sch 2 def term of disqualification ins 2003 No. 1s 44(2)tier 1 defective work see section 67AB(1).sch 2 def tier 1 defective work ins 2003 No. 1s 44(2)trade licence ...sch 2 def trade licence reloc 1999 No. 43s 4(4)om 2004 No. 53s 2schtrainee see the Further Education and Training Act 2014, schedule 1.sch 2 def trainee ins 2007 No. 47s 82(2)sub 2014 No. 25s 223 sch 1pt 2tribunal means QCAT.sch 2 def tribunal reloc 1999 No. 43s 4(4)sub 2000 No. 10s 183sch 1; 2003 No. 30s 169sch 1; 2009 No. 24s 1697(3)Tribunal Act ...sch 2 def Tribunal Act ins 2000 No. 10s 183sch 1sub 2003 No. 30s 169sch 1om 2009 No. 24s 1697(1)tribunal work see sections 75 and 76.sch 2 def tribunal work ins 2007 No. 47s 82(2)undertake to carry out, for building work, means any of the following—
(a)enter into a contract to carry out the work;
(b)submit a tender to carry out the work;
(c)make an offer to carry out the building work.
sch 2 def undertake to carry out ins 2007 No. 47s 82(2)unsatisfied, in relation to a judgment debt, see section 67AT.sch 2 def unsatisfied ins 2003 No. 1s 44(2)valuable instrument, for part 4A, see section 67A.sch 2 def valuable instrument ins 1999 No. 43s 4(2)reloc 1999 No. 43s 4(4)value of building work means an amount representing the reasonable cost to a consumer of having the work carried out by a licensed contractor on the basis that all building materials are to be supplied by the contractor (whether or not the work is in fact carried out by a licensed contractor on that basis).sch 2 def value reloc 1999 No. 43s 4(4)variation, for part 4A, see section 67A.sch 2 def variation ins 1999 No. 43s 4(2)reloc 1999 No. 43s 4(4)warning statement, for part 6AA, see section 74AZC(1).sch 2 def warning statement ins 2017 No. 29s 31(2)work performance arrangement means an arrangement under which an employee of a government entity performs work for another government entity.sch 2 def work performance arrangement ins 2007 No. 20s 59written form, for schedule 1B, see schedule 1B, section 1.sch 2 def written form prev def ins 1999 No. 43s 4(2)reloc 1999 No. 43s 4(4)om 2004 No. 6s 113sch 1pres def ins 2014 No. 57s 61(2)sch 2 ins 1999 No. 43s 39Note—definitions for this Act were originally located in s 4.